CONFIDENTIAL TREATMENT EXHIBIT 10.3
CONFIDENTIAL AND PROPRIETARY
IRU AGREEMENT
DATED AS OF MAY 2, 1997
BY AND BETWEEN
QWEST COMMUNICATIONS CORPORATION ("QWEST")
AND
GTE INTELLIGENT NETWORK SERVICES INCORPORATED ("GTE")
TABLE OF CONTENTS
Page
RECITALS
ARTICLE X. XXXXX OF IRU IN QWEST SYSTEM. . . . . . . . . . . . . . . . . .
ARTICLE II. CONSIDERATION FOR GRANT. . . . . . . . . . . . . . . . . . . .
ARTICLE III. CONSTRUCTION OF THE QWEST SYSTEM. . . . . . . . . . . . . . .
ARTICLE IV. ACCEPTANCE AND TESTING OF GTE FIBERS . . . . . . . . . . . . .
ARTICLE V. DOCUMENTATION . . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE VI. TERM . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE VII. NETWORK ACCESS; REGENERATION FACILITIES . . . . . . . . . . .
ARTICLE VIII. OPERATIONS . . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE IX. MAINTENANCE AND REPAIR OF THE QWEST SYSTEM . . . . . . . . . .
ARTICLE X. PERMITS; UNDERLYING RIGHTS; RELOCATION. . . . . . . . . . . . .
ARTICLE XI. USE OF QWEST SYSTEM. . . . . . . . . . . . . . . . . . . . . .
ARTICLE XII. INDEMNIFICATION . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XIII. LIMITATION OF LIABILITY. . . . . . . . . . . . . . . . . . .
ARTICLE XIV. INSURANCE . . . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XV. TAXES, FEES AND OTHER GOVERNMENTAL IMPOSITIONS . . . . . . . .
ARTICLE XVI. NOTICE. . . . . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XVII. CONFIDENTIALITY. . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XVIII. DEFAULT . . . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XIX. TERMINATION . . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XX. FORCE MAJEURE. . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XXI. DISPUTE RESOLUTION. . . . . . . . . . . . . . . . . . . . . .
ARTICLE XXII. WAIVER . . . . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XXIII.GOVERNING LAW. . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XXIV. RULES OF CONSTRUCTION. . . . . . . . . . . . . . . . . . . .
ARTICLE XXV. ASSIGNMENT AND TRANSFER RESTRICTIONS. . . . . . . . . . . . .
ARTICLE XXVI. REPRESENTATIONS, WARRANTIES AND ACKNOWLEDGMENTS. . . . . . .
ARTICLE XXVII. ENTIRE AGREEMENT; AMENDMENT . . . . . . . . . . . . . . . .
ARTICLE XXVIII. NO PERSONAL LIABILITY. . . . . . . . . . . . . . . . . . .
ARTICLE XXIX. RELATIONSHIP OF THE PARTIES. . . . . . . . . . . . . . . . .
ARTICLE XXX. LATE PAYMENTS . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XXXI. SEVERABILITY . . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XXXII. COUNTERPARTS. . . . . . . . . . . . . . . . . . . . . . . .
ARTICLE XXXIII. CERTAIN DEFINITIONS. . . . . . . . . . . . . . . . . . . .
EXHIBITS
Exhibit A: QWEST System Description
Exhibit A-1: QWEST System Description and Delivery Dates
Exhibit A-2: General Route Map
Exhibit A-3: Detailed Route Maps
Exhibit A-4: Designated Endpoint and Intermediate Point Cities
Exhibit B: IRU Fee Payment Schedule
Exhibit C: Construction Specifications
Exhibit D: Fiber Cable Splicing, Testing, and Acceptance Procedures
Exhibit E: Fiber Specifications
Exhibit E-1: Fiber Deployment Diagram
Exhibit F: Specifications for Regeneration Facilities
Page 1
CONFIDENTIAL TREATMENT
Exhibit G: Regeneration Facility Sites
Exhibit H: QWEST System Maintenance Specifications and Procedures
Exhibit I: Underlying Rights and Underlying Rights Requirements
IRU AGREEMENT
THIS IRU AGREEMENT (this "Agreement") is made and entered into as of May 2,
1997, by and between QWEST COMMUNICATIONS CORPORATION, a Delaware corporation
("QWEST"), and GTE INTELLIGENT NETWORK SERVICES INCORPORATED, a Delaware
corporation ("GTE").
RECITALS
A. QWEST is planning to construct a continuous fiberoptic communication system,
contiguous from end to end, as described in Exhibit A hereto, and between each
of the city pairs identified in Exhibit A-1 hereto (the fiberoptic communication
system between each such city pair being referred to as a "Segment"), being
referred to herein collectively as the "QWEST System". The route that the QWEST
System shall follow as described in this paragraph is referred to herein as the
"System Route."
B. GTE desires to be granted the right to use certain optical fibers in the
QWEST System.
C. QWEST desires to grant GTE an exclusive, indefeasible right to use certain
fibers and associated property in the QWEST System, all upon the terms and
conditions set forth below. Accordingly, in consideration of the mutual promises
set forth below, and other good and valuable consideration, the receipt and
sufficiency of which are hereby acknowledged, the parties hereby agree as
follows:
ARTICLE X.
XXXXX OF IRU IN QWEST SYSTEM
1.1 (a) Effective as of the effective date described in Section 6.1 below,
for each particular Segment delivered by QWEST to GTE hereunder and with respect
to which an Acceptance Date (as defined in Section 4.2 below) has occurred,
QWEST hereby grants to GTE, and GTE hereby purchases from QWEST, (i) an
exclusive, Indefeasible Right of Use (as defined in Section 33.1(f), for the
purposes described herein, in twenty-four (24) "Dark Fibers" (as defined in
Section 33.1(c)), to be specifically identified, in the QWEST System in the
Segments and more specifically described in the maps included in Exhibit A-3
hereto and (ii) an associated and non-exclusive Indefeasible Right of Use, for
the purposes described herein, in the tangible and intangible property needed
for the use of such Dark Fibers as Dark Fibers, including, but not limited to,
the associated conduit, QWEST's rights in all "Underlying Rights" (as defined in
Section 10.1), but in any event excluding any electronic or optronic equipment
(collectively, the "Associated Property"), for the Term (as defined in Section
6.1) respecting such Segment, and all on the terms and subject to the covenants
and conditions set forth herein (collectively, the "IRUs"). The Dark Fibers
subject to the IRUs are referred to collectively as the "GTE Fibers."
(b) The parties acknowledge and agree that the specific route of any Segment
that has not been finally designed or engineered, or with respect to which a
right-of-way agreement has not been obtained as of the date hereof is subject to
final determination by QWEST, based on specific engineering, right-of-way,
permitting, authorization and other requirements; provided, however, that (i)
any such Segment route, as finally determined, must include all of the endpoint
and intermediate point cities identified in Exhibit A-4 and all of the junction
points identified in the System Route maps included in Exhibit A; (ii) no
deviation in the route of any Segment as set forth in the maps included in
Exhibit A-3 shall result in a Material Deviation (as defined below) in the
System Route as set forth in Exhibit A, and (iii) once the final route of any
Segment has been so determined, QWEST shall deliver to GTE corresponding
revisions to the relevant maps included in Exhibit A hereto. As used herein, the
term "Material Deviation" shall mean a deviation in the general route
Page 2
CONFIDENTIAL TREATMENT
of a Segment (A) that modifies the System Route architecture in a manner that
breaks a ring, creates a spur or breaks the contiguous nature of Segments; (B)
that modifies the route of the System Route through any city, identified in
Exhibit A-3 as being the location of a GTE POP site, from the detailed route map
shown in Exhibit A-3 for such city in a manner that materially changes the
proximity of such POP site to the System Route right-of-way (provided that, if
any such detailed city map shows that the POP site is in direct proximity to the
System Route right-of-way, any route modification which does not provide such
direct proximity shall be considered a material change in proximity); (C) that
modifies the route of the System Route through any city, as set forth in the
detailed route map for such city set forth in Exhibit A-3, such that the
location of the route at any point would be moved more than 1,200 feet in any
direction, without the prior written approval of GTE (such approval not to be
unreasonably withheld or delayed); or (D) that modifies any parallel route shown
within any city that is the subject of a detailed map included in Exhibit A-3
such that the distance between such parallel routes is less than 1,200 feet
outside metropolitan areas and less than two city blocks within metropolitan
areas.
(c) If any deviation(s) in the routes of Segments comprising the System
Route cause(s) the aggregate route miles as reflected in Exhibit A estimated for
the System Route to increase by more than ##MATERIAL OMITTED AND SEPARATELY
FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## %) of such estimate such
mileage shall be solely at QWEST's cost and expense and any route mileage in
excess of the applicable ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## %) increase as aforesaid shall not be
included in the route mileage for purposes of determining the IRU Fee as defined
and described in Section 2.1 below.
ARTICLE II.
CONSIDERATION FOR GRANT
2.1 In consideration of the grant of the IRUs hereunder by QWEST to GTE, GTE
agrees to pay to QWEST an IRU fee determined based on the QWEST mileage (and
allocated among the Segments based on Segment Rate mileage as set forth in
Exhibit B. (the "IRU Fee").
The IRU Fee shall be payable with respect to each Segment according to the
payment schedule set forth in Exhibit B.
2.2 QWEST will fax or send by overnight delivery each invoice for payments
to be made by GTE hereunder. GTE shall pay such invoiced amounts, less any
reasonably disputed amounts, for receipt by QWEST within thirty (30) days after
receipt of such invoice by GTE with respect to payments of the IRU Fee and
within thirty (30) days after receipt of such invoice by GTE for any other
amounts owed to QWEST hereunder; provided that GTE shall provide written notice
describing in detail the basis for any disputed amounts; and provided further
that any disputed amounts that are resolved in favor of QWEST shall be due for
payment based on the original invoice date. All payments to be made by GTE
hereunder of the IRU Fee and of any other amounts in excess of $100,000 shall be
made by wire transfer of immediately available funds to the account or accounts
as QWEST shall notify GTE in writing from time to time. Payments of all other
amounts by GTE hereunder may be made by check payable to QWEST. QWEST agrees to
provide GTE from time to time, upon request, with QWEST's estimate of the next
invoice date for a portion of the IRU Fee and the estimated amount of such IRU
Fee payment; provided that failure to provide any such notice shall not in any
way alter or impair GTE's payment obligations hereunder.
2.3 QWEST and GTE acknowledge and agree that with respect to Segment 23,
notwithstanding the fact that Segment 23 has already been constructed and
installed, delivery of Segment 23 shall occur in two installments of twelve (12)
Dark Fibers each as indicated in Exhibit A, and payment of the IRU Fee
established pursuant to Section 2.1 therefor (other than the initial
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
Page 3
CONFIDENTIAL TREATMENT
CONFIDENTIAL TREATMENT## % due upon execution of this Agreement), shall be
deferred until each such deferred installment delivery date as set forth in
Exhibit B.
ARTICLE III.
CONSTRUCTION OF THE QWEST SYSTEM
3.1 QWEST shall, at QWEST's sole cost and expense, be responsible for and
shall effect the design, engineering, installation, and construction of those
portions of the QWEST System not already constructed as of the date hereof in
accordance with the System Route (as it may be modified pursuant to Section 1.1)
and in conformity with (i) the construction specifications set forth in Exhibit
C, (ii) industry standards and practices, and (iii) applicable Underlying Rights
Requirements (as defined in Section 11.1). Such responsibilities shall include,
without limitation, preparation of construction drawings, bills of materials,
materials specifications and materials requisitions. Except for the existing
fibers on Segments 11A, 00X, 00X, 00X, 00X and 12D (which are Corning SMF-DS)
and any alternative fibers approved pursuant to the following sentence, all
fiber included in the GTE Fibers shall be Corning SMF-LS non-zero dispersion-
shifted or Lucent Technologies True Wave and shall meet or exceed the applicable
fiber specifications set forth in Exhibit E. QWEST may use alternative types of
fiber equivalent to either of the aforementioned fibers; provided that (i) prior
to any such use, QWEST meets with GTE (and GTE hereby agrees to so meet) to,
cooperatively and in good faith, jointly evaluate the use of any such fiber and
(ii) thereafter, GTE approves the use of such fiber, which approval shall not be
unreasonably withheld or delayed. QWEST agrees that, to the extent possible in
light of the fiber already incorporated in Segments that have been constructed,
in whole or in part, prior to the date hereof and the availability and cost of
the fiber of a particular type and manufacture hereafter, fiber utilized with
respect to the loops, rings and regions of the QWEST System shall be of the same
type and manufacture, as depicted in the fiber deployment diagram set forth in
Exhibit E-1 hereto, indicating the type of fiber QWEST currently plans to use in
each such Segment. Any deviation from the planned fiber use set forth in the
diagram must be approved by GTE, which approval shall not be unreasonably
withheld or delayed.
3.2 Subject to extension for delays described in Article XX, QWEST shall
complete at QWEST's sole cost and expense, all construction, installation, and
satisfactory Fiber Acceptance Testing (as defined in Section 4.1) of each of the
Segments, including the provision of such Regeneration Facilities on such
Segment as may be provided pursuant to Section 7.2(a), by the applicable
"Estimated Delivery Date" (as defined in Section 33.1(d)) respecting such
Segment.
3.3 Except as may be provided herein, QWEST shall, at QWEST's sole cost and
expense, procure all materials to be incorporated in and to become a permanent
part of the QWEST System, including, without limitation, the Regeneration
Facilities provided pursuant to Section 7.2(a).
3.4 QWEST shall, at QWEST's sole cost and expense, obtain all Underlying
Rights and other rights, licenses, permits and authorizations as required
pursuant to Article X hereof.
3.5 QWEST shall perform, at QWEST's sole cost and expense, substantially in
accordance with industry standards and practices and as deemed necessary or
appropriate in QWEST's reasonable business judgment, all supervisory and
inspection services relating to the construction of the QWEST System, including,
without limitation, performing construction inspections to assure that all
construction shall be in material compliance with the specifications, drawings,
Underlying Rights, provisions of this Agreement, and applicable governmental
codes. During the course of construction of each Segment, QWEST shall prepare
and provide to GTE construction schedule and progress reports every two weeks.
GTE shall have the right, but not the obligation, to inspect the construction of
each Segment,
Page 4
CONFIDENTIAL TREATMENT
including the installation, splicing and testing of the GTE Fiber incorporated
therein, during the course and at the time of the relevant design, construction
and installation period. No inspection or failure to inspect by GTE shall impair
or invalidate any rights and remedies of GTE under this Agreement or modify,
amend or otherwise affect any of the representations, warranties, covenants or
agreements of QWEST under this Agreement.
3.6 Upon GTE's written request, QWEST shall make available for inspection by
GTE, at QWEST's offices, copies of all information, documents, agreements,
reports, permits, drawings and specifications generated, obtained or acquired by
QWEST in performing its duties pursuant to this Article III that are material to
grant of the IRUs to GTE, including, without limitation, the Underlying Rights,
subject only to the conditions that (i) the terms of each such document or the
legal restrictions applicable to such information or document permits
disclosure; provided that QWEST will use its best efforts (without requiring the
expenditure of money) to obtain a waiver of any existing confidentiality and/or
non-disclosure restrictions, and to exempt GTE from subsequent confidentiality
and/or non-disclosure restrictions, that would restrict QWEST's ability to make
such documents and/or information available to GTE for inspection; (ii)
notwithstanding the existence or non-existence of such restrictions and/or
waivers, QWEST may, in its sole discretion, redact portions of such documents it
deems proprietary business terms prior to GTE's inspection. No inspection or
failure to inspect by GTE shall impair or invalidate any rights and remedies of
GTE under this Agreement or modify, amend or otherwise affect any of the
representations, warranties, covenants or agreements of QWEST under this
Agreement.
ARTICLE IV.
ACCEPTANCE AND TESTING OF GTE FIBERS
4.1 QWEST shall test all GTE Fibers in accordance with the procedures
specified in Exhibit D ("Fiber Acceptance Testing") to verify that the GTE
Fibers are installed and operating in accordance with the specifications
described in Exhibit D. Fiber Acceptance Testing shall progress span by span
along each Segment as cable splicing progresses, so that test results may be
reviewed in a timely manner. QWEST shall provide GTE at least five (5) days
advance notice of the date and time of each Fiber Acceptance Testing such that
GTE shall have the right, but not the obligation, to have a person or persons
present to observe QWEST's Fiber Acceptance Testing. When QWEST has determined
that the results of the Fiber Acceptance Testing with respect to a particular
span show that the GTE Fibers so tested are installed and operating in
conformity with the applicable specifications set forth in Exhibit D, QWEST
shall promptly provide GTE with a copy of such test results.
4.2 When QWEST reasonably determines in good faith that the GTE Fibers with
respect to an entire Segment are installed and operating in conformity with the
applicable specifications set forth in Exhibit D, QWEST shall promptly provide
written notice of same to GTE (a "Completion Notice"). GTE shall, within thirty
(30) days of receipt of the Completion Notice, either reject the Completion
Notice specifying, in good faith, the defect or failure in such Fiber Acceptance
Testing or give QWEST written notice of acceptance of such Fiber Acceptance
Testing (the period from the date of GTE's receipt of the Completion Notice to
the date of QWEST's receipt of GTE's notice of rejection or acceptance being
referred to herein as the "GTE Review Period"). In the event GTE rejects the
Completion Notice, QWEST shall promptly, and not later than seven days, and at
no cost to GTE, commence to remedy the defect or failure. Thereafter QWEST shall
again give GTE a Completion Notice with respect to such GTE Fibers. The
foregoing procedure shall apply again and successively thereafter for a total of
two attempts to remedy the defect or failure. If QWEST fails to adequately
remedy or complete the defect or failure after two attempts, GTE shall have the
right to proceed promptly and in an economically efficient manner to cure such
defects or failures at QWEST's cost and expense, which shall be paid by QWEST to
GTE upon demand, or at the election of GTE, offset from any IRU Fee payable by
Page 5
CONFIDENTIAL TREATMENT
GTE to QWEST with respect to such Segment or any other Segment. No acceptance
of, or failure by GTE to reject, the Completion Notice shall be deemed to be a
waiver of any rights or remedies of GTE under this Agreement; provided that, any
failure by GTE to timely reject as set forth above shall operate as a
constructive acceptance for purposes of this Agreement. The date when GTE
accepts or is deemed to have accepted a Completion Notice or cures such defects
at QWEST's cost and expense as provided above with respect to a Segment is
herein defined as the "Acceptance Date".
ARTICLE V.
DOCUMENTATION
5.1 Notwithstanding the conditions and limitations set forth in Section 3.6,
QWEST shall provide GTE with a copy of all Underlying Right Requirements (as
defined in Section 11.1) applicable to each Segment promptly following the grant
to QWEST of the Underlying Right pursuant to which such Underlying Right
Requirements are imposed and, in any event, on or before the date of completion
of conduit installation in such Segment (as defined in Exhibit B, paragraph
3(ii)).
5.2 Not later than ninety (90) days after the Acceptance Date for each
Segment, QWEST shall provide GTE with the following documentation:
(a) As-built drawings for such Segment in accordance with the requirements
described in Exhibit C ("As-Builts").
(b) Technical specifications of the optical fiber cable and associated
splices and other equipment placed in that Segment.
5.3 As a condition to, and effective upon receipt of, each IRU Fee payment
installment that is due upon QWEST's achievement of a construction,
installation, testing or acceptance milestone as set forth in Exhibit B, QWEST
shall deliver to GTE a lien waiver with respect to liens in favor of QWEST
arising out of QWEST's services in accomplishing such milestone. Promptly
following QWEST's receipt of each such payment, QWEST shall use reasonable
efforts to obtain (and in any event on or before the Acceptance Date with
respect to the relevant Segment shall obtain) from each subcontractor that
provided services in accomplishing such milestone a lien waiver with respect to
liens arising out of such services and, upon receipt, deliver a copy of each
such lien waiver to GTE.
ARTICLE VI.
TERM
6.1 The grant of the IRUs hereunder with respect to each Segment shall
become effective on the first day when both (i) the Acceptance Date with respect
to that Segment has occurred and (ii) QWEST has received payment in full of the
IRU Fee with respect to such Segment in accordance with Exhibit B, and, subject
to the provisions of Article X, such grant shall terminate at the end of the
economically useful life of the GTE Fibers, as reasonably determined by GTE
pursuant to Section 6.2 below. The period of each such grant respecting each
such Segment and IRU is herein defined as the "Term".
6.2 In the event that GTE, at any time, reasonably determines that the GTE
Fibers comprising any Segment have reached the end of their economically useful
life and desires to not retain the IRU in such Segment, GTE shall have the right
to abandon the IRU with respect to such Segment by written notice to QWEST. If,
at any time during or after the last year of the Minimum Period (as defined in
Section 10.2(ii) below), with respect to any Segment, GTE fails to use any of
the GTE Fibers comprising such Segment for any period of thirty (30) consecutive
days (except to the extent that such non-use is as a result of any of the events
described in Article XX or as a result of QWEST System maintenance, restoration,
relocation, or reconfiguration or as a result of the failure of QWEST to observe
and perform the terms of this Agreement), QWEST shall have the right to request
GTE to acknowledge that the GTE Fibers comprising such Segment have reached the
end of their economic life and, accordingly, has abandoned the GTE Fibers
comprising such Segment (which acknowledgment shall not be unreasonably withheld
or delayed). Upon any such notice of
Page 6
CONFIDENTIAL TREATMENT
abandonment or acknowledgment, the Term shall expire with respect to such
Segment and all rights to the use of such Segment shall revert to QWEST without
reimbursement of any fees or other payments previously made with respect
thereto, and from and after such time GTE shall have no further rights or
obligations hereunder with respect to such Segment (subject to the provisions of
Article XIX).
6.3 It is understood and agreed as between the parties that the grant of the
IRUs hereunder shall be treated for accounting and federal and all applicable
state and local tax purposes as the sale and purchase of the GTE Fibers and a
corresponding interest in QWEST's rights in the Associated Property subject
thereto, and that on and after the Acceptance Date with respect to each Segment,
GTE shall be treated as the owner of the GTE Fibers and an interest in QWEST's
rights in the Associated Property comprising such Segment for such purposes. The
parties agree to file their respective financial reports, income tax returns,
property tax returns, and other returns and reports for their respective
Impositions (as such term is defined in Section 33.1(e)) on such basis and,
except as otherwise required by law, not to take any positions inconsistent
therewith. QWEST shall retain legal title to the entire QWEST System, including
the GTE Fibers and Associated Property subject to the IRUs hereunder. In the
event the grant is not treated as a sale and purchase for tax purposes, the
parties shall pay any taxes arising by reason of such tax treatment on the same
basis as if it had been treated as a sale and purchase. Each party agrees to
indemnify the other with respect to any late filing penalties, interest or fees
incurred as a result of such party's failure to provide the other with such
information solely in such party's possession or control that may be necessary
in order to timely make any such filing.
