AIA DOCUMENT A101-1997
STANDARD FORM OF AGREEMENT BETWEEN OWNER AND CONTRACTOR
WHERE THE BASIS OF PAYMENT IS A STIPULATED SUM
AGREEMENT made as of the Twenty-first day of March in the year Two Thousand Two
(In words, indicate day, month and year)
BETWEEN the Owner: Sun Bancshares, Inc.
(Name, address and other information) ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇
▇▇▇▇▇▇▇▇ ▇▇▇▇▇, ▇▇ ▇▇▇▇▇
And the Contractor: Chancel Construction Group, Inc.
(Name, address and other information) ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇
▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇
The Project is: Sunbank
(Name and location) Murrells Inlet, SC
The Architect is: Designed to Build
(Name, address and other information) ▇▇▇▇▇▇ ▇. Privelle, AIA
▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇, #▇▇▇
▇▇▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇
The Owner and Contractor agree as follows:
ARTICLE 1 THE CONTRACT DOCUMENTS
The Contract Documents consist of this Agreement, Conditions of the
Contract (General, Supplementary and other Conditions), Drawings,
Specifications, Addenda issued prior to execution of this Agreement, other
documents listed in this Agreement and Modifications issued after execution
of this Agreement; these form the Contract, and are as fully a part of the
Contract as if attached to this Agreement or repeated herein. The Contract
represents the entire and integrated agreement between the parties hereto
and supersedes prior negotiations, representations or agreements, either
written or oral. An enumeration of the Contract Documents, other than
Modifications, appears in Article 8.
ARTICLE 2 THE WORK OF THIS CONTRACT
The Contractor shall fully execute the Work described in the Contract
Documents, except to the extent specifically indicated in the Contract
Documents to be the responsibility of others.
ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION
3.1 The date of commencement of the Work shall be the date of this
Agreement unless a different date is stated below or provision is made for
the date to be fixed in a notice to proceed issued by the Owner.
(Insert the date of commencement if it differs from the date of this
Agreement or, if applicable, state that the date will be fixed in a notice
to proceed.)
3.1.1 The date of commencement for this Contract shall be considered ten
(10) days after the completion of the following items:
3.1.1.1 Receipt by the Contractor of signed Contract Agreement.
3.1.1.2 Receipt by the Contractor of written authorization from the
Owner's Representative to begin construction.
3.1.1.3 Receipt by the Contractor of a policy of builder's risk
insurance from the Owner's insurance company naming Chancel
Construction Group, Inc. as additional insured.
3.1.1.4 Receipt by the Contractor of evidence that financial
arrangements have been made to fulfill the Owner's
obligations under the Contract per Article 2.2.1 of the
General Conditions.
3.1.1.5 Receipt by the Contractor of fifteen (15) sets of final
plans.
3.1.1.6 Receipt of a building permit.
3.1.2 If the responsibilities of the Owner as stated in 3.1.1 are not met
within thirty (30) days of the date of this Agreement, then the Contractor
shall have the right to cancel this Agreement without any responsibility to
the Owner.
If, prior to the commencement of the Work, the Owner requires time to file
mortgages, mechanic's liens and other security interests, the Owner's time
requirement shall be as follows:
3.2 The Contract Time shall be measured from the date of commencement.
3.3 The Contractor shall achieve Substantial Completion of the entire Work
not later than 210 days from the date of commencement, or as follows:
2
(Insert number of calendar days. Alternatively, a calendar date may be used
when coordinated with the date of commencement. Unless stated elsewhere in
the Contract Documents, insert any requirements for earlier Substantial
Completion of certain portions of the Work)
The Work shall be considered substantially complete when the Contractor has
met all of its requirements to receive a Certificate of Occupancy for the
building.
, subject to adjustments of this Contract Time as provided in the Contract
Documents. (Insert provisions, if any, for liquidated damages relating to
failure to complete on time or for bonus payments for early completion of
the Work.)
ARTICLE 4 CONTRACT SUM
4.1 The Owner shall pay the Contractor the Contract Sum in current funds
for the Contractor's performance of the Contract. The Contract Sum shall be
One Million, Three Hundred Sixty-One Thousand, One Hundred Sixteen and
No/100's-----Dollars ($1,361,116.00), subject to additions and deductions
as provided in the Contract Documents.
4.2 The Contract Sum is based upon the following alternates, if any, which
are described in the Contract Documents and are hereby accepted by the
Owner: (State the numbers or other identification of accepted alternates.
If decisions on other alternates are to be made by the Owner subsequent to
the execution of this Agreement, attached a schedule of such other
alternates showing the amount for each and the date when that amount
expires.)
4.3 Unit prices, if any, are as follows:
1. Off site fill dirt (not for change of scope). $4.00/cubic yard
ARTICLE 5 PAYMENTS
5.1 PROGRESS PAYMENTS
5.1.1 Based upon Applications for Payment submitted to the Architect by
the Contractor and Certificates for Payment issued by the Architect, the
Owner shall make progress payments on account of the Contract Sum to the
Contractor as provided below and elsewhere in the Contract Documents.
5.1.2 The period covered by each Application for Payment shall be one
calendar month ending on the last day of the month, or as follows:
5.1.3 Provided that an Application for Payment is received by the Architect
not later than the first (1st) day of a month, the Owner shall make payment
to the Contractor not later than the tenth (10th) day of the same month. If
an Application for Payment is received by the Architect after the
application date fixed above, payment shall be made
3
by the Owner not later than ten (10) days after the Architect receives the
Application for Payment.
5.1.4 Each Application for Payment shall be based on the most recent
schedule of values submitted by the Contractor in accordance with the
Contract Documents. The schedule of values shall allocate the entire
Contract Sum among the various portions of the Work. The schedule of values
shall be prepared in such form and supported by such data to substantiate
its accuracy as the Architect may require. This schedule, unless objected
to by the Architect, shall be used as a basis for reviewing the
Contractor's Applications for Payment.
5.1.5 Applications for Payment shall indicate the percentage of completion
of each portion of the Work as of the end of the period covered by the
Application for Payment.
5.1.6 Subject to other provisions of the Contract Documents, the amount of
each progress payment shall be computed as follows:
.1 Take that portion of the Contract Sum properly allocable to
completed Work as determined by multiplying the percentage
completion of each portion of the Work by the share of the
Contract Sum allocated to that portion of the Work in the
schedule of values, less retainage of ten percent (10%). Pending
final determination of cost to the Owner of changes in the Work,
amounts not in dispute shall be included as provided in
Subparagraph 7.3.8 of AIA Document A201-1997;
.2 Add that portion of the Contract Sum properly allocable to
materials and equipment delivered and suitably stored at the site
for subsequent incorporation in the completed construction (or,
if approved in advance by the Owner, suitably stored off the site
at a location agreed upon in writing), less retainage of ten
percent (10%);
.3 Subtract the aggregate of previous payments made by the Owner;
and
.4 Subtract amounts, if any, for which the Architect has withheld or
nullified a Certificate for Payment as provided in Paragraph 9.5
of AIA Document A201-1997.
5.1.7 The progress payment amount determined in accordance with
Subparagraph 5.1.6 shall be further modified under the following
circumstances.
.1 Add, upon Substantial Completion of the Work, a sum sufficient to
increase the total payments to the full amount of the Contract
Sum, less such amounts as the Architect shall determine