6.4 This Agreement shall become effective on the date hereof and shall
terminate on the date when, after completion and delivery of all Segments
required to be delivered hereunder, all the Terms of all such Segments shall
have expired; provided that, those provisions of this Agreement which, by their
express terms, are intended to survive such termination, shall survive.
ARTICLE VII.
NETWORK ACCESS; REGENERATION FACILITIES
7.1 (a) QWEST shall provide GTE with access to, and GTE shall have the right
to connect, at GTE's sole cost and expense, its telecommunications system with,
the GTE Fibers at various network access points on the QWEST System right-of-way
in each of the endpoint cities and intermediate point cities along the route of
each Segment and at such additional locations along the QWEST System right-of-
way as may be requested by GTE (each such access point being referred to as a
"Connecting Point"). The specific locations of each such Connecting Point shall
be as mutually reasonably agreed upon by the parties in good faith, subject to
the Underlying Rights Requirements and QWEST obtaining other required permits,
authorizations and approvals (which QWEST agrees to use its best efforts to
obtain). Any such connection will be performed by QWEST, at GTE's sole cost and
expense, in accordance with QWEST's applicable specifications and operating
procedures. GTE shall pay QWEST's Costs for each such connection within thirty
(30) days of the date of GTE's receipt of QWEST's invoice therefor. In order to
schedule a connection of this type, GTE shall request and coordinate such work
not less than ninety (90) days in advance of the date the connection is
requested to be completed. Such work will be restricted to a Planned System Work
Period ("PSWP"), as defined in Section 33.1(i), unless otherwise agreed to in
writing for specific projects. Subject to all applicable Underlying Rights
Requirements, GTE shall also be provided reasonable access by QWEST to any
Connecting Point at all times. GTE shall have no limitations on the types of
electronics or technologies employed to utilize the GTE Fibers, subject to
mutually agreeable safety procedures and so long as such electronics or
technologies do not interfere with the use of or present a risk of damage to any
portion of the QWEST System.
Page 7
CONFIDENTIAL TREATMENT
(b) QWEST may route the GTE Fibers through QWEST's separate terminal,
endlink, POP or Regeneration Facilities at its sole discretion so long as such
routing does not have a material adverse effect on the security, the safety or
GTE's use of the GTE Fibers or Associated Property hereunder and QWEST is
responsible for all costs and expenses associated therewith.
7.2 (a) QWEST will provide GTE with regeneration site facilities as
identified on Exhibit F or as mutually agreed by the parties to be located at
approximately sixty (60) mile intervals along the QWEST System right-of-way, in
each case consisting of and providing space of approximately ##MATERIAL OMITTED
AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## square
feet and amenities (except for the operating costs associated therewith
expressly required to be paid by GTE pursuant to Section 8.2), as described in
Exhibit F ("Regeneration Facilities") at the rates set forth below. The parties
acknowledge that (i) the locations of such Regeneration Facilities shall be
coincident with the locations of QWEST's own Regeneration Facilities. In
addition, QWEST shall provide to GTE at GTE's Prorated Cost (as defined below in
this paragraph (a)) POP or terminal facilities of approximately ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
square feet along the QWEST System right-of-way at such locations as may be
mutually determined by GTE and QWEST, subject to space and power availability
and Underlying Rights Requirements. GTE's Occupancy of and access to all such
Regeneration Facility Sites (or POP or terminal facilities) shall include
separate, secured, 24-hour-per-day building access. Any Regeneration Facilities
(or POP or terminal facilities) provided by QWEST to GTE shall be at GTE's
Prorated Cost. For purposes of the foregoing two sentences, GTE's Prorated Cost
for Regeneration facilities means $ ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## per facility and for POP or
terminal facilities means $ ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## per facility.
(b) Except as provided in Section 8.2 or as otherwise agreed upon, in
writing, by the parties, all amounts payable under this Section 7.2 shall be due
upon the date that the subject facility is available for occupancy by GTE and
shall be paid in the manner specified in Section 2.2.
7.3 Notwithstanding any qualifications or limitations on QWEST's obligations
under this Article or elsewhere in this Agreement, including but not limited to
the qualification that any obligation of QWEST is subject to the Underlying
Rights Requirements, QWEST is obligated to use its best efforts to obtain and
provide any requisite consents, approvals, permits, authorizations and rights as
may be necessary in order for GTE to be able to install necessary equipment
and/or facilities, to have access to and to maintain its equipment and
facilities, to fully utilize the GTE Fibers, Associated Property, and the IRU
granted or to be granted to GTE under the Agreement, and to provide maintenance
on the Qwest System should QWEST not provide the maintenance services set out in
Exhibit H. QWEST agrees that in the event GTE's ability to utilize and maintain
the GTE Fibers as herein described is impeded in a material way as a result of
the Underlying Rights Requirements, QWEST agrees to use all commercially
reasonable efforts to amend the Underlying Rights or secure additional rights in
order to provide GTE with full access to the GTE Fibers.
ARTICLE VIII.
OPERATIONS
8.1 Each party shall have full and complete control and responsibility for
determining any network and service configuration or designs, routing
configurations, regrooming, rearrangement or consolidation of channels or
circuits and all related functions with regard to the use of that party's Dark
Fiber.
Page 8
CONFIDENTIAL TREATMENT
8.2 GTE shall reimburse QWEST for GTE's proportionate share of all
reasonable and necessary operating costs incurred by QWEST in connection with
the Regeneration Facilities (or alternatively requested POP or terminal
facilities) provided pursuant to Section 7.2(a), including its proportionate
share of any monthly lease costs for any such facilities and/or underlying
property that QWEST leases (including, to the extent included in such lease
costs, base rent, maintenance, insurance, security and taxes), maintenance of
such facilities, and all power and utility fees and charges, excluding any lease
costs for underlying rights on the right-of-way. GTE's proportionate share of
such operating costs, including a proportionate share of common area costs,
shall be the ratio that the floor space provided to GTE in any such facility
(including a proportionate share of the common area) bears to (i) in the case of
lease costs, the total space in such facility, and (ii) in the case of all other
costs (including common area costs), the total utilized space in such facility.
QWEST shall submit invoices to GTE on an annual basis for GTE's pro rata share
of such operating costs during the preceding twelve months. GTE's reimbursement
obligations for insurance and taxes pursuant to this Section 8.2 shall in no
event be duplicative of GTE's payment obligations for insurance or taxes,
respectively, as provided in Article XIV and XV hereof, and in no event shall
relieve QWEST of its payment obligations for insurance costs or taxes,
respectively, as provided in Article XIV and XV hereof.
8.3 GTE acknowledges and agrees that, except to the extent expressly
provided pursuant to Section 7.2, QWEST is not supplying nor is QWEST obligated
to supply to GTE any optronics or electronics or optical or electrical equipment
or other facilities, including without limitation, generators, batteries, air
conditioners, fire protection and monitoring and testing equipment, all of which
are the sole responsibility of GTE, nor is QWEST responsible for performing any
work other than as specified in this Agreement.
8.4 Upon not less than one hundred twenty (120) days' written notice from
QWEST to GTE, QWEST may, subject to GTE's prior written approval (which approval
shall not be unreasonably delayed or withheld) substitute for the GTE Fibers on
the QWEST System, or any Segment or Segments comprising a portion of said QWEST
System, an equal number of alternative fibers along the same or an alternative
route; provided that in any such event, such substitution (i) shall be in
accordance with GTE's applicable specifications and operating procedures, (ii)
shall be effected at the sole cost of QWEST, including, without limitation, all
disconnect and reconnect costs, fees and expenses, (iii) shall be constructed
and tested in accordance with the specifications and drawings set forth in
Exhibits C and D and Section 4.2, and incorporate fiber meeting the
specifications set forth in Exhibit E, and (iv) shall not interrupt or adversely
affect the use, operation or performance of GTE's network or business, or change
any Connecting Points or endpoints of any Segment or change the location of any
Regeneration Facilities (or POPs or terminal facilities) used by GTE hereunder
or any other GTE POP, node or switch facilities, all as determined by GTE, in
its sole discretion.
ARTICLE IX.
MAINTENANCE AND REPAIR OF THE QWEST SYSTEM
9.1 From and after the Acceptance Date with respect to each Segment, the
maintenance of the QWEST System comprising such Segment shall be provided in
accordance with the maintenance requirements and procedures set forth in Exhibit
H hereto.
ARTICLE X.
PERMITS; UNDERLYING RIGHTS; RELOCATION
10.1 QWEST covenants and agrees that it shall obtain, during the course of
construction of, and in any event on or before the completion of conduit
installation with respect to, each Segment of conduit to be delivered hereunder
all Underlying Rights (as defined below) and such other rights, licenses,
permits, authorizations, consents and approvals (including, without limitation,
any necessary local, state, federal or tribal authorizations and environmental
permits) that are necessary in order to permit QWEST to construct,
Page 9
CONFIDENTIAL TREATMENT
install and maintain the conduit and the GTE Fibers to be encompassed in such
Segment in accordance with the terms and conditions hereof. QWEST further
covenants and agrees that it shall obtain, during the course of construction of
and in any event on or before the Acceptance Date with respect to each Segment
to be delivered hereunder, any and all rights-of way, easements, licenses and
other agreements relating to the grant of rights and interests in and/or access
to the real property underlying the QWEST System (collectively, the "Underlying
Rights") and such other rights, licenses, permits, authorizations, consents and
approvals (including without limitation, any necessary local, state, federal or
tribal authorizations and environmental permits) that are necessary in order to
permit QWEST to grant the IRUs, and otherwise to perform its obligations
hereunder, in accordance with the terms and conditions hereof, and to (and all
of which Underlying Rights shall) permit GTE to use the GTE Fibers and
Associated Property as provided and permitted hereunder and in accordance with
the terms and conditions hereof. QWEST shall use its best efforts to cause the
terms of each such Underlying Right to provide GTE with notice of any default on
the part of QWEST and to permit GTE to cure, on behalf of QWEST, any such
default by QWEST and, thereafter, to continue the use of such Underlying Right
in accordance with QWEST's rights and interests thereunder and, if GTE at any
time cures such default by QWEST, QWEST shall reimburse GTE for any and all
amounts reasonably paid by GTE promptly upon demand.
10.2 QWEST further covenants and agrees that, with respect to each Underlying
Right that is necessary in order to continue and maintain the IRUs granted
hereunder, and to permit GTE to exercise its rights to use the GTE Fibers and
Associated Property, in each case in accordance with the terms and conditions
hereof:
(i) QWEST shall, for a period of
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
years from the date hereof (or until the earlier to occur of
(A) the expiration of the economically useful life of the GTE Fibers,
as determined pursuant to Section 6.2, or (B) the expiration or
termination of the term of a particular Underlying Right, so long as
any such termination is not effected as a result of any failure of
QWEST (not caused as a result of GTE's failure to observe and perform
its obligations hereunder) to observe and perform its duties,
obligations and responsibilities under such Underlying Right or under
this Agreement, including under this Article X), observe and perform
each and every of its obligations under each document, agreement or
instrument granting or conveying to QWEST such an Underlying Right if
the failure to observe and perform any such obligation or obligations
would permit the grantor of such Underlying Right to terminate such
Underlying Right prior to its stated expiration date, or would
otherwise materially, adversely impair or affect GTE's ability to use
the GTE Fibers and Associated Property, or exercise its rights with
respect thereto, as provided and permitted hereunder; and
(ii) QWEST shall either require that the initial stated
term of each such Underlying Right be for a period that does not
expire, in accordance with its ordinary terms, prior to the last day
of the Minimum Period (as hereinafter defined with respect to each
Segment) or, if the initial stated term of any such Underlying Right
expires, in accordance with its ordinary terms, on a date earlier than
the last day of the Minimum Period, QWEST shall at its cost exercise
any renewal rights thereunder, or otherwise acquire such extensions,
additions and/or replacements as may be necessary, in order to cause
the stated term thereof to be continued until a date that is not
earlier than the last day of the Minimum Period. The "Minimum Period"
shall be, with respect to each Segment, the period from the date on
which construction of such Segment commences until the
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
Page 10
CONFIDENTIAL TREATMENT
CONFIDENTIAL TREATMENT##
anniversary of such date; and
(iii) From and after the last day of the Minimum Period, QWEST at its sole cost
shall use its best efforts (without being required to expend commercially
unreasonably amounts therefor) to obtain such extensions and/or renewals as may
be necessary in order to cause the stated term of each such Underlying Right to
be continued for an additional period or periods of, in the aggregate,
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
years following the Minimum Period or until the earlier expiration of the
economically useful life of the GTE Fibers, as determined pursuant to Section
6.2; provided that QWEST shall not be required to expend, as consideration for
any such renewal or extension, more than the fair market rate payable at such
time for similar rights and terms except to the extent that GTE agrees at its
option to pay directly or reimburse QWEST for any amounts required to be paid in
excess of such fair market rate to renew or extend such an Underlying Right; and
(iv) Throughout the term of each such Underlying Right, QWEST shall at its
reasonable cost and expense defend and protect QWEST's rights in and interests
under the Underlying Rights and GTE's right to use the GTE Fibers and Associated
Property as provided and permitted hereunder against interfering or infringing
rights, interests or claims of third parties.
10.3 Upon the expiration or termination of any Underlying Right that is
necessary in order to grant, continue or maintain an IRU granted hereunder in
accordance with the terms and conditions hereof, so long as QWEST shall have
fully observed and performed its obligations under this Article X with respect
thereto, the Term of the IRUs hereunder with respect to any Segment or Segments
affected thereby shall automatically expire upon such expiration or termination.
10.4 If, after the Acceptance Date with respect to a Segment, QWEST is required
by a third party with legal authority to so require (including, without
limitation, the grantor of an Underlying Right, but only to the extent that such
relocation is not required as a result of a failure by QWEST to observe and
perform its obligations under such Underlying Right or this Agreement), or if
GTE agrees, to relocate any portion of such Segment including any of the
facilities used or required in providing the IRUs in such Segment hereunder,
QWEST shall proceed with such relocation, including, but not limited to, the
right, in good faith, to reasonably determine the extent of, the timing of, and
methods to be used for such relocation; provided that (i) the route of any such
relocation shall be subject to the good faith agreement of the parties with a
bona fide interest therein, (ii) GTE shall be kept fully informed of all other
determinations made by QWEST in connection with such relocation, and (iii) any
such relocation shall be constructed and tested in accordance with the
specifications and drawings set forth in Exhibits C and D, and incorporate fiber
meeting the specifications set forth in Exhibit E. GTE shall reimburse QWEST for
its proportionate share of the Costs of such relocation of the portion of the
Segment so relocated, reduced by such amount, if any, of the portion of such
Costs as are reimbursed to QWEST by the party requiring such relocation, as
follows: (i) if the affected portion of the Segment includes any conduit other
than the conduit housing the GTE Fibers for which QWEST is responsible for
relocation costs, the total Costs of relocation of the conduits (i.e.,
relocation of the conduits only without regard to whether the conduits contain
fibers) shall be allocated based on the overall number of conduits relocated;
(ii) such Costs allocated to the conduit carrying the GTE Fibers plus the Costs
specifically associated with the
Page 11
CONFIDENTIAL TREATMENT
relocation of the fiber (i.e., relocation of the fiber only without regard to
relocation of conduit) shall be further allocated to GTE based on GTE's
proportionate share of (A) all Costs of fiber acquisitions, splicing and
testing, prorated based on the total fiber count in the affected Cable, as so
relocated, and (B) all other Costs associated with the relocation of the conduit
housing the affected Cable, prorated based on the total number of owners
(including QWEST) and holders of IRUs or equivalent interests (including long-
term lessees) (each, an "Interest Holder") in the affected Cable, as so
relocated. GTE shall have the right to review and audit all Costs incurred in
connection with such relocation. QWEST shall deliver to GTE updated As-Builts
with respect to the relocated Segment not later than sixty (60) days following
the completion of such relocation. Any condemnation or taking under the power of
eminent domain of all or any portion of a Segment shall be deemed a relocation
required by a third party with legal authority to so require, and such affected
Segment, or portion thereof, shall be relocated in accordance with this Section
10.4 and any condemnation proceeds received by QWEST shall be applied to such
relocation as provided above.
ARTICLE XI.
USE OF QWEST SYSTEM
11.1 The requirements, restrictions, and/or limitations upon GTE's right to use
the GTE Fibers and Associated Property as provided and permitted under this
Agreement imposed under, and associated safety, operational and other rules and
regulations imposed in connection with, the Underlying Rights are referred to
collectively as the "Underlying Rights Requirements." QWEST represents and
warrants that, it has made available to GTE for its review and inspection a copy
of certain documents, agreements, or instruments pursuant to which QWEST has
been granted an Underlying Right as of the date hereof (the "Existing Underlying
Rights"), and certain associated safety, operational and other rules and
regulations imposed in connection with the exercise of its rights thereunder
(all of which are identified on Exhibit I hereto). GTE hereby accepts the
Existing Underlying Rights and the Underlying Rights Requirements associated
therewith. QWEST represents that it is not in default under any of the Existing
Underlying Rights that would permit the grantor of such Underlying Right to
terminate such Underlying Right prior to its stated expiration date, or would
otherwise materially, adversely impair or affect GTE's ability to use the GTE
Fibers and Associated Property, or exercise its rights with respect thereto, as
provided and permitted hereunder, and, to the best of its knowledge, none of the
grantors are in default under the Existing Underlying Rights. With respect to
each Underlying Right (other than the Existing Underlying Rights) obtained after
the date hereof by QWEST (or an Underlying Right existing on the date hereof
under any document, agreement or instrument delivered after the date hereof) in
carrying out its obligations hereunder from the same type of grantor as a
grantor of any Existing Underlying Right, QWEST represents and warrants that the
terms and conditions thereof, and rules and regulations imposed in connection
therewith, shall not impose materially more onerous limitations and restrictions
on the rights of GTE to use the GTE Fibers and Associated Property as permitted
and provided hereunder than those imposed by such type of grantor under and in
connection with the Existing Underlying Rights and Underlying Rights
Requirements associated therewith. To the extent that any such Underlying Right
documents, agreements or instruments were or hereafter are provided in a
redacted format to protect confidential and proprietary business terms, QWEST
represents and warrants that no language or information so redacted constitutes
an Underlying Rights Requirement nor otherwise imposes material requirements,
restrictions and/or limitations upon GTE's right to use the GTE Fibers and
Associated Property as provided and permitted hereunder. QWEST represents to GTE
that the map heretofore provided to GTE delineating the general location of
rights of way, easements and other rights held by QWEST under the principal
agreements evidencing the Existing Underlying Rights is a true and complete
depiction, in all material respects, with respect to the general
Page 12
CONFIDENTIAL TREATMENT
location of such Existing Underlying Rights that relate to the GTE Fibers to be
installed along the QWEST System as contemplated by this Agreement.
11.2 GTE represents, warrants and covenants that it will use the GTE Fibers and
Associated Property in compliance with (i) all applicable government codes,
ordinances, laws, rules, regulations and/or restrictions, and (ii) subject to
QWEST's obligations under Section 11.1, the Underlying Rights Requirements.
11.3 In addition to the other rights provided hereunder, but subject to the
provisions of Article VII, the IRUs granted hereunder shall include the right at
GTE's cost to install additional equipment, or replace existing equipment, in
the facility space provided to GTE pursuant to Article VII, subject to the
Underlying Rights Requirements.
11.4 QWEST agrees and acknowledges that it has no right to use the GTE Fibers
during the Term hereof, and that, from and after the effective date of the grant
of each IRU hereunder, QWEST shall keep the GTE Fibers, the Associated Property
and the IRUs granted hereunder free from (i) any liens of any third party
attributable to QWEST, and (ii) any rights or claims of any third party
attributable to QWEST, as and to the extent required pursuant to Article X
hereof. In addition, QWEST agrees that, from and after the execution of this
Agreement and until the effective date of the grant of each IRU hereunder with
respect to any Segment, it shall obtain from any entity in favor of which QWEST
in its discretion shall have granted a security interest or lien on all or part
of such Segment a written nondisturbance agreement substantially to the effect
that such lienholder acknowledges GTE's rights and interests in and to the GTE
Fibers, the Associated Property and the IRU's hereunder and agrees that the same
shall not be diminished, disturbed, impaired or interfered with by such
lienholder.
11.5 Subject to the provisions of Article XXV and this Article XI, GTE may use
the GTE Fibers, the Associated Property and the IRUs for any lawful
telecommunications purpose. For purposes of this Section 11.5
"telecommunications" shall have the meaning as used and interpreted in 47 U.S.C.
Sec.153(2)(43). GTE agrees and acknowledges that it has no right to use any of
the fibers, other than the GTE Fibers, included in the Cable or otherwise
incorporated in the QWEST System, and that GTE shall keep any and all of the
QWEST System, other than the IRU in the GTE Fibers or in the Associated
Property, free from any liens, rights or claims of any third party attributable
to GTE.
11.6 GTE and QWEST shall promptly notify each other of any matters pertaining
to, or the occurrence (or impending occurrence) of, any event which could give
rise to any damage or impending damage to or loss of the QWEST System that are
known to such party. Without limiting the generality of the foregoing, QWEST
shall promptly forward to GTE a copy of any notice of default received by QWEST
with respect to its obligations under any Underlying Right if such default is
not promptly cured by QWEST.
11.7 GTE shall not use the GTE Fibers or any related facilities or equipment in
a way which physically interferes in any way with or adversely affects the use
of the fibers or cable of any other person using the QWEST System, it being
expressly acknowledged that the QWEST System includes or will include other
participants, including QWEST and other owners and holders of Dark Fiber IRUs
and telecommunication system operations. QWEST shall not use any other fibers in
the QWEST System in a way which physically interferes with or adversely affects
the use of the GTE Fibers, and shall obtain a similar agreement from any person
that acquires the right to use fibers in the QWEST System after the date hereof.
11.8 GTE and QWEST each agree to cooperate with and support the other in
complying with any requirements applicable to their respective rights and
obligations hereunder by any governmental or regulatory agency or authority.
11.9 QWEST agrees, so long as any such action would not violate the terms of any
Underlying Right, upon request of GTE, to execute,
Page 13
CONFIDENTIAL TREATMENT
file and/or record such documents or instruments as GTE shall deem reasonably
necessary or appropriate to evidence or safeguard the IRUs granted to GTE
hereunder. GTE agrees to reimburse QWEST for all reasonable costs and out-of-
pocket expenses (including, without limitation, reasonable fees and expenses of
legal counsel) incurred by QWEST in fulfilling its obligations under this
Section 11.9.
ARTICLE XII.
INDEMNIFICATION
12.1 Subject to the provisions of Articles XIII and XVIII, QWEST hereby releases
and agrees to indemnify, defend, protect and hold harmless GTE and its
employees, officers and directors, from and against, and assumes liability for:
(a) Any injury, loss or damage to any person (including GTE), tangible property
or facilities of any person or entity (including reasonable attorneys' fees and
costs) to the extent arising out of or resulting from the acts or omissions,
negligent or otherwise, of QWEST, its officers, employees, servants, affiliates,
agents, contractors, licensees, invitees or vendors arising out of or in
connection with a default (other than a default caused by a failure of GTE to
perform or comply with its obligations hereunder) by QWEST in the performance of
its obligations or breach of its representations under this Agreement
(including, without limitation, any default by QWEST in the performance of its
obligations under Article X with respect to the Underlying Rights and under
Article XI with respect to its use of the QWEST System); and
(b) Any claims, liabilities or damages, including reasonable attorneys' fees and
costs, arising out of any violation by QWEST of any regulation, rule, statute or
court order of any local, state or federal governmental agency, court or body in
connection with the performance of its obligations under this Agreement.
12.2 Subject to the provisions of Articles XIII and XVIII, GTE hereby releases
and agrees to indemnify, defend, protect and hold harmless QWEST, and its
employees, officers and directors, from and against, and assumes liability for:
(a) Any injury, loss or damage to any person (including QWEST), tangible
property or facilities of any person or entity (including reasonable attorneys'
fees and costs) to the extent arising out of or resulting from the acts or
omissions, negligent or otherwise, of GTE, its officers, employees, servants,
affiliates, agents, contractors, licensees, invitees or vendors arising out of
or in connection with a default (other than a default caused by a failure of
QWEST to perform or comply with its obligations hereunder) by GTE in the
performance of its obligations or breach of its representations under this
Agreement (including, without limitation, any default by GTE in the performance
of its obligations under Article XI with respect to its use of the QWEST
System); and
(b) Any claims, liabilities or damages, including reasonable attorneys' fees and
costs, arising out of any violation by GTE of any regulation, rule, statute or
court order of any local, state or federal governmental agency, court or body in
connection with its use of the IRUs and/or the GTE Fibers and Associated
Property hereunder.
12.3 The parties agree to promptly provide each other with notice of any
lawsuit, judicial, administrative or other dispute resolution action or
proceeding, or claim of which it becomes aware and which it believes may result
in an indemnification obligation hereunder (each, an "Action"); provided that
the failure to provide any such notice shall not affect the indemnifying party's
indemnification obligation unless the indemnifying party is actually prejudiced
by the failure to receive such notice. After receipt of any such notice, if the
indemnifying party shall acknowledge in writing to the indemnified party that
the indemnifying party shall be obligated under the terms of this indemnity
hereunder in connection with such Action, then the indemnifying party shall be
entitled, if it so elects (i) to take control of the defense and investigation
of such Action, (ii) to employ and engage attorneys of its own choice to handle
and defend the same, at the indemnifying party's cost, risk and expense unless
the named parties to such action or proceeding include
Page 14
CONFIDENTIAL TREATMENT
both the indemnifying party and the indemnified party and the indemnified party
has been advised in writing by counsel that there may be one or more legal
defenses available to such indemnified party that are different from or
additional to those available to the indemnifying party, in which case the
indemnified party shall also have the right to employ its own counsel in any
such case with the reasonable fees and expenses of such counsel being borne by
the indemnifying party, and (iii) to compromise or settle such Action, which
compromise or settlement shall be made only with the written consent of the
indemnified party, such consent not to be unreasonably withheld. Notwithstanding
anything in this Section 12.3 to the contrary, (i) if there is a reasonable
probability that an indemnifiable claim may materially adversely affect the
indemnified party, other than as a result of money damages or other money
payments, the indemnified party shall have the right to participate in such
defense, compromise or settlement and the indemnifying party shall not, without
the indemnified party's written consent (which consent shall not be unreasonably
withheld), settle or compromise any indemnifiable claim or consent to entry of
any judgment in respect thereof unless such settlement, compromise or consent
includes as an unconditional term thereof the giving by the claimant or the
plaintiff to the indemnified party a release from all liability in respect of
such indemnifiable claim.
12.4 The parties hereby expressly recognize and agree that each party's said
obligation to indemnify, defend, protect and save the other harmless is not a
material obligation to the continuing performance of the parties' other
obligations, if any, hereunder. In the event that a party shall fail for any
reason to so indemnify, defend, protect and save the other harmless, the injured
party hereby expressly recognizes that its sole remedy in such event shall be
the right to bring legal proceedings against the other party for its damages as
a result of the other party's said failure to indemnify, defend, protect and
save harmless. The obligations of the parties under this Article XII shall
survive the expiration or termination of this Agreement.
12.5 Nothing contained herein shall operate as a limitation on the right of
either party hereto to bring an action for damages against any third party,
including indirect, special or consequential damages, based on any acts or
omissions of such third party as such acts or omissions may affect the
construction, operation or use of the GTE Fibers or the QWEST System; provided,
however, that each party hereto shall assign such rights or claims, execute such
documents and do whatever else may be reasonably necessary to enable the other
party to pursue any such action against such third party.
ARTICLE XIII.
LIMITATION OF LIABILITY
13.1 Notwithstanding any provision of this Agreement to the contrary, except to
the extent caused by its own willful misconduct, neither party shall be liable
to the other party for any special, incidental, indirect, punitive or
consequential damages, whether foreseeable or not, arising out of, or in
connection with such party's failure to perform its respective obligations or
breach of its respective representations hereunder, including, but not limited
to, loss of profits or revenue (whether arising out of transmission
interruptions or problems, any interruption or degradation of service or
otherwise), cost of capital, or claims of customers, in each case whether
occasioned by any construction, reconstruction, relocation, repair or
maintenance performed by, or failed to be performed by, the other party or any
other cause whatsoever, including breach of contract, breach of warranty,
negligence, or strict liability, all claims with respect to which such special,
incidental, indirect, punitive or consequential damages are hereby specifically
waived. Nothing contained herein shall be construed to prohibit or reduce the
payment by QWEST of the amounts described in Section 18.2 and which the parties
acknowledge are the sole rights and remedies of GTE to the extent provided in
Section 18.2(e).
ARTICLE XIV.
Page 15
CONFIDENTIAL TREATMENT
INSURANCE
14.1 During the construction period with respect to any Segment, and until the
Acceptance Date with respect thereto, QWEST shall procure and maintain in force
the following insurance coverage from companies lawfully approved to do business
in the state where the construction will be performed:
(a) not less than $5,000,000 combined single-limit liability insurance, on an
occurrence basis, for personal injury and property damage, including, without
limitation, injury or damage arising from the operation of vehicles or equipment
and liability for completed operations;
(b) workers' compensation insurance in amounts required by applicable law and
employers' liability insurance with a limit of at least $1,000,000 per
occurrence;
(c) automobile liability insurance covering death or injury to any person or
persons, or damage to property arising from the operation of vehicles or
equipment, with limits of not less than $2,000,000 per occurrence; and
(d) any other insurance coverages required pursuant to QWEST's right-of-way
agreements with railroads or other third parties. QWEST shall require its
subcontractors who are engaged in connection with the construction of the QWEST
System to maintain insurance in the types and amounts as would be obtained by a
prudent person to provide adequate protection against loss. In all
circumstances, QWEST shall require its subcontractors to carry a minimum of
$1,000,000 in commercial general liability; and
(e) GTE shall be listed as an additional insured on all policies set forth
above, except workers' compensation. QWEST shall provide to GTE a certificate of
insurance evidencing such insurance coverage. Evidence of insurance furnished
shall contain a clause stating GTE "shall be notified in writing at least thirty
(30) days prior to any cancellation of, or any material change or new exclusions
in the policy."
14.2 Following the Acceptance Date with respect to each Segment, and throughout
the remaining term of the IRU with respect to such Segment, each party shall
procure and maintain in force, at its own expense:
(a) not less than $5,000,000 combined single limit liability insurance, on an
occurrence basis, for personal injury and property damage, including, without
limitation, injury or damage arising from the operation of vehicles or equipment
and liability for completed operations;
(b) workers' compensation insurance in amounts required by applicable law and
employers' liability insurance with a limit of at least $1,000,000 per
occurrence;
(c) automobile liability insurance covering death or injury to any person or
persons, or damage to property arising from the operation of vehicles or
equipment, with limits of not less than $2,000,000 per occurrence; and
(d) any other insurance coverages specifically required of such party pursuant
to QWEST's right-of-way agreements with railroads or other third parties.
14.3 Both parties expressly acknowledge that a party shall be deemed to be in
compliance with the provisions of this Article if it maintains an approved self
insurance program providing for a retention of up to $1,000,000. If either party
provides any of the foregoing coverages on a claims-made basis, such policy or
policies shall be for at least a three-year extended reporting or discovery
period. Unless otherwise agreed, GTE's and QWEST's insurance policies shall be
obtained and maintained with companies rated "A" or better by Best's Key Rating
Guide and each party shall provide the other with an insurance certificate
confirming compliance with this requirement for each policy providing such
required coverage.
14.4 In the event either party fails to obtain the required insurance or to
obtain the required certificates from any contractor and a claim is made or
suffered, such party shall indemnify and hold harmless the other party from any
and all claims for which the
Page 16
CONFIDENTIAL TREATMENT
required insurance would have provided coverage. Further, in the event of any
such failure which continues after seven (7) days' written notice thereof by the
other party, such other party may, but shall not be obligated to, obtain such
insurance and will have the right to be reimbursed for the cost of such
insurance by the party failing to obtain such insurance.
14.5 In the event coverage is denied or reimbursement of a properly presented
claim is disputed by the carrier for insurance provided above, the party
carrying such coverage shall make good-faith efforts to pursue such claim with
its carrier.
14.6 GTE and QWEST shall each obtain from the insurance companies providing the
coverages required by this Agreement the permission of such insurers to allow
such party to waive all rights of subrogation and such party does hereby waive
all rights of said insurance companies to subrogation against the other party,
its parent corporation, affiliates, subsidiaries, assignees, officers,
directors, and employees or any other party entitled to indemnity under this
Agreement.
ARTICLE XV.
TAXES, FEES AND OTHER GOVERNMENTAL IMPOSITIONS
15.1 The parties acknowledge and agree that it is their mutual objective and
intent to (i) minimize, to the extent feasible, the aggregate Impositions (as
defined in Section 33.1(e)) payable with respect to the QWEST System and (ii)
share such Impositions according to their respective interests in the QWEST
System , and that they will cooperate with each other and coordinate their
mutual efforts to achieve such objectives in accordance with the provisions of
this Article XV.
15.2 (a) QWEST shall be responsible for and shall timely pay any and all
Impositions with respect to the construction or operation of the QWEST System
which Impositions are (i) imposed or assessed prior to the Acceptance Date, (ii)
imposed or assessed with respect to events which occurred or property rights or
obligations of QWEST which existed prior to the acceptance date; or (iii)
imposed or assessed (regardless of the time) with respect to the QWEST System in
exchange for the approval of construction in the original agreement which
resulted in the granting of an Underlying Right. Notwithstanding the foregoing
obligations, QWEST shall have the right to challenge any such Impositions so
long as the challenge of such Impositions does not materially, adversely affect
the title, rights or property to be delivered to GTE pursuant hereto.
(b) Real and/or personal property or ad valorem taxes shall be prorated
between QWEST and GTE based on the period the Property was owned by each
respective party during the fiscal period for which such taxes were imposed by
the taxing jurisdiction (as such fiscal period is reflected on the xxxx rendered
by such taxing jurisdiction). If the fiscal period is not identified on the tax
xxxx, proration between QWEST and GTE shall be calculated based on the privilege
period of the taxing jurisdiction. QWEST and GTE shall pay or be reimbursed for
real and/or personal property taxes (including instances in which such property
taxes have been paid before the Acceptance Date) prorated on this basis.
15.3 Except as to Impositions described in paragraphs (ii) and (iii) of Section
15.2, which are clearly for QWEST's account following the Acceptance Date, QWEST
shall timely pay any and all Impositions imposed upon or with respect to the
QWEST System to the extent such Impositions may not feasibly be separately
assessed or imposed upon or against the respective ownership interests of QWEST
and GTE in the QWEST System; provided that, upon receipt of a notice of any such
Imposition, QWEST shall promptly notify GTE of such Imposition and following
payment of such Imposition by QWEST, GTE shall promptly reimburse QWEST for its
proportionate share of such Imposition, which share shall be determined (i) to
the extent possible, based upon the manner and methodology used by the
particular authority imposing such Impositions (e.g., on the cost of the
relative property interests, historic or projected revenue derived therefrom, or
any combination thereof) and, if based upon projected revenue or gross receipts,
then
Page 17
CONFIDENTIAL TREATMENT
based on the relative number of GTE Fibers in the affected portion of the QWEST
System compared to the total number of fibers in the affected portion of the
QWEST System during the relevant tax period which are subject to an indefeasible
right of use or are otherwise in use; or (ii) if the same cannot be so
determined, then based upon GTE's proportionate share of the total fiber count
in the affected portion of the QWEST System. If QWEST's assessed value, for
property tax purposes, is based on its entire operation in any state (i.e.,
central assessment), QWEST and GTE shall work together in good faith to allocate
a proper portion n of said assessment to the QWEST System and GTE's ownership
interest in the QWEST System. If GTE's assessed value, for property tax
purposes, is based on a duplicate assessment of the same property as QWEST,
QWEST and GTE shall work together in good faith to allocate a portion of this
duplicate assessment to each party. QWEST and GTE shall work together in good
faith to aggressively defend against such duplicate assessment in any state
which attempts to impose a duplicate assessment. QWEST shall provide GTE with
reasonable supporting documentation for Impositions for which QWEST seeks
reimbursement. Any reimbursement made under this Section 15.3 shall be in an
amount that, after deductions of all Impositions required to be paid by QWEST in
respect of the receipt or accrual of such reimbursement and after consideration
of any deduction to which QWEST may be entitled with respect to the payment or
accrual of the Impositions which have been reimbursed shall be equal to the
amount otherwise required to be paid by QWEST hereunder. Hereafter, such
additional amount or amounts shall be referred to as the "Gross-up Amount."
QWEST shall, upon request, provide GTE with documentation in support of any
Gross-up Amount so as to ensure that both parties are made whole in a manner
that is consistent with the mutual objectives set forth in section 15.1 of the
Agreement. If such Gross-up Amount exceeds $
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
, GTE may elect to engage the services of an independent consultant, at GTE's
sole cost and expense, to review QWEST's computation of such Gross-up Amount.
Any independent consultant selected by GTE shall be subject to approval by
QWEST, which such approval shall not be unreasonably withheld, and such
independent consultant shall be subject to confidentiality restrictions as may
be determined in QWEST's sole discretion. Further, if, after review of such
documentation or otherwise, in the event the parties are unable to agree upon
the amount of the Gross-up Amount, such dispute shall be resolved pursuant to
Article XXI of the Agreement.
15.4 Upon notice of the assertion or proposed assertion of any Imposition
described in Section 15.3 (including Impositions that trigger a Gross-up Amount)
QWEST shall promptly and in good faith consult with GTE concerning the
underlying facts and whether to contest or continue to contest such assertion or
proposed assertion. Notwithstanding any provision herein to the contrary, QWEST
shall have the right to contest any Imposition described in Section 15.3, above,
(including Impositions which trigger a Gross-up Amount), provided that such
contest does not materially adversely affect GTE. Such contest may be pursued by
any lawful means including by non-payment of such Imposition provided such non-
payment contest does not materially, adversely affect the title, rights or
property to be delivered to GTE pursuant hereto. The out-of-pocket costs and
expenses (including reasonable attorneys' fees) incurred by QWEST in any such
contest shall be shared by QWEST and GTE in the same proportion as to which the
parties shared in any such Imposition, as it was originally assessed. Any
refunds or credits resulting from a contest brought pursuant to this Section
15.4 shall be divided between QWEST and GTE in the same proportion as to which
such refunded or credited Impositions were borne by QWEST and GTE. In any such
event, QWEST shall provide timely notice of such challenge to GTE. If QWEST
chooses to proceed with such challenge after receipt of a written objection to
the challenge from GTE, QWEST shall conduct such challenge at its own costs and
expense, provided that GTE shall not
Page 18
CONFIDENTIAL TREATMENT
receive the benefit of any refund or credit, if any, obtained as a result of a
successful challenge. Further, where QWEST does not contest an Imposition, GTE
shall have the right, after notice to QWEST, to contest such Imposition as long
as such contest does not materially, adversely affect the title property or
rights of QWEST. The out-of-pocket costs and expenses (including reasonable
attorneys' fees) incurred by GTE in any such contest shall be shared by GTE and
QWEST in the same proportion as to which the parties shared in such Imposition,
as it was originally assessed. Any refunds or credits resulting from a contest
shall be divided between GTE and QWEST in the same proportion as to which such
refunded or credited Imposition was borne by GTE and QWEST. If GTE chooses to
proceed with such contest after receipt of written objection to the challenge
from QWEST, GTE shall conduct such challenge at its own costs and expense,
provided that QWEST shall not receive the benefit of any refund or credit, if
any, obtained as a result of a successful challenge. Provided, however, that
notwithstanding anything to the contrary in this Article XV, QWEST shall have
complete authority over and discretion to control (including the authority to
dismiss or not pursue) any contests relating to Impositions based upon the
computation of QWEST's taxable income under the Federal Internal Revenue Code or
state income or franchise tax laws (hereinafter "Net Income Based Impositions").
GTE shall, however, be consulted on the conduct and status of such contest.
QWEST shall have no obligation to disclose to GTE its income or franchise tax
returns and records except as to the discrete portion of such return or record
that directly relates to the computation and payment of such Net Income Based
Impositions. Provided further, however, that in the event QWEST shall determine
in its own discretion not to pursue a contest of any Net Income Based Imposition
as to which GTE has requested a contest pursuant to the provisions described
above in this Section 15.4, then GTE shall have no obligation to provide any
reimbursement for such amount if GTE shall have obtained and provided to QWEST
an opinion of nationally recognized legal counsel confirming that a meritorious
defense exists to such Net Income Based Imposition.
15.5 Except as to Impositions described in paragraph (iii) of Section 15.2,
following the Acceptance Date QWEST and GTE, respectively, shall be separately
responsible for any and all Impositions (i) expressly or implicitly imposed
upon, based upon, or otherwise measured by the gross receipts, gross income, net
receipts or net income received by or accrued to such party due to its
respective ownership or use of the QWEST System and/or the GTE Fibers, or (ii)
which have been separately assessed or imposed upon the respective ownership
interest of such party in the QWEST System and/or the GTE Fibers. If the GTE
Fibers are the only fibers located in the Cable from the point where the Cable
leaves the QWEST System right-of-way to a GTE POP, GTE shall be solely
responsible for any and all Impositions imposed on or with respect to such
portion of the QWEST System.
15.6 Notwithstanding any provision herein to the contrary, GTE shall have the
right to protest by appropriate proceedings any Imposition described in Section
15.5, above. In such event, GTE shall indemnify and hold QWEST harmless from any
expense, legal action or cost, including reasonable attorneys' fees, resulting
from GTE's exercise of its rights hereunder. In the event of any refund, rebate,
reduction or abatement to GTE of any such Imposition imposed upon and/or paid by
GTE, GTE shall be entitled to receive the entire benefit of such refund, rebate,
reduction or abatement attributable to GTE's use of the QWEST System. In the
event GTE has exhausted all its rights of appeal in protesting any Imposition
and has failed to obtain the relief sought in such proceedings or appeals
("Finally Determined Taxes and Fees"), GTE and QWEST may jointly agree (with the
consent and participation of the other Interest Holders in the affected portion
of the QWEST System) to relocate a portion of the QWEST System so as to bypass
the jurisdiction which had imposed or assessed such Finally Determined Taxes and
Fees with the total Costs thereof to be shared proportionately as follows: (i)
if the affected portion of the QWEST System includes any conduit other than the
conduit in which the
Page 19
CONFIDENTIAL TREATMENT
GTE Fibers are located, the total Costs of relocation of the conduits (i.e.,
relocation of the conduits only without regard to whether the conduits contain
fibers) shall be allocated based on the overall number of conduits in the QWEST
System which are relocated; and (ii) such Costs allocated to the conduit
carrying the GTE Fibers plus the Costs specifically associated with the
relocation of the fiber (i.e., relocation of the fiber only without regard to
relocation of conduit) to be further allocated to GTE based upon GTE's
proportionate share of (A) all Costs of fiber acquisitions, splicing and
testing, prorated based on the total fiber count in the Cable, as so relocated;
and (B) all other Costs associated with the relocation of the conduit housing
the affected Cable, prorated based upon the total number of Interest Holders in
the affected Cable, as so relocated. QWEST shall deliver to GTE updated As-
Builts with respect to the relocated QWEST System not later than sixty (60) days
following the completion of such relocation. If GTE and QWEST do not determine
to relocate the affected portion of the QWEST System, GTE shall have the right
to terminate its use of the GTE Fibers in the affected portion of the QWEST
System. Such termination shall be effective on the date specified by GTE in a
notice of termination, which date shall be at least ninety (90) days after the
notice. Upon such termination, the IRU in the affected portion of the QWEST
System shall immediately terminate, and the GTE Fibers in the affected portion
of the QWEST System shall thereupon revert to QWEST without reimbursement of any
of the IRU Fee or other payments previously made with respect thereto.
15.7 Notwithstanding the provisions of Section 15.6, with respect to any
Impositions relating to the QWEST System which are imposed upon both QWEST and
GTE (or both of their respective interests therein), QWEST, at its option and at
its own expense, shall have the right to direct and manage in good faith any
such contest; subject, however, to reasonable and appropriate consultation with
GTE which hereby agrees to reasonably cooperate with QWEST in any such contest.
The right of QWEST to contest any Imposition pursuant to this Section 15.7 shall
be contingent upon reasonable and appropriate assurances that any such contest
will not adversely affect the title, property or rights of GTE hereunder.
15.8 QWEST and GTE agree to cooperate fully in the preparation of any returns or
reports relating to the Impositions. QWEST and GTE further acknowledge and agree
that the provisions of this Article XV are intended to allocate the Impositions
expected to be assessed against or imposed upon the parties with respect to the
QWEST System based upon the procedures and methods of computation by which
Impositions generally have been assessed and imposed to date, and that material
changes in the procedures and methods of computation by which such assessments
are assessed and imposed could significantly alter the fundamental economic
assumptions underlying the transactions hereunder to the parties. Accordingly,
the parties agree that, if in the future the procedures or methods of
computation by which Impositions are assessed or imposed against the parties
change materially from the procedures or methods of computation by which they
are imposed as of the date hereof, the parties will negotiate in good faith an
amendment to the provisions of this Article XV in order to preserve, to the
extent reasonably possible, the economic intent and effect of this Article XV as
of the date hereof.
ARTICLE XVI.
NOTICE
16.1 Unless otherwise provided herein, all notices and communications concerning
this Agreement shall be addressed to the other party as follows:
If to QWEST: QWEST Communications Corporation
ATTENTION: President
000 Xxxxxxxxxxx Xxxxxx
Xxxxxx, Xxxxxxxx 00000
Telephone No.: (000) 000-0000
Facsimile No.: (000) 000-0000
with a copy to: QWEST Communications Corporation
Page 20
CONFIDENTIAL TREATMENT
ATTENTION: General Counsel
000 Xxxxxxxxxxx Xxxxxx
Xxxxxx, Xxxxxxxx 00000
Telephone No.: (000) 000-0000
Facsimile No.: (000) 000-0000
If to GTE: GTE Intelligent Network Services Incorporated
ATTENTION: President
000 Xxxxxx Xxxxx
P.O. Box 152092
Xxxxxx, Xxxxx 00000
Telephone No.:
Facsimile No:
with a copy to:
or at such other address as either party may designated from time to time in
writing to the other party.
16.2 Unless otherwise provided herein, notices shall be hand delivered, sent
by registered or certified U.S. mail, postage prepaid, or by commercial
overnight delivery service, or transmitted by facsimile, and shall be deemed
served or delivered to the addressee or its office when received at the address
for notice specified above when hand delivered, upon confirmation of sending
when sent by fax, on the day after being sent when sent by overnight delivery
service, or three (3) days after deposit in the mail when sent by U.S. mail.
16.3 All invoices concerning payment obligations due to QWEST pursuant to
this Agreement shall be addressed to GTE as follows:
GTE Intelligent Network Services Incorporated
000 Xxxxxx Xxxxx
P.O. Box 152092
Xxxxxx, Xxxxx 00000
ATTENTION: Accounts Payable
with a copy to:
ARTICLE XVII.
CONFIDENTIALITY
17.1 QWEST and GTE hereby agree that if either party provides (or, prior to
the execution hereof, has provided) confidential or proprietary information to
the other party ("Proprietary Information"), such Proprietary Information shall
be held in confidence, and the receiving party shall afford such Proprietary
Information the same care and protection as it affords generally to its own
confidential and proprietary information (which in any case shall be not less
than reasonable care) in order to avoid disclosure to or unauthorized use by any
third party. The parties acknowledge and agree that this Agreement, including
all of the terms, conditions and provisions hereof, and all drafts hereof,
constitutes Proprietary Information. In addition, all information disclosed by
either party to the other in connection with or pursuant to this Agreement,
including prior to the date hereof, shall be deemed to be Proprietary
Information. All Proprietary Information, unless otherwise specified in writing,
shall remain the property of the disclosing party, shall be used by the
receiving party only for the intended purpose, and such written Proprietary
Information, including all copies thereof, shall be returned to the disclosing
party or destroyed after the receiving party's need for it has expired or upon
the request of the disclosing party. Proprietary Information shall
Page 21
CONFIDENTIAL TREATMENT
not be reproduced except to the extent necessary to accomplish the purpose and
intent of this Agreement, or as otherwise may be permitted in writing by the
disclosing party.
17.2 The foregoing provisions of Section 17.1 shall not apply to any
Proprietary Information which (i) becomes publicly available other than through
the recipient; (ii) is required to be disclosed by a governmental or judicial
law, order, rule or regulation; (iii) is independently developed by the
disclosing party; (iv) becomes available to the disclosing party without
restriction from a third party; or (v) becomes relevant to the settlement of any
dispute or enforcement of either party's rights under this Agreement in
accordance with the provisions of this Agreement, in which case appropriate
protective measures shall be taken to preserve the confidentiality of such
Proprietary Information as fully as possible within the confines of such
settlement or enforcement process. If any Proprietary Information is required to
be disclosed pursuant to the foregoing clause (ii), the party required to make
such disclosure shall promptly inform the other party of the requirements of
such disclosure.
17.3 Notwithstanding Sections 17.1 and 17.2 of this Article, either party may
disclose Proprietary Information to its employees, agents, and legal, financial,
and accounting advisors and providers (including its lenders and other
financiers) to the extent necessary or appropriate in connection with the
negotiation and/or performance of this Agreement or its obtaining of financing,
provided that each such party is notified of the confidential and proprietary
nature of such Proprietary Information and is subject to or agrees to be bound
by similar restrictions on its use and disclosure.
17.4 Notwithstanding the foregoing sections of this Article 17, the parties
may provide public statements concerning their participation in this Agreement
that do not disclose Proprietary Information of the other party. Any news
release, public announcement, advertising or any form of publicity pertaining to
this Agreement, provision of services pursuant to it, or association of the
parties with respect to the subject of this Agreement shall be subject to prior
written approval of both parties which approval shall not be unreasonably
withheld.
17.5 The provisions of this Article XVII shall survive expiration or
termination of this Agreement.
ARTICLE XVIII.
DEFAULT
18.1 With respect to all payments required to be made by GTE hereunder,
including, without limitation, payment of the IRU Fee and all other amounts
payable by GTE hereunder, in the event GTE shall fail to make a payment by the
date due and payable hereunder, from and after such date, (i) such unpaid amount
shall bear interest until paid at a rate equal to the rate set forth in Article
XXX and (ii) if such payment is due with respect to a Segment on or prior to the
Acceptance Date of such Segment, the Estimated Delivery Date for such Segment
shall be extended by a number of days equal to the number of days that elapse
from the date such payment is due until paid. In the event any amount or amounts
due and payable hereunder remain unpaid for a period of eighty (80) days after
written notice from QWEST to GTE, and the amount thereof is not in bona fide
dispute, then QWEST may, in its sole and absolute discretion and in addition to
its other rights and remedies hereunder, after ten (10) days prior written
notice to GTE and the failure of GTE to pay such amount within such ten-day
period, terminate any and all of its obligations hereunder with respect to any
Segment or Segments as to which the Acceptance Date has not yet occurred or the
grant of the IRU with respect to which has not yet become effective, and to
apply any and all amounts previously paid by GTE hereunder with respect to such
Segment or Segments toward the payment of any other amounts then or thereafter
payable by GTE hereunder. With respect to all of its other obligations
hereunder, in the event GTE shall fail to perform a non-payment obligation and
such failure shall continue for a period of thirty (30) days after QWEST shall
have given GTE written notice of such failure, GTE shall be in
Page 22
CONFIDENTIAL TREATMENT
default hereunder unless GTE shall have cured such failure or such failure is
otherwise waived in writing by QWEST within such thirty (30) days; provided,
however, that where such failure cannot reasonably be cured within such 30-day
period, if GTE shall proceed promptly to cure the same and prosecute such cure
with due diligence, the time for curing such failure shall be extended for such
period of time as may be necessary to complete such cure; and provided further
that if GTE certifies in good faith to QWEST in writing that a non-payment
failure has been cured, such failure shall be deemed to be cured unless QWEST
otherwise notifies GTE in writing within fifteen (15) days of receipt of such
notice from GTE. GTE shall be in default hereunder (i) automatically upon the
making by GTE of a general assignment for the benefit of its creditors, the
filing by GTE of a voluntary petition in bankruptcy or the filing by GTE of any
petition or answer seeking, consenting to, or acquiescing in reorganization,
arrangement, adjustment, composition, liquidation, dissolution, or similar
relief; (ii) one hundred twenty (120) days after the filing of an involuntary
petition in bankruptcy or other insolvency protection against GTE which is not
dismissed within such one hundred twenty (120) days, or (iii) upon any default
by GTE under the Guaranty, which default is not cured within the relevant cure
period, if any, provided with respect thereto under the Guaranty. Except as
otherwise provided in this Section 18.1, upon any default by GTE, after written
notice thereof from QWEST, QWEST may (i) take such action as it determines, in
its sole discretion, to be necessary to correct the default and, subject to
Section 13.1, recover from GTE its reasonable costs incurred in correcting such
default, and (ii) pursue any legal remedies it may have under applicable law or
principles of equity relating to such default, including specific performance.
Notwithstanding any other provision of this Agreement, QWEST acknowledges and
agrees that QWEST shall have no right to terminate the IRU or any of the rights
and interests of GTE hereunder with respect to any Segment for which the IRU Fee
relating thereto has been fully paid.
18.2 (a) With respect to its obligation to complete the construction,
installation, and satisfactory Fiber Acceptance Testing of the GTE Fibers
comprising a particular Segment by the Estimated Delivery Date with respect to
such Segment pursuant to Section 3.2, the parties acknowledge and agree that it
is in their mutual best interest to work together in a cooperative effort to
determine whether and to what extent any event or occurrence that is reasonably
likely to cause a delay in the delivery of a Segment hereunder, as a result of
any force majeure event or other occurrence described in Article XX or
otherwise, can be terminated, resolved or avoided, and to cause the
construction, installation and delivery of the Segment to be completed in the
most expeditious and practical manner feasible under the circumstances.
Accordingly, within three (3) months following its discovery of an event or
occurrence that QWEST reasonably believes is likely to cause (i) an extension of
the Estimated Delivery Date of one hundred twenty (120) days or more pursuant to
Article XX or (ii) a Delivery Default (as defined pursuant to Section 18.2(d)
below), QWEST shall give written notice to GTE of such event or occurrence.
Thereupon, each of QWEST and GTE (i) will designate a senior executive officer
with decision-making authority and familiarity with this Agreement and the
relevant issue hereunder, and (ii) may designate one technical representative
and one financial representative, to participate in the following resolution
efforts. Each of such designees shall participate in such meetings, promptly
scheduled at mutually agreed upon times and places, as may be necessary or
appropriate to discuss in good faith the status of construction of the affected
Segment, the reason or reasons for the anticipated Estimated Delivery Date
extension or Delivery Default, various possible and practical means by which the
event(s) or occurrence(s) causing such anticipated Estimated Delivery Date
extension or Delivery Default might be terminated, avoided or resolved,
including, without limitation, possible modifications to the route, selection of
right-of-way, or manner of construction of the affected Segment, and
Page 23
CONFIDENTIAL TREATMENT
(iii) use their best efforts to settle upon and implement a procedure by which
such event(s) or occurrence(s) may be terminated, avoided or resolved and the
construction, installation and delivery of the affected Segment completed in an
expeditious and economically practical and feasible manner under the
circumstances. The parties acknowledge and agree that, because the QWEST System
includes or will include other participants, including owners and holders of
Dark Fiber IRUs and telecommunication system operations, such meetings may, and
likely will, involve designees and representatives of such other participants,
and the resolution of any matters so acted upon will require the cooperative
efforts of, and have to be structured, to the extent feasible, in an effort to
meet the needs of all such participants. The parties hereto further acknowledge
and agree that no failure of the parties hereto to resolve, or to agree upon a
manner in which they might resolve, any issue addressed hereunder shall impair,
adversely affect or invalidate any of their respective rights, claims or
remedies under this Agreement.
(b) If, notwithstanding the efforts of the parties pursuant to Section
18.2(a): (i) (A) a force majeure event or occurrence described in Article XX
causing an anticipated Estimated Delivery Date extension has not been
terminated, avoided or resolved by the date that is twelve (12) months following
QWEST's discovery of such event or occurrence, and
(B) there is no "Reasonably Apparent Probability" (either as mutually
determined by QWEST and GTE or, if QWEST and GTE are unable to make such a
mutual determination, as determined by an independent third party mutually
selected by QWEST and GTE and familiar with large-scale fiberoptic system
constructions projects or, if QWEST and GTE are unable to make such a mutual
selection, each of QWEST and GTE shall designate such an independent third
party, the two of which shall designate such an independent third party to make
such determination) that the Acceptance Date with respect to any such affected
Segment will occur within (1) twelve (12) months following the Estimated
Delivery Date (without extension for any delay pursuant to Article XX) with
respect to any Segment designated as a "priority" Segment on Exhibit A-1, or (2)
eighteen (18) months following the Estimated Delivery Date (without extension
for any delay pursuant to Article XX) with respect to any other Segment (such
date with respect to each Segment being referred to as the "Outside Force
Majeure Date"); or
(ii) notwithstanding a determination pursuant to the foregoing clause (i) that
there was a Reasonably Apparent Probability that the Acceptance Date with
respect to the affected Segment would occur by the applicable Outside Force
Majeure Date, nonetheless the event or occurrence described in Article XX
causing such delay is continuing on such applicable Outside Force Majeure Date;
or
(iii) notwithstanding such a determination that there was a Reasonably Apparent
Probability that the Acceptance Date with respect to the affected Segment would
occur by the applicable Outside Force Majeure Date, nonetheless, on the
applicable Outside Force Majeure Date, although the event or occurrence
described in Article XX has been terminated, avoided or resolved and QWEST has
resumed its construction, installation, splicing, and/or testing efforts, QWEST
is unable to demonstrate to GTE's reasonable satisfaction that the Acceptance
Date for such Segment will occur, in all reasonable probability, by the date
that is six (6) months following such Outside Force Majeure Date, then, in any
such event described in foregoing clauses (i), (ii), and (iii), GTE may elect,
in its sole discretion, by written notice to QWEST, to delete such Segment from
the System Route otherwise to be delivered pursuant to this Agreement, and
recover from QWEST (1) the amount of the IRU Fee previously paid by GTE
hereunder with respect to such Segment, plus (2) interest at the prime rate
interest published by The Wall Street Journal as the base rate on corporate
loans posted by a substantial percentage of the nation's largest banks on such
date, plus (3) an amount equal to ##MATERIAL OMITTED AND SEPARATELY FILED UNDER
AN APPLICATION FOR
Page 24
CONFIDENTIAL TREATMENT
CONFIDENTIAL TREATMENT##
of the IRU Fee for such Segment, as determined pursuant to Section 2.1 (with
such aggregate amount payable to GTE promptly following QWEST's receipt of such
election notice or, at the election of GTE, offset against the unpaid amount of
the IRU Fee payable hereunder with respect to any other Segment or Segments).
Upon any such election and payment (or offset), neither party shall have any
further rights or obligations with respect to such Segment hereunder. (c) If,
notwithstanding the efforts of the parties pursuant to Section 18.2(a):
(i) (A) an event or occurrence causing an anticipated Delivery Default (as
defined in Section 18.2(d) below) has not been terminated, avoided, resolved or
waived by the date that is twelve (12) months following QWEST's discovery of
such event or occurrence; and
(B) there is no Reasonably Apparent Probability that the Acceptance Date
with respect to any such affected Segment will occur within (x) twelve (12)
months following the Estimated Delivery Date with respect to each Segment
designated as a "Priority" Segment on Exhibit A-1, or (y) eighteen (18) months
following the Estimated Delivery Date with respect to any other Segment (such
dates being referred to collectively as the "Outside Delivery Default Date"); or
(ii) notwithstanding a determination pursuant to the foregoing clause (i)
that there was a Reasonably Apparent Probability that the Acceptance Date with
respect to the affected Segment would occur by the applicable Outside Delivery
Default Date, nonetheless, on the applicable Outside Delivery Default Date, the
Acceptance Date for such Segment has not occurred; then, in any such event
described in the foregoing clauses (i) and (ii), GTE may elect, in its sole
discretion, by written notice to QWEST, to delete such Segment from the System
Route otherwise to be delivered pursuant to this Agreement, and recover from
QWEST (1) the amount of the IRU Fee previously paid by GTE hereunder with
respect to such Segment, plus (2) interest thereon at the rate of interest
applicable to late payments set forth in Article XXX, plus (3) an amount equal
to
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL
TREATMENT##
of the IRU Fee for such Segment, as determined pursuant to Section 2.1, but
without reduction of such IRU fee under Section 18.2(d) (with such aggregate
amount payable to GTE promptly following QWEST's receipt of such election notice
or, at the election of GTE, offset against the unpaid amount of the IRU Fee
payable hereunder with respect to any other Segment or Segments). Upon any such
election and payment (or offset), neither party shall have any further rights or
obligations with respect to such Segment hereunder. (d) In addition to the
specific rights and remedies provided pursuant to the foregoing paragraphs (b)
and (c) in connection with delays and anticipated delays in the delivery of
Segments hereunder, QWEST shall be in default under this Agreement if the
Acceptance Date with respect to any Segment has not occurred within one hundred
twenty (120) days after the Estimated Delivery Date (a "Delivery Default"). From
the date of any such Delivery Default, and until the Acceptance Date with
respect to such Segment occurs, the IRU Fee with respect to such Segment, as
determined or redetermined pursuant to Section 2.1 hereof, shall be reduced by
an amount equal to
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL
TREATMENT##
% of such IRU Fee for each thirty (30) days (or a pro rata percentage of
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL
TREATMENT##
% for any period of less than thirty (30) days) that elapse between such date of
Delivery Default and the Acceptance Date. (e) The rights and remedies set forth
in the foregoing Sections 18.2(c) and 18.2(d) shall be the sole remedies
available to GTE with respect to any failure by QWEST to construct, install, and
conduct satisfactory Fiber Acceptance Testing with respect to the GTE
Page 25
CONFIDENTIAL TREATMENT
Fibers comprising any Segment by the relevant Estimated Delivery Date (it being
expressly acknowledged and agreed that the rights provided to GTE pursuant to
Section 18.2(b) are provided only as an accommodation in the event of lengthy
force majeure delays pursuant to Article XX, and that the events described in
Section 18.2(b) do not constitute defaults hereunder). With respect to all of
QWEST's other obligations hereunder, in the event that QWEST shall fail to
perform an obligation and such failure shall continue for a period of thirty
(30) days after GTE shall have given QWEST written notice of such failure, QWEST
shall be in default hereunder unless QWEST shall have cured such failure or such
failure is otherwise waived in writing by GTE within such thirty (30) days;
provided however, that where such failure cannot reasonably be cured within such
30-day period, if QWEST shall proceed promptly to cure the same and prosecute
such cure with due diligence, the time for curing such failure shall be extended
for such period of time as may be necessary to complete such cure; and provided
further, that if QWEST certifies in good faith to GTE in writing that failure
has been cured, such failure shall be deemed to be cured unless GTE otherwise
notifies QWEST in writing within fifteen (15) days of receipt of such notice
from QWEST. QWEST shall be in default hereunder automatically upon the making by
QWEST of a general assignment for the benefit of its creditors, the filing by
QWEST of a voluntary petition in bankruptcy or the filing by QWEST of any
petition or answer seeking, consenting to, or acquiescing in reorganization,
arrangement, adjustment, composition, liquidation, dissolution, or similar
relief, or (ii) one hundred twenty (120) days after the involuntary filing of a
petition in bankruptcy or other insolvency protection against QWEST which is not
dismissed within such 120-day period. Except as otherwise provided in this
Section 18.2, upon any default by QWEST, after notice thereof from GTE, GTE may
(i) take such action as it determines, in its sole discretion, to be necessary
to correct the default, and, subject to Section 13.1, recover from QWEST its
reasonable costs in correcting such default, and (ii) pursue any legal remedies
it may have under applicable law or principles of equity relating to such
default including specific performance.
ARTICLE XIX.
TERMINATION
19.1 This Agreement automatically shall terminate with respect to a Segment
upon the expiration or termination of the Term of the IRU respecting such
Segment pursuant to Article VI or Section 18.2 hereof.
19.2 Upon the expiration or termination of this Agreement with respect to a
Segment, the IRU in such Segment shall immediately terminate and all rights of
GTE to use the QWEST System, the GTE Fibers, the Associated Property or any part
thereof relating to such Segment, shall cease and QWEST shall owe GTE no
additional duties or consideration with respect to such Segment. Promptly
thereupon, GTE shall remove all of GTE's electronics, equipment, separate
Regeneration Facilities (as provided pursuant to Section 7.2) and other
associated GTE property from such Segment and any related QWEST facilities at
its sole cost under QWEST's supervision (which supervision shall be without cost
to GTE).
19.3 Notwithstanding the foregoing, no termination or expiration of this
Agreement shall affect the rights or obligations of any party hereto (i) with
respect to any then existing defaults or the obligation to make any payment
hereunder for services rendered prior to the date of termination or expiration
or (ii) pursuant to Article XII, Article XIII, Article XV or Article XVII
herein, which shall survive the expiration or termination hereof.
ARTICLE XX.
FORCE MAJEURE
20.1 Neither party shall be in default under this Agreement if and to the
extent that any failure or delay in such party's performance of one or more of
its obligations hereunder is caused by any of the following conditions, and such
party's performance of such obligation or obligations shall be excused and
extended for and during the period of any such delay: act of God; fire; flood;
fiber, Cable,
Page 26
CONFIDENTIAL TREATMENT
or other material failures, shortages or unavailability or other delay in
delivery not resulting from the responsible party's failure to timely place
orders therefor (it being expressly acknowledged that the Cable that is being
acquired for and installed in the QWEST System and that will include the GTE
Fibers must include higher fiber counts than that necessary solely for the GTE
Fibers in order to permit completion of the entire QWEST System); lack of or
delay in transportation; government codes, ordinances, laws, rules, regulations
or restrictions (collectively, "Regulations"); war or civil disorder; strikes or
other labor disputes; failure of a third party to grant or recognize an
Underlying Right, or any other cause beyond the reasonable control of such
party; provided that any delay caused by the failure of a third party to grant
an Underlying Right shall constitute a force majeure delay hereunder only to the
extent that such delay does not extend beyond a period of six months (such that
the Estimated Delivery Date with respect to any Segment affected by such delay
shall be extended only up to a period of six months of any such delay, and shall
not be further extended if such delay extends beyond a period of six months).
The party claiming relief under this Article shall notify the other in writing
of the existence of the event relied on and the cessation or termination of said
event.
ARTICLE XXI
DISPUTE RESOLUTION
21.1 Except as provided in Sections 18.1 and 18.2, if the parties are unable
to resolve any disagreement or dispute arising under or related to this
Agreement, including without limitation, the failure to agree upon any item
requiring a mutual agreement of the parties hereunder, they shall resolve the
disagreement or dispute as follows:
(a) Officers. Either party may refer the matter to the Chief Executive
Officers or the Chief Operating Officers (the "Officers") of the parties by
giving the other party written notice (a "Notice"). Within fifteen (15) days
after delivery of a Notice, the Officers of both parties shall meet at a
mutually acceptable time and place to exchange relevant information and to
attempt to resolve the dispute.
(b) Negotiation. If the matter has not been resolved within thirty (30) days
after delivery of such Notice, or if the Officers fail to meet within fifteen
(15) days after delivery of such Notice, either party may initiate mediation
and, if applicable, arbitration in accordance with the procedure set forth in
subsections (c) and (d) below. All negotiations conducted by the Officers
pursuant to this clause are confidential and shall be treated as compromise and
settlement negotiations for purposes of the Federal Rules of Evidence and State
Rules of Evidence.
(c) Mediation. In the event a dispute exists between the parties and the
respective Officers are unable to resolve the dispute, the parties agree to
participate in a non-binding mediation procedure as follows:
(i) A mediator will be selected by having counsel for each party agree on a
single person to act as mediator. The parties' counsel as well as the
Officers of each party and not more than two other participants from each
party will appear before the mediator at a time and place determined by the
mediator, but not more than sixty (60) days after delivery of a Notice. The
fees of the mediator and other costs of mediation will be shared equally by
the parties. (ii) Each party's counsel will have forty-five (45) minutes to
present a review of the issue and argument before the mediator. After each
counsel's presentation, the other counsel may present specific counter-
arguments not to exceed ten (10) minutes. The 45-minute and 10-minute periods
will be exclusive of the time required to answer questions from the mediator
or attendees. (iii) After both presentations, the Officers may ask questions
of the other side. At the conclusion of both presentations and the question
periods, the Officers and their
Page 27
CONFIDENTIAL TREATMENT
counsels will meet together to attempt to resolve the dispute. The length of
the meeting will be as agreed between the parties. Either party may abandon
the procedure at the end of the presentations and question periods if they
feel it is not productive to go further. The mediation procedure is not
binding on either party.
(iv) The duties of the mediator are to be sure that the above set-out
time periods are adhered to and to ask questions so as to clarify the issues
and understandings of the parties. The mediator may also offer possible
resolutions of the issues but has no duty to do so.
(d) Arbitration. If the matter is not resolved after applying the mediation
procedures set forth above, or if either party refuses to take part in the
mediation process, the parties hereby agree to submit all controversies, claims
and matters of difference that are unresolved to arbitration in Denver,
Colorado, according to the commercial rules and practices of the American
Arbitration Association ("AAA") from time to time in force, and in accordance
with the following provisions of this subsection (d), and unless otherwise
agreed by the parties and subject to the rights of the parties as provided in
Section 18.1 and Section 18.2 hereof (including the right not to continue to
perform under this Agreement), they shall continue to perform under this
Agreement during arbitration.
(i) Arbitration discovery shall be conducted in accordance with the
Federal Rules of Civil Procedure, with any disputes over the scope of
discovery to be determined by the arbitrators, it being intended that the
arbitrators shall allow limited, reasonable discovery prior to any hearing on
the merits.
(ii) Arbitration hereunder shall be by three independent and impartial
arbitrators. Each of the parties shall appoint one arbitrator within thirty
(30) days after initiation of arbitration and the two arbitrators so
appointed shall select a third arbitrator within forty-five (45) days after
initiation of arbitration. In the event that the parties or the arbitrators
fail to select arbitrators as required above, the AAA shall select such
arbitrators.
(iii) The AAA shall have the authority to disqualify any arbitrator who it
determines not to be independent and impartial. The arbitrators shall be
entitled to a fee commensurate with their fees for professional services
requiring similar time and effort.
(iv) The arbitrators shall conduct a hearing no later than sixty (60)
days after initiation of the matter to arbitration, and a decision shall be
rendered by the arbitrators within thirty (30) days of the hearing. At the
hearing, the parties shall present such evidence and witnesses as they may
choose, with or without counsel. Adherence to formal rules of evidence shall
not be required but the arbitration panel shall consider any evidence and
testimony that it determines to be relevant, in accordance with procedures
that it determines to be appropriate. The arbitration determination shall be
in writing and shall specify the factual and legal bases for the
determination. The arbitrators may award legal or equitable relief, including
but not limited to specific performance. (v) The parties agree that this
submission and agreement to arbitrate shall be governed by and specifically
enforceable in accordance with the laws of the State of Colorado. Arbitration
may proceed in the absence of any party if prior written notice of the
proceedings has been given to such party. The parties agree to abide by all
decisions and determinations rendered in such proceedings. Such decisions and
determinations shall be final and binding on all parties. All decisions and
determinations may be filed with the clerk of one or more courts, state,
federal or foreign having jurisdiction over the party against whom it is
rendered or its property, as a basis of judgment.
Page 28
CONFIDENTIAL TREATMENT
(vi) The arbitrators' fees and other costs of the arbitration shall be
borne by the party against whom the award is rendered, except as the
arbitration panel may otherwise provide in its written opinion.
ARTICLE XXII.
WAIVER
22.1 The failure of either party hereto to enforce any of the provisions of
this Agreement, or the waiver thereof in any instance, shall not be construed as
a general waiver or relinquishment on its part of any such provision, but the
same shall nevertheless be and remain in full force and effect.
ARTICLE XXIII.
GOVERNING LAW
23.1 This Agreement shall be governed by and construed in accordance with the
domestic laws of the State of Colorado, without reference to its choice of law
principles. Any litigation based hereon, or arising out of or in connection with
a default by either party in the performance of its obligations hereunder, shall
be brought and maintained exclusively in the courts of the State of Colorado or
in the United States District Court for the District of Colorado, and each party
hereby irrevocable submits to the jurisdiction of such courts for the purpose of
any such litigation and irrevocably agrees to be bound by any judgment rendered
thereby in connection with such litigation.
ARTICLE XXIV.
RULES OF CONSTRUCTION
24.1 The captions or headings in this Agreement are strictly for convenience
and shall not be considered in interpreting this Agreement or as amplifying or
limiting any of its content. Words in this Agreement which import the singular
connotation shall be interpreted as plural, and words which import the plural
connotation shall be interpreted as singular, as the identity of the parties or
objects referred to may require.
24.2 Unless expressly defined herein, words having well known technical or
trade meanings shall be so construed. All listing of items shall not be taken to
be exclusive, but shall include other items, whether similar or dissimilar to
those listed, as the context reasonably requires.
24.3 Except as set forth to the contrary herein, any right or remedy of GTE
or QWEST shall be cumulative and without prejudice to any other right or remedy,
whether contained herein or not.
24.4 Except as expressly provided in Section
28.1, nothing in this Agreement is intended to provide any legal rights to
anyone not an executing party of this Agreement.
24.5 This Agreement has been fully negotiated between and jointly drafted by
the parties.
24.6 All actions, activities, consents, approvals and other undertakings of
the parties in this Agreement shall be performed in a reasonable and timely
manner, it being expressly acknowledged and understood that time is of the
essence in the performance of obligations required to be performed by a date
expressly specified herein. Except as specifically set forth herein, for the
purpose of this Agreement the standards and practices of performance within the
telecommunications industry in the relevant market shall be the measure of a
party's performance.
ARTICLE XXV.
ASSIGNMENT AND TRANSFER RESTRICTIONS
25.1 Except as provided below, QWEST shall not assign, encumber or otherwise
transfer this Agreement or all or any portion of its rights or obligations
hereunder to any other party without the prior written consent of GTE, which
consent will not be unreasonably withheld or delayed. Notwithstanding the
foregoing, QWEST shall have the right, without GTE's consent, to (i) subcontract
any of its construction or maintenance obligations hereunder, or (ii) assign or
otherwise transfer this Agreement in whole or in part (A) as collateral to any
institutional lender to QWEST (or institutional lender to any permitted
transferee or assignee of QWEST) subject to
Page 29
CONFIDENTIAL TREATMENT
the prior rights and obligations of the parties hereunder, (B) to any parent,
subsidiary or affiliate of QWEST, (C) to any person, firm or corporation which
shall control, be under the control of or be under common control with QWEST, or
(D) any corporation or other entity into which QWEST may be merged or
consolidated or which purchases all or substantially all of the stock or assets
of QWEST, or (E) any partnership, joint venture or other business entity of
which QWEST or any wholly owned subsidiary of QWEST HOLDING CORPORATION owns at
least 50 percent of the equity interests thereof and which cannot make major
decisions without the consent of QWEST (or subsidiary of QWEST HOLDING
CORPORATION); provided that the assignee or transferee in any such circumstance
shall continue to be subject to all of the provisions of this Agreement,
including without limitation, this Section 25.1 (except that any lender referred
to in clause (A) above shall not incur any obligations under this Agreement nor
shall it be restricted from exercising any right of enforcement or foreclosure
with respect to any related security interest or lien, so long as the purchaser
in foreclosure is subject to the provisions of this Agreement, including,
without limitation, this Section 25.1); and provided further that promptly
following any such assignment or transfer, QWEST shall give GTE written notice
identifying the assignee or transferee. In the event of any permitted partial
assignment of any rights hereunder, QWEST shall remain the sole point of contact
with GTE. No permitted partial or complete assignment shall release or discharge
QWEST from its duties and obligations hereunder.
25.2 Except as provided in this Section 25.2 and the following Section 25.3,
GTE shall not assign, encumber or otherwise transfer this Agreement or all or
any of portion of its rights or obligations hereunder to any other party without
the prior written consent of QWEST, which consent will not be unreasonably
withheld or delayed. Subject to the provisions of Section 25.3 (which provision
shall be binding upon any permitted assignee or transferee hereunder), GTE shall
have the right, without QWEST's consent, to assign or otherwise transfer this
Agreement in whole or in part (i) as collateral to any institutional lender to
GTE (or institutional lender to any permitted transferee or assignee of GTE)
subject to the prior rights and obligations of the parties hereunder, (ii) to
any parent, subsidiary or affiliate of GTE, (iii) to any person, firm or
corporation which shall control, be under the control of or be under common
control with GTE, or (iv) any other entity into which GTE may be merged or
consolidated or which purchases all or substantially all of the stock or assets
of GTE or (v) any partnership, joint venture or other business entity of which
GTE or any wholly owned subsidiary of GTE owns at least 50 percent of the equity
interests thereof and which cannot make major decisions without the consent of
GTE (or subsidiary of GTE); provided that no assignment or other transfer under
this clause (v) shall be permitted hereunder if its purpose or effect would
constitute, directly or indirectly, a Restricted Transaction (as defined in
Section 25.3) or otherwise violate the provisions of Section 25.3; provided that
the assignee or transferee in any such circumstance shall continue to be subject
to all of the provisions of this Agreement, including without limitation this
Section 25.2 and the following Section 25.3 (except that any lender referred to
in clause (i) above shall not incur any obligations under this Agreement, nor
shall it be restricted from exercising any right of enforcement or foreclosure
with respect to any related security interest or lien, so long as the purchaser
in foreclosure is subject to the provisions of this Agreement, including,
without limitation, this Section 25.2 and the following Section 25.3); and
provided further that in any of circumstances described in clauses (ii), (iii)
or (iv) all of the payment obligations of GTE hereunder for the remainder of the
Term shall be fully guaranteed by GTE or shall be paid in full as a condition to
such transfer or assignment; and provided further that promptly following any
such assignment or transfer, GTE shall give QWEST written notice identifying the
assignee or transferee. In the event of any permitted partial assignment of any
rights hereunder, GTE shall remain the sole party and point of contact with
QWEST hereunder.
Page 30
CONFIDENTIAL TREATMENT
No permitted partial or complete assignment shall release or discharge GTE from
its duties and obligations hereunder.
25.3 Notwithstanding the provisions of Article XI, except as expressly permitted
in Section 25.2(i)-(v), inclusive, without the prior written consent of QWEST,
which consent may be withheld in QWEST's sole discretion, for a period of
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
following the date that the last Segment of the QWEST System is accepted by GTE:
(a) GTE shall not sell, assign, lease, grant an IRU with respect to, exchange,
encumber, or otherwise in any manner transfer or make available in any manner to
any third party the ownership, right to use, use of, or access in any manner to,
any of GTE's rights in the whole or discrete GTE Fibers which at the time of
such transaction are Dark Fibers, or engage in substantive discussions or
negotiations with respect thereto, or otherwise engage in a similar transaction
with respect to any GTE Fibers in a manner designed or intended to circumvent
the foregoing limitations.
(b) GTE shall not sell, assign, lease, grant an IRU with respect to, exchange,
encumber, or otherwise in any manner transfer or make available in any manner to
a Capacity Reseller (as defined below) any of GTE's rights in the whole or
discrete GTE Fibers at a capacity in excess of OC-12, or engage in substantive
discussions or negotiations with respect thereto, or otherwise engage in a
similar transaction with respect to any GTE Fibers in a manner designed or
intended to circumvent the foregoing limitations. As used in this subparagraph,
a Capacity Reseller is any person or entity which, in whole or in part, seeks to
obtain such capacity for the purpose of reselling or otherwise providing access
thereto to third parties for profit, whether or not such person or entity
actually realizes a profit as a result of such transaction.
(c) Each transaction prohibited in subparagraphs (a) or (b) of this Section
25.3 shall constitute a "Restricted Transaction." Except as provided in
subparagraph (b) of this Section 25.3, nothing contained herein shall restrict
or prohibit GTE from creating telecommunications capacity along or through the
GTE Fibers by the addition of GTE's electronic and optronic equipment and
selling or otherwise permitting third parties to use such telecommunications
capacity.
25.4 QWEST and GTE recognize that QWEST may desire to obtain tax-deferred
exchange treatment pursuant to Section 1031 of the Internal Revenue Code, as
amended, with respect to certain of the Dark Fibers and Associated Property in
which the IRUs are to be granted hereunder and which are used or held for use by
QWEST in its business as of the date hereof (the "Existing Properties"), and GTE
agrees to reasonably cooperate as provided herein in obtaining such treatment
(at no cost or expense to GTE). Accordingly, notwithstanding any provision
contained in this Agreement to the contrary, QWEST may, at its sole option, on
or prior to the Acceptance Date for any relevant Segment, appoint a third party
(the "Intermediary") as agent for QWEST with respect to the transfer of the
Existing Properties to GTE, and assign its rights under this Agreement (insofar
as they relate to the Existing Properties) to such Intermediary. If QWEST so
elects to appoint an Intermediary, QWEST shall notify GTE, in writing, on or
prior to the Acceptance Date with respect to the relevant Segment, and shall
provide GTE with copies of all agreements between QWEST and the Intermediary. If
QWEST appoints an Intermediary, QWEST shall transfer the Existing Properties or
such portion thereof as designated by QWEST to the Intermediary, and GTE shall
pay the IRU Fee with respect to the
Page 31
CONFIDENTIAL TREATMENT
Existing Properties (as designated by QWEST) to the Intermediary; provided that
QWEST agrees that such transfer shall be expressly subject to this Agreement,
and that QWEST shall remain liable for performance under this Agreement to the
same extent as if it had not appointed an Intermediary; provided that in such
event QWEST shall indemnify and hold harmless GTE from and against any and all
loss, damage, cost or expense suffered, sustained or incurred by GTE in
connection with any such cooperation and/or payment of such IRU Fee to such
Intermediary.
25.5 This Agreement and each of the parties' respective rights and
obligations under this Agreement, shall be binding upon and shall inure to the
benefit of the parties hereto and each of their respective permitted successors
and assigns.
ARTICLE XXVI.
REPRESENTATIONS, WARRANTIES AND ACKNOWLEDGMENTS
26.1 Each party represents and warrants that:
(a) it has the full right and authority to enter into, execute, deliver and
perform its obligations under this Agreement;
(b) this Agreement constitutes a legal, valid and binding obligation
enforceable against such party in accordance with its terms, subject to
bankruptcy, insolvency, creditors' rights and general equitable principles; and
(c) its execution of and performance under this Agreement shall not violate
any applicable existing regulations, rules, statutes or court orders of any
local, state or federal government agency, court or body.
26.2 QWEST represents and warrants that the Segments of the QWEST System that
it has heretofore constructed or will construct pursuant hereto have been or
shall be designed, engineered, installed, and constructed in compliance with the
terms and provisions of this Agreement and in material compliance with any and
all applicable building, construction and safety codes for such construction and
installation, as well as any and all other applicable governmental laws, codes,
ordinances, statutes and regulations.
26.3 With respect to each of the Segments that has been constructed prior to
the date hereof, QWEST represents and warrants that such Segment, when
constructed, generally was constructed substantially in accordance with the
specifications set forth in Exhibit C hereto, and QWEST has no actual knowledge
on the date hereof of any material deviation in the construction of such Segment
from such specifications. If, within twelve (12) months from the respective
Acceptance Date for each of the Segments referred to in this Section 26.3 ,
there is an event or occurrence that is caused by a material deviation in the
construction or installation of any of such Segments from such specifications,
and which has a material adverse affect on the operation or performance of the
GTE Fibers in such Segment, then, promptly following receipt of written notice
thereof from GTE, QWEST, at its sole cost and expense, shall undertake to repair
the affected portion of such Segment to the relevant specifications.
26.4 QWEST represents and warrants that the Segments of the QWEST System that
it constructs pursuant hereto shall be constructed in all material respects in
accordance with the specifications set forth in Exhibit C hereto; provided that
GTE's sole rights and remedies with respect to any failure to so construct shall
be (i) to inspect the construction, installation and splicing, and participate
in the acceptance testing, of the GTE Fibers incorporated in each such Segment,
during the course and at the time of the relevant construction, installation and
testing periods for each Segment, as provided in Articles III and IV, (ii) if,
during the course of such construction, installation and testing any material
deviation from the specifications set forth in Exhibit C is discovered, the
construction or installation of the affected portion of the Segment shall be
repaired to such specification by QWEST at QWEST's sole cost and expense, and
(iii) if, at any time prior to the date that is twelve (12) months after the
Acceptance Date, GTE shall notify QWEST in writing of its discovery of a
material deviation from the
Page 32
CONFIDENTIAL TREATMENT
specifications set forth in Exhibit C with respect to any such Segment (which
notice shall be given within thirty (30) days of such discovery) the
construction or installation of the affected portion of such Segment shall be
repaired to such specification by QWEST at QWEST's sole cost and expense. For
purposes hereof, "material deviation" means a deviation which is reasonably
likely to have a material adverse affect on the operation or performance of the
GTE Fibers affected thereby.
26.5 EXCEPT AS SET FORTH IN THE FOREGOING PARAGRAPHS 26.2, 26.3 AND 26.4, AND
EXCEPT AS MAY BE SET FORTH SPECIFICALLY AND EXPRESSLY ELSEWHERE IN THIS
AGREEMENT, QWEST MAKES NO WARRANTY, EXPRESS OR IMPLIED, WITH RESPECT TO THE GTE
FIBERS OR THE SEGMENTS DELIVERABLE HEREUNDER, INCLUDING ANY WARRANTY OF
MERCHANTABILITY OR FITNESS FOR PARTICULAR PURPOSE, AND ALL SUCH WARRANTIES ARE
HEREBY EXPRESSLY DISCLAIMED.
26.7 The parties acknowledge and agree that on and after the relevant
Acceptance Date GTE's sole rights and remedies with respect to any defect in or
failure of the GTE Fibers to perform in accordance with the applicable vendor's
or manufacturer's specifications with respect to the GTE Fibers shall be limited
to the particular vendor's or manufacturer's warranty with respect thereto,
which warranty, to the extent permitted by the terms thereof, shall be assigned
to GTE upon its request. In the event any maintenance or repairs to the QWEST
System are required as a result of a breach of any warranty made by any
manufacturers, contractors or vendors, unless GTE shall elect to pursue such
remedies itself, QWEST shall pursue all remedies against such manufacturers,
contractors or vendors on behalf of GTE, and QWEST shall reimburse GTE's costs
for any maintenance GTE has incurred as a result of any such breach of warranty
to the extent the manufacturer, contractor or vendor has paid such costs.
26.8 QWEST and GTE acknowledge and agree:
(a) that each grant of the IRU in the GTE Fibers and Associated Property for
a Segment hereunder (each herein called a "Grant") will be treated by each of
them, vis-a-vis the other, as of and after the relevant effective date thereof
as described in Section 6.1, an executed grant to GTE of an interest in real
property with respect to such Segment; and
(b) that, from and after the effective date of a Grant with respect to a
Segment, no material obligation of either QWEST or GTE will remain to be
performed with respect to such Grant or Segment; and
(c) that, with respect to each such Grant, this Agreement is not intended as
an executory contract or unexpired lease subject to assumption, rejection, or
assignment by the trustee in bankruptcy of any party to this Agreement,
including, without limitation, assumption, rejection, or assignment under
Bankruptcy Code Section 365.
ARTICLE XXVII.
ENTIRE AGREEMENT; AMENDMENT
27.1 This Agreement, together with any Confidentiality Agreement entered into
in connection herewith constitutes the entire and final agreement and
understanding between the parties with respect to the subject matter hereof and
supersedes all prior agreements relating to the subject matter hereof, which are
of no further force or effect. The Exhibits referred to herein are integral
parts hereof and are hereby made a part of this Agreement. To the extent that
any of the provisions of any Exhibit hereto are inconsistent with the express
terms of this Agreement, the terms of this Agreement shall prevail. This
Agreement may only be modified or supplemented by an instrument in writing
executed by a duly authorized representative of each party and delivered to the
party relying on the writing.
ARTICLE XXVIII.
NO PERSONAL LIABILITY
28.1 Each action or claim against any party arising under or relating to this
Agreement shall be made only against such party as a corporation, and any
liability relating thereto shall be enforceable only against the corporate
assets of such party. No party shall seek to xxxxxx the corporate veil or
otherwise seek to impose any liability
Page 33
CONFIDENTIAL TREATMENT
relating to, or arising from, this Agreement against any shareholder, employee,
officer or director of the other party. Each of such persons is an intended
beneficiary of the mutual promises set forth in this Article and shall be
entitled to enforce the obligations of this Article.
ARTICLE XXIX.
RELATIONSHIP OF THE PARTIES
29.1 The relationship between GTE and QWEST shall not be that of partners,
agents, or joint venturers for one another, and nothing contained in this
Agreement shall be deemed to constitute a partnership or agency agreement
between them for any purposes, including, but not limited to federal income tax
purposes. GTE and QWEST, in performing any of their obligations hereunder, shall
be independent contractors or independent parties and shall discharge their
contractual obligations at their own risk subject, however, to the terms and
conditions hereof.
ARTICLE XXX.
LATE PAYMENTS
30.1 In the event a party shall fail to make any payment under this Agreement
when due, such amounts shall accrue interest, from the date such payment is due
until paid, including accrued interest compounded monthly, at an annual rate
equal to
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
of the prime rate of interest published by The Wall Street Journal as the base
rate on corporate loans posted by a substantial percentage of the nation's
largest banks on the date any such payment is due or, if lower, the highest
percentage allowed by law.
ARTICLE XXXI.
SEVERABILITY
31.1 If any term, covenant or condition contained herein shall, to any
extent, be invalid or unenforceable in any respect under the laws governing this
Agreement, the remainder of this Agreement shall not be affected thereby, and
each term, covenant or condition of this Agreement shall be valid and
enforceable to the fullest extent permitted by law.
ARTICLE XXXII.
COUNTERPARTS
32.1 This Agreement may be executed in one or more counterparts, all of which
taken together shall constitute one and the same instrument.
ARTICLE XXXIII.
CERTAIN DEFINITIONS
33.1 The following terms shall have the stated definitions in this Agreement.
(a) "Cable" means the fiberoptic cable and the fibers contained therein, and
associated splicing connections, splice boxes, and vaults to be installed by
QWEST as part of the QWEST System.
(b) "Costs" means actual, direct costs paid or payable in accordance with
the established accounting procedures generally used by QWEST and which it
utilizes in billing third parties for reimbursable projects which costs shall
include, without limitation, the following: (i) internal labor costs, including
wages and salaries, and benefits and overhead allocable to such labor costs
(with the overhead allocation percentage equal to
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
), and (ii) other direct costs and out-of-pocket expenses on a pass-through
basis (e.g., equipment, materials, supplies, contract services, etc.).
(c) "Dark Fiber" means fiber provided without electronics or optronics, and
which is not "lit" or activated; provided that such fiber may be used in any
manner and for any purpose permitted under Article XI.
(d) "Estimated Delivery Date" means, with respect to each Segment of the
QWEST System to be delivered hereunder, the date set forth in Exhibit A hereto
with respect to such Segment, as any such
Page 34
CONFIDENTIAL TREATMENT
date may be extended for and during (A) the period of any delay described in
Article XX and/or (B) the period of any payment default pursuant to Section 18.1
with respect to any Segment and/or (C) the aggregate number of days of the GTE
Review Period or Periods (in the event of multiple remedy attempts) under
Section 4.2 with respect to such Segment.
(e) "Impositions" means all taxes, fees, levies, imposts, duties, charges or
withholdings of any nature (including, without limitation, gross receipts taxes
and franchise, license and permit fees), together with any penalties, fines or
interest thereon (except for penalties or interest imposed as a direct result of
acts or failures to act on the part of QWEST) arising out of the transactions
contemplated by this Agreement and/or imposed upon the QWEST System by any
federal, state or local government or other public taxing authority.
(f) "Indefeasible Right of Use" or "IRU" means (i) an exclusive,
indefeasible right of use, for the purposes described herein, in the GTE Fibers,
as granted in Article II, and (ii) an associated non-exclusive, indefeasible
right of use, for the purposes described herein, in the Associated Property;
provided that the IRUs granted hereunder do not provide GTE with any ownership
interest in or other rights to physical access to, control of, modification of,
encumbrance in any manner of, or other use of the QWEST System except as
expressly set forth herein.
(g) This item left blank intentionally.
(h) "POP" means the GTE point of presence at locations along the QWEST
System route.
(i) "PSWP" means Planned System Work Period, which is a prearranged period
of time reserved for performing certain work on the QWEST System that may
potentially impact traffic. Generally, this will be restricted to weekends,
avoiding the first and last weekend of each month and high-traffic weekends. The
PSWP shall be agreed upon pursuant to Exhibit H.
(j) "QWEST System" shall have the meaning ascribed thereto in Recital A.
(k) When used herein in connection with a covenant of a party to this
Agreement "best efforts" shall not obligate such party, unless otherwise
specifically required by the operative covenant, to make unreimbursed
expenditures (other than costs or expenditures that would have been required of
such party in the absence of the requirements of such covenant) that are
material in amount, in light of the circumstances to which the requirement to
use best efforts applies. In confirmation of their consent and agreement to the
terms and conditions contained in this IRU Agreement and intending to be legally
bound hereby, the parties have executed this IRU Agreement as of the date first
above written.
"QWEST":
QWEST COMMUNICATIONS CORPORATION, a
Delaware corporation
By:_/s/___________________________________________________
Name:
Title:
"GTE":
GTE INTELLIGENT NETWORK SERVICES INCORPORATED, a
Delaware corporation
By:___/s/_________________________________________________
Name:
Title:
EXHIBIT A
Page 35
CONFIDENTIAL TREATMENT
QWEST System Description
EXHIBIT A-1: QWEST System Description and Delivery Dates
GTE - Exhibit A-1
System Description and Delivery Dates
Estimated Estimated
Segment System Route Delivery
No. Segment Miles Date
1A Chicago - Detroit 305 1/31/98
1B Detroit - Xxxxxxxxx 000 0/00/00
0X Xxxxxxxxx - Xxxxxxxxxx 162 3/1/98
1D Pittsburgh - Philadelphia 356 3/31/98
1E Philadelphia - Washington, D.C. 138 4/30/98
Chicago - Detroit - Cleveland -
1 Washington DC Total 1,126 4/30/98
2A Cleveland - Columbus 133 10/31/97
2B Columbus - Cincinnati 125 10/31/97
2 Cleveland - Columbus Total 258 10/31/97
3 Cincinnati - Louisville 107 7/30/98
4 Indianapolis - Chicago 215 12/31/97
5 Indianapolis - Xx. Xxxxx 000 00/00/00
0 Xx. Xxxxx - Xxxxxx Xxxx 297 10/31/97
7 Kansas City - Topeka 75 10/31/97
8 Denver - Topeka 565 10/31/97
9A Denver - Grand Junction 271 10/31/97
9B Grand Junction - Salt Lake City 295 10/31/97
9 Denver - Salt Lake Total 566 10/31/97
10A Salt Lake City - Reno 575 10/31/97
10B Reno - Roseville 136 10/31/97
10 Salt Lake - Roseville Total 711 10/31/97
11A Roseville - Oakland 111 10/31/97
11B Oakland - San Xxxx 43 10/31/97
11 Roseville - San Xxxx Total 154 10/31/97
12A San Xxxx - Salinas 71 10/31/97
12B Salinas - San Xxxx Obispo 132 10/31/97
12C San Xxxx Obispo - Santa Xxxxxxx 119 10/31/97
12D Santa Xxxxxxx - Los Angeles 107 10/31/97
12 San Xxxx - Los Angeles Total 429 10/31/97
13A Los Angeles - Anaheim 32 10/31/97
13B Anaheim - San Diego 132 10/31/97
13C San Diego - Yuma 235 12/31/97
13D Yuma - Phoenix 187 1/31/98
13 LA - San Diego - Phoenix Total 586 1/31/98
14A Phoenix - Tucson 123 2/29/98
14B Tucson - El Paso 310 3/31/98
14 Phoenix - Tucson - El Paso Total 433 3/31/98
Page 36
CONFIDENTIAL TREATMENT
15A El Paso - San Antonio 586 5/31/98
15B San Xxxxxxx - Xxxxxx 85 1/31/98
15C Austin - Houston 221 12/31/97
00 Xx Xxxx - Xxx Xxxxxxx - Xxxxxxx Total 892 5/31/98
16 Houston - Dallas 269 10/31/97
17A Dallas - Oklahoma City 264 1/31/98
17B Oklahoma City - Tulsa 119 1/31/98
17C Tulsa - Kansas City 256 1/31/98
17 Dallas - Kansas City Total 639 1/31/98
18 Cincinnati - Indianapolis 117 10/31/97
19A Louisville - Nashville 189 9/30/98
19B Nashville - Chattanooga 147 10/31/98
19C Chattanooga - Atlanta 137 10/31/98
19 Louisville - Nashville - Atlanta Total 473 10/31/98
20A Atlanta - Charlotte 261 10/31/98
20B Charlotte - Raleigh 174 8/31/98
20C Raleigh - Richmond 301 10/31/98
20D Richmond - Washington D.C. 110 10/31/98
20 Atlanta - Raleigh - Washington Total 846 10/31/98
21A Chicago - Milwaukee 84 10/31/98
21B Milwaukee - Green Bay 118 10/31/98
21C Green Bay - Minneapolis 295 10/31/98
21D Minneapolis - Des Moines 281 10/31/98
21 Chicago - Des Moines Total 778 10/31/98
22C Des Moines - Omaha 140 10/31/98
22D Omaha - Topeka 224 10/31/98
22 Des Moines - Topeka Total 364 10/31/98
23 Denver - El Paso Total 746 3/31/98
24A Roseville - Chico 98 1/31/98
24B Xxxxx - Xxxxxxx 75 1/31/98
24C Xxxxxxx - Xxxxxxx 177 1/31/98
24D Medford - Eugene 206 1/31/98
24E Eugene - Portland 123 1/31/98
24 Roseville - Portland Total 679 1/31/98
25 Portland - Seattle 182 1/31/98
27 San Xxxx - San Francisco 56 10/31/97
28A Boston - Albany 208 12/31/97
28B Albany - Buffalo 298 12/31/97
28C Buffalo - Cleveland 197 12/31/97
28 Boston - Cleveland Total 703 12/31/97
29 Albany - New York City 157 5/31/98
30 New York City - Philadelphia 95 5/31/98
Total 12,766 10/31/98
EXHIBIT A-2: General Route Map
[MAP APPEARS HERE]
EXHIBIT A-3: Detailed Route Maps
[MAPS APPEAR HERE]
Page 37
CONFIDENTIAL TREATMENT
EXHIBIT A-4: Designated End Point and Intermediate Point
Cities
Exhibit A-4
DESIGNATED ENDPOINT and INTERMEDIATE CITIES
CITY ST LATA LATA NAME
Base Phoenix AZ 000 XXXXXXX
Xxxxxx XX 668 TUCSON
Yuma AZ 000 XXXXXXX
Xxxxxxx XX 000 XXX XXXXXXX
Xxxxx XX 724 CHICO
Los Angeles CA 000 XXX XXXXXXX
Xxxxxxx XX 000 XXX XXXXXXXXX
Xxxxxxx XX 000 XXXXX
Xxxxxxxxx XX 726 SACRAMENTO
Sacramento CA 726 SACRAMENTO
Salinas CA 000 XXXXXXXX
Xxx Xxxxx XX 000 XXX XXXXX
Xxx Xxxxxxxxx XX 000 XXX XXXXXXXXX
Xxx Xxxx XX 000 XXX XXXXXXXXX
Xxx Xxxx Xxxxxx XX 740 SAN XXXX OBISPO
Santa Barbara CA 000 XXX XXXXXXX
Xxxxxxxx Xxxxxxx XX 000 XXXXXXXX XXX.
Xxxxxx XX 000 XXXXXX
Xxxxx Xxxxxxxx XX 656 DENVER
Pueblo CO 000 XXXXXXXX XXX.
Xxxxxxxxxx XX 000 XXXX XX
Xxxxxxx XX 000 XXXXXXX
Xxx Xxxxxx XX 000 XXX XXXXXX
Xxxxxxx XX 358 CHICAGO
Indianapolis IN 000 XXXXXXXXXXXX
Xxxxx Xxxx IN 000 XXXXX XXXX
Xxxxxx XX 000 XXXXXX
Xxxxxxx Xxxxx XX 000 XXXXXXXXX
Xxxxxxxxxx XX 000 XXXXXXXXXX
Xxxxxx XX 000 XXXX XXXX
Xxxxxxxxx XX 000 XXXXXXXXX
Xxxxxx Xxxxx XX 000 XXXXX XXXXXX
Xxxxxxx XX 000 XXXXXXX
Xxxxxxxxxxx XX 000 XXXXXXXXXXX
Xxxxxxxx XX 000 XXXXXXXXX
Xxxxxx Xxxx XX 000 XXXXXX XXXX
Xx. Xxxxx XX 000 XX.XXXXX
Xxxxxxxxx XX 000 XXXXXXXXX
Xxxxxxxxxx XX 000 XXXXXXXXXX
Xxxxxxx XX 000 XXXXXXX
Xxxxx Xxxxx XX 000 XXXXX XXXXX
Xxxxxxx XX 958 LINCOLN
Xxxxx XX 000 XXXXX
Xxxxxx XX 000 XXXXX XXXXXX
Xxxxxxx XX 000 XXXXXXXX XXXXXX
Xxxxxxxxxxx XX 000 XXX XXXXXX
Xxxxx Xx XX 664 NEW MEXICO
Reno NV 720 RENO
Albany NY 134 ALBANY
Buffalo NY 140 BUFFALO
New York NY 000 XXX XXXX XXXXX
Xxxxxxxxxxxx XX 000 XXXXXXXXXXXX
Xxxxxxxxx XX 000 XXXXXXXXX
Xxxxxxxx XX 136 SYRACUSE
Utica NY 136 SYRACUSE
Page 38
CONFIDENTIAL TREATMENT
White Plains NY 000 XXX XXXX XXXXX
Xxxxx XX 000 XXXXX
Xxxxxxxxxx XX 000 XXXXXXXXXX
Xxxxxxxxx XX 000 XXXXXXXXX
Xxxxxxxx XX 324 COLUMBUS
Dayton OH 328 DAYTON
Toledo OH 326 TOLEDO
Youngstown OH 000 XXXXXXXXXX
Xxxxxxxx Xxxx XX 536 OKLAHOMA CITY
Tulsa OK 538 TULSA
Eugene OR 670 XXXXXX
Xxxxxxx OR 670 EUGENE
Portland OR 672 PORTLAND
Salem OR 000 XXXXXXXX
Xxxxxxxxxx XX 000 XXXXXXX,XX
Xxxxxxxxxxxx XX 000 XXXXXXXXXXXX
Xxxxxxxxxx XX 000 XXXXXXXXXX
Xxxxxxxxxx XX 000 XXXXXXXXXX
Xxxxxxxxxxx XX 472 CHATTANOOGA
Nashville TN 000 XXXXXXXXX
Xxxxxx XX 558 AUSTIN
Bryan TX 000 XXXXXX
Xxxxxx XX 000 XXXXXX
Xx Xxxx XX 000 XX XXXX
Xx. Xxxxx XX 000 XXXXXX
Xxxxxxx TX 000 XXXXXXX
Xxxxx XX 000 XXXX
Xxx Xxxxxxx XX 566 SAN ANTONIO
Provo UT 660 UTAH
Salt Lake City UT 000 XXXX XXXX XXXX
Xxxxxxxxxxxxxx XX 000 XXXXXXXX
Xxxxxxxxxx XX 000 XXXXXXX
Xxxxxxxx XX 000 XXXXXXXX
Xxxxxxx XX 000 XXXXXXX
Xxx Xxxxxx XX 000 XXXXXXXXX XX
Xxxxx Xxx XX 000 XXXXXXXXX XX
Xxxxxxxxx XX 000 XXXXXXXXX XX
EXHIBIT B
IRU Fee Payment Schedule
1. The IRU fee for each Segment shall be paid in accordance with the following
schedule:
i)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% upon execution of the IRU Agreement.
ii)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% upon commencement of the construction of a Segment.
iii)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% upon completion of conduit installation of such Segment.
iv)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% upon completion of fiber cable placement in such Segment.
v)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% upon completion of fiber splicing and completion of civil
Page 39
CONFIDENTIAL TREATMENT
construction in such Segment.
vi)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% on the Acceptance Date for such Segment.
2. The IRU fee for Segment 23 shall be paid in accordance with the
following schedule:
i)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% upon execution of the IRU agreement.
ii)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% upon the Acceptance Date for the first 12 Dark Fibers delivered
in accordance with Exhibit A.
iii)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
% upon the Acceptance Date for the second 12 Dark Fibers
delivered in accordance with Exhibit A.
3. For purposes of determining the occurrence of the construction
milestones triggering payment obligations hereunder, the
following shall apply:
i) Commencement of construction of a Segment shall mean
the establishment of a field office followed promptly by
mobilization of either in-house crews or the subcontract of
a construction manager.
ii) Completion of conduit installation shall mean the
completion of installation of the conduit system for the
Segment, with handholds and manholes, ready for Cable
pulling.
C. Completion of fiber cable placement shall mean the
fiber cable is either pulled into the conduit or completely
installed in aerial installation, but without splicing. In
the event of aerial construction, the IRU Fee installment
otherwise due upon completion of conduit installation shall
be due and payable at the same time as the installment due
upon completion of fiber cable placement.
D. Completion of fiber splicing and civil construction
shall mean all fibers are spliced and ready for testing and
civil facilities are ready for the customer to occupy and
install their equipment.
E. Acceptance Date shall have the meaning established in
the IRU Agreement.
IV. The IRU Fee shall be calculated at the rate of $
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
per mile.
V. Upon execution of the IRU Agreement, GTE shall pay QWEST an
amount equal to the sum of all payments due pursuant to Section 1
clauses (ii), (iii), (iv), (v), and (vi) of this Exhibit B for
each Segment for which construction has commenced.
EXHIBIT C
Construction Specifications
1.0 General.
The intent of this document is to outline the specifications for
construction of a fiber optic cable system. In all cases, the
standards contained in this document or the standards of the
federal, state, local or private agency having jurisdiction,
whichever is stricter, shall be followed.
Page 40
CONFIDENTIAL TREATMENT
2.0 Material.
Steel or PVC conduit shall be minimum schedule ##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## wall
thickness.
Any exposed steel conduit, brackets or hardware (i.e., bridge attachments)
shall be ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##.
Handholes shall have a minimum ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## loading rating or ##MATERIAL OMITTED
AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## with
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL
TREATMENT## to ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## inches of cover.
Manholes shall have a minimum ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## loading rating.
Innerducts used shall be ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## or ##MATERIAL OMITTED AND SEPARATELY
FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##.
Buried cable warning tape shall be ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## wide and display ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##.
Warning signs will display ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT##.
Fiber optic cable shall be ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT##.
3.0 Minimum Depths.
Minimum cover required in the placement of conduit shall be ##MATERIAL OMITTED
AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## inches,
except in the following instances:
Page 41
CONFIDENTIAL TREATMENT
(a) The minimum cover in borrow ditches adjacent to roads, highways, railroads
and interstate highways is ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## inches below the cleanout line or
existing grade, whichever is greater.
(b) The minimum cover across streams, river washes and other waterways is
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL
TREATMENT## inches below the cleanout line or existing grade, whichever is
greater. Steel conduit will be placed at all such crossings unless the crossing
is directional bored.
(c) At locations where conduit crosses other subsurface utilities or other
structures, the conduit shall be installed to provide a minimum of ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
inches of vertical clearance and applicable minimum depth can be maintained;
otherwise, the conduit will be installed under the existing utility or other
structure. If, however, ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## inches cannot be obtained, the cable
shall be encased in steel pipe rather than conduit. No fiber optic cable shall
be buried without being surrounded by conduit or steel pipe.
(d) In rock, the conduit shall be placed to provide a minimum of ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
inches below the surface of the solid rock, or provide a minimum of ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
inches of total cover, whichever requires the least rock excavation. PVC or HDPE
conduit will be backfilled with ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## inches of select materials (padding) in
rock areas.
(e) In the case of the use/conversion of existing steel pipelines or salvaged
conduit systems, the existing depth shall be considered adequate.
4.0 Buried Cable Warning Tape.
All conduit will be installed with buried cable warning tape except where
existing steel pipelines or salvaged conduit systems are used. The warning tape
shall generally be placed at a depth of ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## inches below grade and
directly above the conduit.
5.0 Conduit Construction.
Conduits may be placed by means of trenching, plowing, xxxx and bore, or
directional bore. Conduits will generally be placed on a level grade parallel to
the surface, with only gradual changes in grade elevation.
Steel conduit will be joined with ##MATERIAL OMITTED AND SEPARATELY FILED UNDER
AN APPLICATION FOR
Page 42
CONFIDENTIAL TREATMENT
CONFIDENTIAL TREATMENT##.
All paved city, state, federal and interstate highways and railroad crossings
will be encased in steel conduit. If the crossing is at grade, steel is not
required if the cable is placed with ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## feet of cover or more, and the
crossing is directional bored. All crossings of major streams, rivers, bays and
navigable waterways will be placed in ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## conduit.
At all foreign utility/underground obstacle crossings, ##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## conduit will
be placed and will extend at least ##MATERIAL OMITTED AND SEPARATELY FILED UNDER
AN APPLICATION FOR CONFIDENTIAL TREATMENT## feet beyond the outer limits of the
obstacle in both directions.
All xxxx and bores will use steel conduit.
All directional bores will use ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## conduit.
Any cable placed in rock will be placed in ##MATERIAL OMITTED AND SEPARATELY
FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## conduit.
Any cable placed in swamp or wetland areas will be placed in ##MATERIAL OMITTED
AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## conduit.
All conduits placed on bridges will be ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##.
All conduits placed on bridges shall have expansion joints placed ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
or at least every ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION
FOR
Page 43
CONFIDENTIAL TREATMENT
CONFIDENTIAL TREATMENT## feet, whichever is the shorter distance.
6.0 Innerduct Installation.
Innerduct(s) shall be installed in all steel conduits. No cable will be placed
directly in any split/solid steel conduit without innerduct.
Innerduct(s) shall extend beyond the end of all conduits a minimum of
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL
TREATMENT## inches.
7.0 Cable Installation.
The fiber optic cable shall be installed using a powered pulling winch and
hydraulic-powered assist pulling wheels. The maximum pulling force to be applied
to the fiber optic cable shall be ##MATERIAL OMITTED AND SEPARATELY FILED UNDER
AN APPLICATION FOR CONFIDENTIAL TREATMENT## pounds.
Bends of small radii (less than 20 times the outside diameter of the cable) and
twists that may damage the cable shall be avoided during cable placement.
The cable shall be lubricated and placed in accordance with the cable
manufacturer specifications.
A pulling swivel break-away rated at ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## pounds shall be used at all
times.
All splices will be contained in a handhole or manhole.
A minimum of ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## meters of slack cable will be left in all intermediate
handholes or manholes.
A minimum of ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## meters of slack cable will be left in all splice
locations.
A minimum of ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## meters of slack cable will be left in all facility
locations (i.e., POP sites, switch sites, regens or CEVs).
8.0 Manholes and Handholes.
Manholes shall be placed in traveled surface streets and shall have locking
lids.
Handholes shall be placed in all other areas and be installed with a minimum of
Page 44
CONFIDENTIAL TREATMENT
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL
TREATMENT## inches of soil covering the lid.
9.0 EMS Markers.
EMS markers shall be placed 6 inches directly above the lid of all buried
handholes and assist points. EMS markers fabricated into the lids of handholes
are acceptable.
10.0 Cable Markers (Warning Signs).
Cable markers (with the same information as buried cable warning tape) shall be
installed at all changes in cable running line direction, splices, waterways,
subsurface utilities, handholes and at both sides of street, highway, bridge or
railroad crossings. At no time shall any markers be spaced more than ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
feet apart in metro areas and ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## feet apart in non-metro areas. Markers
shall be positioned so that they can be seen from the location of the cable and
generally set facing perpendicular to the cable running line.
11.0 Compliance.
All work will be done in strict accordance with federal, state, local and
applicable private rules and laws regarding safety and environmental issues,
including those set forth by OSHA and the EPA. In addition, all work and the
resulting fiber system will comply with the current requirements of all
governing entities (FCC, NEC, DEC and other national, state and local codes).
12.0 As Built Drawings.
As built drawings will contain a minimum of the following:
1) Information showing the location of running line, relative to permanent
landmarks, including but not limited to, railroad mileposts, boundary
crossings and utility crossings.
2) Splice locations
3) Manhole and handhole locations
4) Conduit information (type, length, expansion joints, etc.)
5) Cable information (manufacturer, type of fiber, type of cable, fiber
assignments, final cable lengths)
6) Notation of all deviations from specifications (depth, etc.)
7) ROW detail (type, centerline distances, boundaries, waterways, road
crossings, known utilities and obstacles)
8) Cable marker locations and stationing
9) Regeneration locations and floorplans to include FDP
Page 45
CONFIDENTIAL TREATMENT
assignments (also labeled on site)
Drawings will be updated with actual field data during and after construction.
Metro areas scale shall not exceed 1 inch = 200 feet.
Rural areas scale shall not exceed 1 inch = 500 feet.
As-builts will be provided within ##MATERIAL OMITTED AND SEPARATELY FILED UNDER
AN APPLICATION FOR CONFIDENTIAL TREATMENT## days after acceptance, in both hard
copy and electronic format (Auto-CAD version 13.0 or later). Updates to the as-
builts will be provided within ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## days of completion of change, like a
relocation project.
13.0 Aerial Construction.
Subject to prior approval by both parties (which approval shall not be
unreasonably withheld), aerial construction methods will only be used when
buried construction techniques are impractical due to environmental conditions,
schedule or economic considerations, right-of-way issues, or code restrictions.
The parties acknowledge that aerial construction on utility towers (not utility
poles) using optical groundwire or all dielectric self-support methods may be
used without GTE approval provided QWEST agrees to give GTE reasonable prior
notice of its decision to use such aerial methods.
Aerial design standards and construction techniques will conform with industry-
accepted practices for aerial fiber optic cable systems. All aerial plant must
comply with applicable national (NEC, NESC, etc.), state and local codes.
The fiber optic cable placed on an aerial system shall be armored and designed
for aerial applications.
The cable will be placed in accordance with manufacturer specifications. Cable
tension will be monitored during placement. Cable rollers will be placed at a
maximum interval of ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION
FOR CONFIDENTIAL TREATMENT## feet. Cable expansion loops will be placed at every
pole. Cable identification/warning tags will be placed at every pole. All cable
splices will be buried in handholes or manholes.
Cable sheath to suspension strand bonds and grounding will be performed at the
first and last pole of the system and at ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## mile intervals.
Fiber optic cable at all riser poles will be protected with galvanized steel U-
guard from ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## inches below grade to a point
Page 46
CONFIDENTIAL TREATMENT
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL
TREATMENT## inches below the suspension strand. Conduit sweeps will be used to
transition from the U-guard to either a handhole or manhole.
All aerial plant will be designed and constructed with 10M EHS (Class A
galvanized) suspension strand unless otherwise dictated by the pole owners or
field conditions. The fiber optic cable will be double lashed to the suspension
strand using 45 mil stainless lashing wire.
Span length shall account for storm loading (wind and ice) in accordance with
zones outlined in NESC code. Sags and tensions will be calculated in accordance
with industry accepted practices and account for strand size, span length,
ambient temperature at placement and loading. The suspension strand will be
tensioned with a strand dynamometer. A catenary suspension system may be used if
the system exceeds maximum span length specifications.
Prior to attachment to any existing pole line, the system will be inspected for
compliance with applicable codes and standards, as well as the physical
condition of the poles and existing hardware. Any make-ready work will be
reviewed with the pole owner and specifically addressed prior to construction.
If a pole line need be constructed, the preferred poles will be Class 4 (40
feet) and Class 5 (35 feet). Use of the preferred poles will make it unnecessary
to calculate pole loading (horizontal, vertical and bending moments) in most
field conditions. Some unusual conditions may require the use of a stronger
class pole. Depth of placement will be dictated by soil conditions, slope of
terrain and length of pole. Poles will be guyed in accordance with industry-
accepted standards. All pole attachment hardware will be galvanized steel.
Aerial cable will be placed below power attachments and above all other
attachments unless otherwise dictated by the pole owner. Pole contact clearances
and locations will be dictated by current NESC code and the presence of existing
attachments; however, the following minimum objective clearances will apply:
a) Power line -##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION
FOR CONFIDENTIAL TREATMENT## inches (below)
b) Non-current carrying power line -##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## inches
c) Telephone, CATV and other signal lines -##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## inches
(above) Verticle clearances for crossings or parallel lines will be dictated by
current NESC code; however, the objective clearance for most objects (roads,
alleys, etc.) Is ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION
FOR CONFIDENTIAL TREATMENT## feet (at 100 F) with the exception of railroad
tracks and waterways which have an objective of ##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## feet (at
100 F).
Page 47
CONFIDENTIAL TREATMENT
14.0 Approval of Deviations From Specifications.
QWEST will seek the approval of GTE, which approval shall not be unreasonably
withheld or delayed, prior to undertaking any construction which will deviate
from the Construction Specifications set forth in this Exhibit C.
EXHIBIT D
Fiber Cable Splicing, Testing and Acceptance Procedures
1. All splices will be performed with an industry-accepted fusion splicing
machine. Qwest will perform two stages of testing during the construction of a
new fiber cable route. Initially, OTDR tests will be taken from one direction.
As soon as fiber connectivity has been achieved to both regen sites, Qwest will
verify and record the continuity of all fibers. Qwest will take and record power
level readings on all fibers in both directions. Qwest will bi-directional OTDR
test all fibers.
2. During the initial construction, it is only possible to measure the fiber
from one direction. Because of this, splices will be qualified during initial
construction with an OTDR from only one direction. The profile alignment system
or light injection detection system on the fusion splicer may be used to qualify
splices as long as a close correlation to OTDR data is established. The pigtails
will also be qualified at this stage using an OTDR and a minimum 1 km launch
reel. All measurements at this stage in construction will be taken at ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
nm.
3. After Qwest has provided end-to-end connectivity on the fibers, bi-
directional span testing will be done. These measurements must be made after the
splice manhole or handhole is closed in order to check for macro-bending
problems. Continuity tests will be done to verify that no fibers have been
"frogged" or crossed in any of the splice points. Once the pigtails have been
spliced, loss measurements will be recorded using an industry-accepted laser
source and a power meter. OTDR traces will be taken and splice loss measurements
will be recorded. Qwest will also store OTDR traces on diskette and on data
sheets. Laser Precision format will be used on all traces. Qwest will provide
three copies of all data sheets and tables, and one set of diskettes with all
traces.
a. The power loss measurements shall be made at ##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## nm, and
performed bi-directionally.
b. OTDR traces shall be taken in both directions at ##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## nm.
4. The splicing standards are as follows:
a. The loss value of the pigtail connector and its associated splice will not
exceed ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## dB. This value does not include the insertion loss from
its connection to the FDP. For values greater than this, the splice will be
broken and respliced
Page 48
CONFIDENTIAL TREATMENT
until an acceptable loss value is achieved. If, after five attempts, Qwest is
not able to produce a loss value less than ##MATERIAL OMITTED AND SEPARATELY
FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## dB, the splice will be
marked as Out-of-Spec ("OOS") on the data sheet. Each splicing attempt shall be
documented on the data sheet.
b. During initial uni-directional OTDR testing, the objective for each splice
is a loss of ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## or less. If, after three attempts, Qwest is not able to
produce a loss value of less than ##MATERIAL OMITTED AND SEPARATELY FILED UNDER
AN APPLICATION FOR CONFIDENTIAL TREATMENT## dB, then ##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## dB will be
acceptable. If, after two additional attempts, a value of less than ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
dB is not achievable, then the splice will be marked as OOS on the data sheet.
Each splicing attempt shall be documented on the data sheet.
c. During end-to-end testing of a span (a span shall be FDP to FDP), the
objective for each splice is a bi-directional average loss of ##MATERIAL OMITTED
AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## dB or
less.
d. The standard for each fiber within a span shall be an average bi-
directional loss of ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION
FOR CONFIDENTIAL TREATMENT## dB or less for each splice. For example, if a given
span has 10 splices, each fiber shall have total bi-directional loss (due to the
10 splices) of ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## or less. Each individual splice may have a bi-
directional loss of ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION
FOR CONFIDENTIAL TREATMENT## dB or less, but the average bi-directional splice
loss across the span must be ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## dB or less.
5. The entire fiber optic cable system shall be properly protected from
foreign voltage and grounded with an industry-accepted system. The current
system in use by Qwest is depicted in the attached schematic-DWG No. SAH-1
(typical for Surge Arrestor HH Placement).
6. Customer fiber assignments will be consecutive in count and in a separate
buffer tube (or ribbon or fiber bundles) from others. The maximum number of
fibers within a single buffer tube (or ribbon or fiber bundles) shall be 12.
7. The fibers shall be terminated to the FDP with Ultra FC-PC connectors,
unless another type of connector is specified. The pigtails shall be
manufactured with the same glass as the backbone cable to minimize splice loss.
Page 49
CONFIDENTIAL TREATMENT
EXHIBIT E
Fiber Specifications
[This exhibit contains product specification information that is
largely set forth in graphic format]
EXHIBIT E-1
Fiber Deployment Diagram
[Exhibit E-1 is a map of the United States with the heading "Fiber Deployment
Diagram" showing state lines and routes of the fiber optic network upon
completion.]
EXHIBIT F
Specifications for Regeneration Facilities
Qwest will install modular, prefabricated, conditioned space along the right-
of-way to house regenerations and other electronic equipment (supplied by User)
necessary for the operation of the Qwest System.
Regeneration site facilities consist of ##MATERIAL OMITTED AND SEPARATELY FILED
UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## square feet of caged space in
such facilities with separate, lockable, secured 24 hour access. The buildings
will be ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT## feet wide by approximately ##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## feet interior
length to provide such square footage. Also included is access to ##MATERIAL
OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT##
amps of DC power provided from a common source backed up by a standby generator
as described below. To the extent provided in the Agreement, any additional
space and/or power required may be made available, with User responsible for
QWEST'S incremental cost. Following are the general specifications of the
buildings and support equipment.
Standard production, metal-framed buildings with steel substructure or
concrete; bullet resistant to 30-06 slugs from 15 feet; walls and ceilings R-19
insulated.
Security-type weatherproof exterior light fixtures, equipped with motion
sensors.
Building is equipped with Marvair Compact II or equivalent redundant HVAC units.
The building platform comes equipped with an external ##MATERIAL OMITTED AND
SEPARATELY FILED UNDER AN APPLICATION FOR CONFIDENTIAL TREATMENT## kw backup
generator designed to provide power during emergency periods. The generator fuel
tanks will have a minimum ##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN
APPLICATION FOR CONFIDENTIAL TREATMENT## gallon capacity. As part of the normal
maintenance, the generator will be exercised twice monthly, running on a load
bank for a minimum
Page 50
CONFIDENTIAL TREATMENT
of
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
.
Fire extinguishers are provided one inside the main door, and one
located near the HVAC systems.
A fire suppression system (FM-200) will be in place as the main
overall fire protection coverage.
The building will have an earth ground termination bar (safety
green wire ground) terminated to building steel and/or driven
ground rod.
The building will be equipped with A/C duplex isolated outlets
for testing and miscellaneous equipment. Such outlets shall be
national electronic code and placed every 6 feet around perimeter
walls.
The building will have sufficient lighting.
Two properly sized cable racks will be installed, one from the DC
power source and once from the FDP. Qwest will run properly
sized cables from the common DC power plant to the User-supplied
fuse panel in the User space.
DC power in the amount of
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
amps shall be provided based upon a one (1) for N rectifier format
(i.e.,
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
amp units or
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
amp units). A battery plant capable of handling the load for a
minimum of four (4) hours to ensure uninterruptable power will be
installed in the building. At remote regeneration locations,
QWEST will also provide a battery plant designed to provide at
least
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
, and
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
at all other locations, in both cases with sufficient generator fuel
to provide
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
backup in the event of a power outage. The battery plant shall
incorporate load disconnect protection and batteries capable of
recharging in 12 hours. The battery plant shall also include
dual battery strings with battery disconnects for maintenance
purposes.
Power will be monitored twenty-four (24) hours per day, seven (7)
days a week.
Each party's fibers will be terminated in a separate bulkhead
module within the QWEST fiber distribution panel.
Upon execution of the IRU Agreement, the parties will finalize
the locations of the regeneration facilities in accordance with
Section 7.2 of the IRU Agreement.
Estimated Points
Page 51
CONFIDENTIAL TREATMENT
Segment Route of
Amplifier
No. Segment Miles Presence
Sites
Exhibit G
POP/Regeneration Facility Sites
Segment Estimated Points
Route of Amplifier
No. Segment Miles Presence Sites
1A Chicago to Detroit 305
Chicago to Xxxxx Xxxx 0 0
Xxxxx Xxxx to Battle Creek 1 1
Battle Creek to Detroit 1 2
1B Detroit to Cleveland 165
Detroit to Toledo 1 0
Toledo to Xxxxxxxxx 0
0X Xxxxxxxxx to Pittsburgh 162 1 0
Akron to Youngstown 1 0
Youngstown to Pittsburgh 1 0
1D Pittsburgh to Philadelphia 356
Pittsburgh to Harrisburg 1 3
Harrisburg to Philadelphia 1 1
1E Philadelphia to Washington 138
Philadelphia to Baltimore 2 0
Baltimore to Washington 1 0
2A Cleveland to Columbus 133 1 2
2B Columbus to Cincinnati 125
Columbus to Dayton 1 1
Dayton to Cincinnati 1 0
4 Indianapolis to Chicago 215 1 3
5 Indianapolis to Xx. Xxxxx 000 0 0
0 Xx. Xxxxx to Xxxxxx Xxxx 000 0 0
0 Xxxxxx Xxxx to Xxxxxx 00 0 0
0 Xxxxxx to Denver 565 1 9
9A Denver to Grand Junction 271 1 4
9B Grand Junction to Xxxx Xxxx Xxxx 000
Xxxxx Xxxxxxxx to Provo 1 4
Provo to Xxxx Xxxx Xxxx 0 0
00X Xxxx Xxxx Xxxx to Reno 575 1 9
10B Reno to Xxxxxxxxx 000 0 0
00X Xxxxxxxxx to Oakland 111
Roseville to Sacramento 1 0
Sacramento to Oakland 1 1
11B Oakland to San Xxxx 43 1 0
Page 52
CONFIDENTIAL TREATMENT
12A San Xxxx to Xxxxxxx 71 1 1
12B Xxxxxxx to San Xxxx Xxxxxx 000 0 0
00X Xxx Xxxx Xxxxxx to Santa Xxxxxxx 119 1 1
12D Santa Xxxxxxx to Los Angeles 107 1 1
13A Los Angeles to Anaheim 32 1 0
13B Anaheim to San Diego 132 1 2
13C San Diego to Yuma 235 1 3
13D Yuma to Phoenix 187 1 3
14A Phoenix to Tucson 123 1 1
14B Tucson to Xx Xxxx 000 0 0
00X Xx Xxxx to Xxx Xxxxxxx 000 0 0
00X Xxx Xxxxxxx to Austin 85 1 1
15C Austin to Houston 221 1 3
16 Houston to Xxxxxx 000
Xxxxxxx to Xxxxx 1 1
Xxxxx to Dallas 1 2
17A Dallas to Oklahoma City 264 1 0
Ft. Worth to Xxxxxxxx Xxxx 0 0
00X Xxxxxxxx Xxxx to Tulsa 119 1 1
17C Tulsa to Kansas City 256 1 4
18 Cincinnati to Indianapolis 117 0 1
23 Denver to El Paso 746
Denver to Xxxxxxxx Xxxxxxx 0 0
Xxxxxxxx Xxxxxxx to Pueblo 1 0
Pueblo to Lamy 1 4
Lamy to Albuquerque 1 0
Albuquerque to El Paso 0 4
Lamy to Santa Fe 1 0
24A Sacramento to Chico 98 1 1
24B Chico to Redding 75 1 0
24C Redding to Medford 177 1 2
24D Medford to Eugene 206 1 3
24E Eugene to Portland 123
Eugene to Salem 0
Salem to Portland 1 0
25 Portland to Xxxxxxx 000 0 0
00 Xxx Xxxx to San Francisco 56 1 0
28A Boston to Xxxxxx 000 0 0
00X Xxxxxx to Buffalo 298
Page 53
CONFIDENTIAL TREATMENT
Albany to Syracuse 2 1
Syracuse to Rochester 1 1
Rochester to Buffalo 1 0
28C Buffalo to Cleveland 197 0 3
29 Albany to Xxx Xxxx Xxxx 000 0 0
00 Xxx Xxxx Xxxx to Philadelphia 95 2 0
21A Chicago to Milwaukee 84 1 1
21B Milwaukee to Xxxxx Xxx 000 0 0
00X Xxxxx Xxx to Minneapolis 295
Green Bay to Eau Claire 1 3
Eau Claire to Minneapolis 1 1
21D Minneapolis to Des Moines 281
Minneapolis to Owatonna 1 1
Owatonna to Xxx Xxxxxx 0 0
00X Xxx Xxxxxx to Omaha 140 1 2
22D Omaha to Topeka 224
Omaha to Lincoln 1 1
Lincoln to Topeka 0 2
3 Cincinnati to Louisville 107 0 1
19A Louisville to Nashville 189
Louisville to Bowling Green 1 1
Bowling Green to Xxxxxxxxx 0 0
00X Xxxxxxxxx to Chattanooga 147 1 2
19C Chattanooga to Atlanta 137 1 2
20A Atlanta to Charlotte 261
Atlanta to Greenville 1 2
Greenville to Charlotte 1 1
20B Charlotte to Raleigh 174
Charlotte to Greensboro 1 1
Greensboro to Raleigh 1 1
20C Raleigh to Richmond 301
Raleigh to Rocky Mount 1 0
Rocky Mount to Portsmouth 1 1
Portsmouth to Richmond 1 1
20D Richmond to Washington 110
Richmond to Fredericksburg 1 0
Fredericksburg to Washington 0 0
Total 12,766 93 149
EXHIBIT H
Qwest System Maintenance Specifications and Procedures
Page 54
CONFIDENTIAL TREATMENT
Any party responsible for providing maintenance of the Qwest
System hereunder shall be referred to herein as the "Service
Provider". The Party receiving maintenance services from the
Service Provider hereunder shall be referred to herein as the
"Service Recipient". All other capitalized terms not otherwise
defined herein shall have their respective meanings as set forth
in the IRU Agreement of which this Exhibit forms a part.
1. Maintenance.
(a) Scheduled Maintenance. Routine maintenance and
repair of the Qwest System described in this section ("Scheduled
Maintenance") shall be performed by or under the direction of
Service Provider, at Service Provider's reasonable discretion or
at Service Recipient's request. Scheduled Maintenance shall
commence with respect to each Segment upon the effective date of
the grant of the IRU therein, as provided in the IRU Agreement.
Scheduled Maintenance shall include the following activities:
(i) Patrol of Qwest System route on a regularly
scheduled basis, which will be weekly unless hyrail access is
necessary, in which case, it will be quarterly;
(ii) Maintenance of a "Call-Before-You-Dig"
program and all required and related cable locates;
(iii) Maintenance of sign posts along the
Qwest System right-of-way with the number of the local "Call-Before-
You-Dig" organization and the "800" number for Qwest's
"Call-Before-You-Dig" program; and
(iv) Assignment of fiber maintenance technicians
to locations along the route of the Qwest System at approximately
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
intervals dependent upon terrain and accessability.
(b) Unscheduled Maintenance. Non-routine maintenance
and repair of the Qwest System which is not included as Scheduled
Maintenance ("Unscheduled Maintenance"), shall be performed by or
under the direction of Service Provider. Unscheduled Maintenance
shall commence with respect to each Segment upon the effective
date of the grant of the IRU therein, as provided in the IRU
Agreement. Unscheduled Maintenance shall consist of:
(i) "Emergency Unscheduled Maintenance" in
response to an alarm identification by Service Provider's
Operations Center, notification by Service Recipient or
notification by any third party of any failure, interruption or
impairment in the operation of the Qwest System, or any event
imminently likely to cause the failure, interruption or
impairment in the operation of the Qwest System.
(ii) "Non-Emergency Unscheduled Maintenance" in
response to any potential service-affecting situation to prevent
any failure, interruption or impairment in the operation of the
Qwest System.
Service Recipient shall immediately report the need for
Unscheduled Maintenance to Service Provider in accordance with
procedures promulgated by Service Provider from time to time.
Service Provider will log the time of Service Recipient's report,
verify the problem and dispatch personnel immediately to take
corrective action.
2. Operations Center.
Page 55
CONFIDENTIAL TREATMENT
Service Provider shall operate and maintain an
Operations Center ("OC") staffed twenty-four (24) hours a day,
seven (7) days a week by trained and qualified personnel.
Service Provider's maintenance employees shall be available for
dispatch twenty-four (24) hours a day, seven (7) days a week.
Service Provider shall have its first maintenance employee at the
site requiring Emergency Unscheduled Maintenance activity within
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
after the time Service Provider becomes aware of an event requiring
Emergency Unscheduled Maintenance, unless delayed by
circumstances beyond the reasonable control of Service Provider.
Service Provider shall maintain a toll-free telephone number to
contact personnel at the OC. Service Provider's OC personnel
shall dispatch maintenance and repair personnel along the system
to handle and repair problems detected in the Qwest System, (i)
through the Service Recipient's remote surveillance equipment and
upon notification by Service Recipient to Service Provider, or
(ii) upon notification by a third party.
3. Cooperation and Coordination.
(a) Service Recipient shall utilize an Operations
Escalation List, as updated from time to time, to report and seek
immediate initial redress of exceptions noted in the performance
of Service Provider in meeting maintenance service objectives.
(b) Service Recipient will, as necessary, arrange for
unescorted access for Service Provider to all sites of the Qwest
System, subject to applicable contractual, underlying real
property and other third-party limitations and restrictions.
(c) In performing its services hereunder, Service
Provider shall take workmanlike care to prevent impairment to the
signal continuity and performance of the Qwest System. The
precautions to be taken by Service Provider shall include
notifications to Service Recipient. In addition, Service
Provider shall reasonably cooperate with Service Recipient in
sharing information and analyzing the disturbances regarding the
cable and/or fibers. In the event that any Scheduled or
Unscheduled Maintenance hereunder requires a traffic roll or
reconfiguration involving cable, fiber, electronic equipment, or
regeneration or other facilities of the Service Recipient, then
Service Recipient shall, at Service Provider's reasonable
request, make such personnel of Service Recipient available as
may be necessary in order to accomplish such maintenance, which
personnel shall coordinate and cooperate with Service Provider in
performing such maintenance as required of Service Provider
hereunder.
(d) Service Provider shall notify Service Recipient at
least ten (10) business days prior to the date in connection with
any PSWP of any Scheduled Maintenance and as soon as possible
after becoming aware of the need for Unscheduled Maintenance.
Service Recipient shall have the right to be present during the
performance of any Scheduled Maintenance or Unscheduled
Maintenance so long as this requirement does not interfere with
Service Provider's ability to perform its obligations under this
Agreement. In the event that Scheduled Maintenance is canceled
or delayed for whatever reason as previously notified, Service
Provider shall notify Service Recipient at Service Provider's
earliest opportunity, and will comply with the provisions of the
previous sentence to reschedule any delayed activity.
4. Facilities.
(a) Service Provider shall maintain the Qwest System
Page 56
CONFIDENTIAL TREATMENT
in a manner which will permit Service Recipient's use, in
accordance with the terms and conditions of the IRU Agreement, of
the IRU, the User Fibers and the Associated Property required to
be provided under the terms of the IRU Agreement.
(b) Except to the extent otherwise expressly provided
in the IRU Agreement, Service Recipient will be solely
responsible for providing and paying for any and all maintenance
of all electronic, optronic and other equipment, materials and
facilities used by Service Recipient in connection with the
operation of the Dark Fibers, none of which is included in the
maintenance services to be provided hereunder.
5. Cable/Fibers.
(a) Service Provider shall perform appropriate
Scheduled Maintenance on the Cable contained in the Qwest System
in accordance with Service Provider's then current preventative
maintenance procedures as agreed to by Service Recipient, which
shall not substantially deviate from standard industry practice.
(b) Service Provider shall have qualified
representatives on site any time Service Provider has reasonable
advance knowledge that another person or entity is engaging in
construction activities or otherwise digging within five (5) feet
of the Cable.
(c) Service Provider shall maintain sufficient
capability to teleconference with Service Recipient during an
Emergency Unscheduled Maintenance in order to provide regular
communications during the repair process. When correcting or
repairing Cable discontinuity or damage, including but not
limited to in the event of Emergency Unscheduled Maintenance,
Service Provider shall use reasonable efforts to repair traffic-
affecting discontinuity within
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
after the Service Provider maintenance employee's arrival at the
problem site. In order to accomplish such objective, it is
acknowledged that the repairs so effected may be temporary in
nature. In such event, within
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
after completion of any such Emergency Unscheduled Maintenance,
Service Provider shall commence its planning for permanent
repair, and thereafter promptly shall notify Service Recipient of
such plans, and shall implement such permanent repair within an
appropriate time thereafter. Restoration of open fibers on fiber
strands not immediately required for service shall be completed
on a mutually agreed-upon schedule. If the fiber is required for
immediate service, the repair shall be scheduled for the next
available Planned Service Work Period (PSWP).
(d) In performing repairs, Service Provider shall
comply with the splicing specifications as set forth in Exhibit
D. Service Provider shall provide to Service Recipient any
modifications to these specifications as may be necessary or
appropriate in any particular instance for Service Recipient's
approval, which approval shall not be unreasonably withheld.
(e) Service Provider's representatives that are
responsible for initial restoration of a cut Cable shall carry on
their vehicles the typically appropriate equipment that would
enable a temporary splice, with the objective of restoring
operating capability in as little time as possible. Service
Provider shall maintain and supply an inventory of spare Cable in
storage facilities supplied and maintained by Service Provider at
Page 57
CONFIDENTIAL TREATMENT
strategic locations to facilitate timely restoration.
6. Planned Service Work Period (PSWP).
Scheduled Maintenance which is reasonably expected to
produce any signal discontinuity must be coordinated between the
parties. Generally, this work should be scheduled after midnight
and before 6:00 a.m. local time. Major system work, such as
fiber rolls and hot cuts, will be scheduled for PSWP weekends. A
calendar showing approved PSWP will be agreed upon in the last
quarter of every year for the year to come. The intent is to
avoid jeopardy work on the first and last weekends of the month
and high-traffic holidays.
7. Restoration.
(a) Service Provider shall respond to any interruption
of service or a failure of the Dark Fibers to operate in
accordance with the specifications set forth in Exhibit D (in any
event, an "Outage") as quickly as possible (allowing for delays
caused by circumstances beyond the reasonable control of Service
Provider) in accordance with the procedures set forth herein.
(b) When restoring a cut Cable in the Qwest System,
the parties agree to work together to restore all traffic as
quickly as possible. Service Provider, promptly upon arriving on
the site of the cut, shall determine the course of action to be
taken to restore the Cable and shall begin restoration efforts.
Service Provider shall splice fibers tube by tube or ribbon by
ribbon or fiber bundle by fiber bundle, rotating between tubes or
ribbons operated by the separate Interest Holders (as defined in
paragraph 9(a)), including Service Recipient, in accordance with
the following described priority and rotation mechanics; provided
that, lit fibers in all buffer tubes or ribbons or fiber bundles
shall have priority over any dark fibers in order to allow
transmission systems to come back on line; and provided further
that, Service Provider will continue such restoration efforts
until all lit fibers in all buffer tubes or ribbons are spliced
and all traffic restored. In general, priority among Interest
Holders affected by a cut shall be determined on a rotating
restoration-by-restoration and Segment-by-Segment basis, to
provide fair and equitable restoration priority to all Interest
Holders, subject only to such restoration priority to which Qwest
is contractually obligated prior to the date of the Agreement.
Service Provider shall use all reasonable efforts to implement a
Qwest System-wide rotation mechanism on a Segment-by-Segment
basis so that the initial rotation order of the Interest Holders
in each Segment is varied (from earlier to later in the order),
such that as restorations occur, each Interest Holder has
approximately equivalent rotation order positions across the
Qwest System. Additional participants in the Qwest System that
become Interest Holders after the date hereof shall be added to
the restoration rotation mechanism.
(c) The goal of emergency restoration splicing shall
be to restore service as quickly as possible. This may require
the use of some type of mechanical splice, such as the "3M Fiber
Lock" to complete the temporary restoration. Permanent
restorations will take place as soon as possible after the
temporary splice is complete.
8. Subcontracting.
Service Provider may subcontract any of the maintenance
services hereunder; provided that Service Provider shall require
the subcontractor(s) to perform in accordance with the
requirement and procedures set forth herein. The use of any such
Page 58
CONFIDENTIAL TREATMENT
subcontractor shall not relieve Service Provider of any of its
obligations hereunder.
9. Fees and Costs.
(a) Scheduled Maintenance Fees. The fees payable for
any and all Scheduled Maintenance hereunder shall be determined
in accordance with the following provisions. During any time
after the Acceptance Date for any Segment but subject to
paragraph 10 below, Qwest shall be the Service Provider and
provide Scheduled Maintenance at a cost not to exceed $
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
per route mile per year, subject to the CPI adjustment described below
(the "Qwest Fixed Fee") and Unscheduled Maintenance as provided
in subparagraph 9 below. The Scheduled Maintenance fee payable
by Service Recipient shall be equal to a pro rata share of
Qwest's Costs based first upon the number of conduits so
maintained by Qwest and included in such Costs and second upon
the number of Interest Holders (as defined in Section 10.4 of the
Agreement) in the portion of the Qwest System so maintained by
Qwest and included in such Costs; provided however, the total fee
shall in no event exceed the amount of the Qwest Fixed Fee as
adjusted by the CPI-U Adjustment.
A quarter of the first such Scheduled Maintenance fee with
respect to each Segment will be due and payable thirty (30) days
after the Acceptance Date with respect to such Segment.
Thereafter, one quarter of such fee shall be due quarterly. All
fees shall be paid by Service Recipient within thirty (30) days
of receipt of invoice therefor. The Qwest Fixed Fee, if
applicable, may be adjusted annually, in Qwest's Sole discretion,
beginning with the first anniversary date of the execution date
of this Agreement, for increases in the United States Bureau of
Labor Statistics, CPI-U All Services Index (unadjusted), as
originally published. Said adjustment shall be hereinafter
referred to as "CPI-U Adjustment". Such fee, as adjusted by the
CPI-U Adjustment, shall be equal to the product of the fee
specified herein multiplied by the fraction (i) whose numerator
is the CPI-U All Services for March of the previous calendar year
for which the adjustment to the fee is being made, and (ii) whose
denominator is the CPI-U All Services for March of the preceding
year. The adjusted fee shall remain in effect until the next
annual fee is due, when a new adjusted fee fixed pursuant to this
provision shall become effective. In no event shall the amount
of the fee as adjusted pursuant to this provision be less than
the amount of fee in effect for the immediately-preceding year.
The parties agree that the Index for March 1995 is defined as
151.4. In the event that the Bureau of Labor Statistics (or any
successor organization) changes the current base of the CPI-U
from 1982-84 = 100, the calculation of a fee under this provision
shall be adjusted to ensure that Qwest receives the same amount
as it would have had, had the base not been changed. In the
event the Bureau of Labor Statistics (or any successor
organization) no longer publishes the CPI-U, Qwest may, subject
to Service Recipient's agreement (which shall not be unreasonably
withheld), designate the statistical index it deems most
appropriate for collocation of adjustments to a fee and, from the
date the CPI-U ceased to be published, such index shall be used
to make adjustments in a fee under this provision.
(b) Unscheduled Maintenance Fees. If the aggregate
amount of the Costs of Unscheduled Maintenance required as a
result of any single event or multiple, closely-related events is
less than
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
Page 59
CONFIDENTIAL TREATMENT
, such Costs shall be borne by Service Provider. For any other
Unscheduled Maintenance, the Costs thereof shall be allocated
among the various Interest Holders in the conduit, cable an/or
fibers affected thereby as follows: (i) Costs of Unscheduled
Maintenance solely to or affecting a conduit or cable which
houses fibers of a single Interest Holder shall be borne 100% by
such Interest Holder; (ii) Costs of Unscheduled Maintenance to or
affecting a conduit which houses multiple innerduct conduits, not
including such Costs attributable to the repair or replacement of
fiber therein, shall be borne proportionately by the Interest
Holds in each of the affected innerduct conduits based on the
ratio that such affected conduit bears to the total number of
affected innerduct conduits, and (iii) Costs of Unscheduled
Maintenance attributable to the repair or replacement of fiber,
including the acquisition, installation, inspection, testing and
splicing thereof, shall be borne proportionately by the Interest
Holders in the affected fiber, based on the ratio that the number
of affected fibers subject to the interest of each such Interest
Holder bears to the total number of affected fibers. All such
Costs which are allocated to Service Recipient pursuant to the
foregoing provisions shall be the responsibility of and paid by
Service Recipient within thirty (30) days after its receipt from
Service Provider of an invoice therefor.
(c) Costs. "Costs" means the actual, direct costs
paid or payable in accordance with the established accounting
procedures generally used by each party, as the case may be, and
which it utilizes in billing third parties for reimbursable
projects, which costs shall include, without limitation, the
following: (i) labor costs, including wages and salaries, and
benefits and overhead allocable to such labor costs (overhead
allocation percentage shall not exceed the lesser of (x) the
percentage Service Provider typically allocates to its internal
projects or (y)
##MATERIAL OMITTED AND SEPARATELY FILED UNDER AN APPLICATION FOR
CONFIDENTIAL TREATMENT##
, and (ii) other direct costs and out-of-pocket expenses on a pass-
through basis (e.g., equipment, materials, supplies, contract
services, etc.).
10. Term.
(a) Service Provider's obligation to perform
maintenance on the relevant portion of the Qwest System shall be
for an initial term expiring June 30, 2006. Qwest shall be the
Service Provider. Thereafter, Qwest shall have no obligation to
provide Scheduled or Unscheduled Maintenance hereunder, but shall
be entitled to continue to provide maintenance under the terms
and conditions of this agreement.
(b) Notwithstanding Section 10(a) above, Qwest
represents and warrants that it shall either (1) make a proposal
not later than June 30, 2004, to the several Service Recipients
to continue to serve as the Service Provider for the services
described in this Exhibit H under commercially reasonable terms
for the remainder of the Minimum Period following June 30, 2006,
or (2) provide notice to the Service Recipients that Qwest shall
not continue to provide those services beyond June 30, 2006.
Should Qwest make a proposal under clause (1), the Service
Recipients and Qwest shall negotiate in good faith toward
reaching agreement on those services. If the parties have not
concluded an agreement for continuing services by December 31,
2004, the Service Recipients shall be entitled to solicit
proposals from other vendors and may select whichever vendor or
vendors they jointly agree to use for all or separate portions of
the Qwest System and Service Recipient's fibers and Associated
Property, to include Qwest or separate vendors as each Service
Page 60
CONFIDENTIAL TREATMENT
Recipient individually selects for its portion of the Qwest System and for its
own fibers and Associated Property. Should Qwest provide notice under clause
(2), the Service Recipients may solicit proposals from other vendors and may
select another vendor or vendors to assume after June 30, 2006, the Service
Provider responsibilities, and Qwest agrees to cooperate fully in the
negotiations and transition period.
EXHIBIT I
UNDERLYING RIGHTS AND
---------------------
UNDERLYING RIGHTS REQUIREMENTS
------------------------------
Note: Prior to April 6, 1995 Qwest Communications Corporation was known as
"Southern Pacific Telecommunications Company," and the documents listed
below that predate April 6, 1995 are in that former name.
Pueblo Easements:
Easement Agreement dated October 25, 1995 between the Pueblo of Santa Xxx and
Qwest Communications Corporation.
Easement Agreement dated February 2, 1996 between the Pueblo of Santo Xxxxxxx
and Qwest Communications Corporation.
Easement Agreement dated February 26, 1996 between the Pueblo of San Xxxxxx and
Qwest Communications Corporation.
Easement Agreement dated April 12, 1996 between the Pueblo of Isleta and Qwest
Communications Corporation.
Easement Agreement dated June 6, 1996 between the Pueblo of Sandia and Qwest
Communications Corporation.
SPTCo Easement:
Easement Agreement dated September 30, 1991 between Southern Pacific
Transportation Company, as Grantor, and Southern Pacific Telecommunications
Company, as Grantee.
Fifth Amendment to Easement Agreement dated August 9, 1996 between Southern
Pacific Transportation Company, as Grantor, and Qwest Communications
Corporation, as Grantee.
D&RGW Easement:
Easement Agreement dated September 30, 1991 between Denver and Rio Grande
Western Railroad Company, as Grantor, and Southern Pacific Telecommunications
Company, as Grantee.
First Amendment to Easement Agreement dated July 14, 1993 between Denver and Rio
Grande Western Railroad Company, as Grantor, and Southern Pacific
Telecommunications Company, as Grantee.
Second Amendment to Easement Agreement dated May 1, 1995 between Denver and Rio
Grande Western Railroad Company, as Grantor, and Southern Pacific
Telecommunications Company, as Grantee.
SSW Easement:
Easement Agreement dated September 30, 1991 between St. Louis Southwestern
Railway, as Grantor, and Southern Pacific Telecommunications Company, as
Grantee.
Second Amendment to Easement Agreement dated November 16, 1994 between St. Xxxxx
Xxxx 61
CONFIDENTIAL TREATMENT
Southwestern Railway, as Grantor, and Southern Pacific Telecommunications
Company, as Grantee.
ATSF Easement
Master Rail Corridor Fiber Optic Agreement dated December 5, 1994 between The
Xxxxxxxx, Topeka and Santa Fe Railway Company, as Grantor, and Southern Pacific
Telecommunications Company, as Grantee.
CSX Easement:
Fiber Optic Placement Agreement dated as of March 1, 1995 between CSX
Transportation, Inc., as Grantor, and Southern Pacific Telecommunications
Company, as Grantee.
Letter Agreement dated as of March 1, 1995 between CSX Transportation, Inc., as
Grantor, and Southern Pacific Telecommunications Company, as Grantee.
DART Easement:
Fiber Optics Agreement dated as of February 3, 1994 between Dallas Area Rapid
Transit, as Grantor, and Southern Pacific Telecommunications Company, as
Grantee.
First Amendment to Fiber Optics Agreement dated as of November 13, 1995 between
Dallas Area Rapid Transit, as Grantor, and Southern Pacific Telecommunications
Company, as Grantee.
Fiber Optics Easement dated as of December 21, 1994 between Dallas Area Rapid
Transit, as Grantor, and Southern Pacific Telecommunications Company, as
Grantee.
MTA Easement:
(SPTCo Easement Agreement dated September 30, 1991 was assigned as part of sale
of route.)
Amendment to Easement Agreement dated January 13, 1995 between the Los Angeles
County Metropolitan Transportation Authority, as Grantor, and Southern Pacific
Telecommunications Company, as Grantee.
First Severance Agreement and Amendment to Easement Agreement dated June 23,
1995 between Los Angeles County Metropolitan Transportation Authority and
Southern Pacific Telecommunications Company.
Public Easements:
License Agreement dated March 2, 1993 between the Utah Department of
Transportation and Southern Pacific Telecommunications Company.
Agreement dated March 17, 1992 between The Moffat Tunnel Improvement District
and Southern Pacific Telecommunications Company.
License Agreement dated September 11, 1995 between the City and County of
Denver, Board of Water Commissioners and SP Construction Services (covering the
Highline Canal Property).
License Agreement dated August 30, 1995 between the City and County of Denver,
Board of Water Commissioners and SP Construction Services (covering Conduit
Number 55).
License Agreement dated August 30, 1995 between the City and County of Denver,
Board of Water Commissioners and SP Construction Services (covering Conduit
Number 96).
License Agreement No. 95-01-25 dated July 24, 1995 between the City of Aurora,
Director of Utilities and Qwest Communications Corporation.
Page 62
CONFIDENTIAL TREATMENT
License Agreement dated August 18, 1995 between the City of Aurora, Director of
Utilities and Qwest Communications Corporation.
Arapahoe County Street Cut and R.O.W. Use Permit Nos. SC5212, SC5213, SC5193,
SC5191, SC5190, SC5194, SC5195, and SC5192 issued to Southern Pacific
Telecommunications Company by Arapahoe County.
Utility Permit Nos. 596067, 595099, 95-145, 95-147, and 95-149 issued to
Southern Pacific Telecommunications Company by the Colorado Department of
Transportation.
Permit for Right-of-Way Use and/or Construction Permit No. 1095 1262 E issued by
SP Construction Services by Xxxxxxx County.
Utility Permit Nos. 7528, 7526, and 7525 issued to Qwest Communications
Corporation by the Colorado Department of Transportation.
Permit dated March 3, 1995 issued to SP Telecom Construction Services by the
Huerfano County Road and Bridge Department.
Permit for Construction and Installation of Communication Facilities in Public
Rights of Way (Permit No. TFI-95-002) dated February 21, 1995 issued to
Southern Pacific Telecommunications Company by Las Animas County.
Contractor License No. 70 dated May 9, 1995 issued to Southern Pacific
Telecommunications by the Town of Xxxxxxx.
Permit dated April 28, 1995 issued to Southern Pacific Telecommunications
Company by the Town of Xxxxxxx.
Right-of-Way 2983, Book 29, dated March 22, 1995 between the State of Colorado,
State Board of Land Commissioners, as Grantor, and Qwest Communications
Corporation, as Grantee.
Letter dated April 25, 1995 from the City of Trinidad, authorizing SP Telecom to
proceed with construction on the North Linden Avenue Communication Conduits.
Ordinance No. 950310 issued by the City of Kansas City, Missouri, granting
Southern Pacific Telecommunications Company and MCI Telecommunications
Corporation the right to install and maintain underground telecommunication
lines.
Missouri Highway and Transportation Commission Permit Nos. 0-00-00000, 6-95-
00286, 0-00-00000, 0-00-00000, 0-00-00000, 0-00-00000, and 0-00-00000 and
Excavation Permit(s) Receipts.
Private Easements:
Easement dated November 21, 1995 between American Federation of Human Rights, as
Grantor and Qwest Communications Corporation, as Grantee.
Easement dated September 26, 1995 between Xxx X. Xxxxxxx and Xxxxxxx Xxxxxx
Xxxxxxx, as Grantors and Qwest Communications Corporation, as Grantee.
Easement dated December 4, 1995 between Xxxxx X. Xxxxxxxxx and Xxxxxx X.
Xxxxxxxxx, as Grantors and Qwest Communications Corporation, as Grantee.
Easement dated March 29, 1995 between Xxxxx X. Xxxxxxx and Xxxxxx X. Xxxxxxx, as
Grantors and Qwest Communications Corporation, as Grantee.
Easement dated March 29, 1995 between Walsenburg Sand and Gravel Company, as
Grantor and Qwest Communications Corporation, as Grantee.
Easement dated March 29, 1995 between Xxx Xxxxx Xxxxxx, as Grantor and Qwest
Communications Corporation, as Grantee.
Easement dated March 30, 1995 between Lindo X. Xxxxxxx and Xxxxxxx X. Xxxxxxx,
Page 63
CONFIDENTIAL TREATMENT
as Grantors and Qwest Communications Corporation, as Grantee.
Easement dated May 19, 1995 between Xxxxxx Propane Gas, as Grantor and Qwest
Communications Corporation, as Grantee.
Easement dated March 30, 1995 between Xxxxxx X. Xxxxx, as Grantor and Qwest
Communications Corporation, as Grantee.
Easement dated April 17, 1995 between Xxxx Xxxxx Xxxxx, as Grantor and Qwest
Communications Corporation, as Grantee.
Easement dated May 15, 1995 between Xxxx Xxxxxx and Xxxxx Xxxx Xxxxxx, as
Grantors and Qwest Communications Corporation, as Grantee.
Easement between Xxxxxx X. Xxxxxxxxxx (2/19/96), Xxxxxxxx X. Xxxxxx (4/17/95),
Xxxx X. Xxxxxxx (7/17/95), Xxxxx X. Xxxxxxxx (4/16/95) and Xxxxxxx Xxxxxxxx
(4/16/95), as Grantors and Qwest Communications Corporation, as Grantee.
Easement dated March 30, 1995 between Xxx Xxxxx and Xxxxx Xxxxx, as Grantors,
and Qwest Communications Corporation, as Grantee.
Easement dated March 31, 1995 between Trinidad Properties, Inc. and MYBI
Partnership, as Grantors, and Qwest Communications Corporation, as Grantee.
Easement dated June 6, 1995 between Xxxx Xxxxx, as Grantor, and Qwest
Communications Corporation, as Grantee.
Easement dated May 5, 1995 between Xxxxxx X. Winter and Xxxxx X. Winter, as
Grantors, and Qwest Communications Corporation, as Grantee.
Easement dated May 18, 1995 between Ayuda Me Dios, as Grantor, and Qwest
Communications Corporation, as Grantee.
Easement dated April 19, 1995 between Xxxxxxx Xxxxxx and Xxxx X. Xxxxxx, as
Grantors, and Qwest Communications Corporation, as Grantee.
Easement dated June 1, 1995 between Interstate Underground Warehouse and
Industrial Park, Inc., as Grantor, and Qwest Communications Corporation, as
Grantee.
Easement dated May 26, 1995 between Xxxxxxx Xxxxxxx and Xxxxxxx Xxxxxxx, as
Grantors, and Qwest Communications Corporation, as Grantee.
Easement dated August 28, 1996 between Red Creek Ranch, Inc., as Grantor and
Qwest Communications, as Grantee (Pueblo, CO).
Miscellaneous Easements
Grant of Right of Way and Easement dated December 20, 1961 between X. X.
Xxxxxxxx and X. Xxxxxxx Xxxxxx, as Grantors, and American Liberty Pipe Line
Company, as Grantee.
Amendment to Right-of-Way Agreement dated April 19, 1994 between Xxxxxx/LICO
Properties II, as Grantor, and Southern Pacific Telecommunications Company, as
Grantee.
Amendment to Right of Way Grant dated January 31, 1996 between Prestonwood Golf
Club Corporation, as Grantor, and Qwest Communications Corporation, as Grantee.
Miscellaneous Documents:
SP Construction Services Safety Manual
Railroad Safety-Rules Governing Contractors Working on Railroads
Railroad Rules and Instructions for Maintenance of Way and Engineering and
Operating Manuals for Southern Pacific Lines
Page 64
CONFIDENTIAL TREATMENT
The Xxxxxxxx, Topeka and Santa Fe Railway Company Manual
Page 65
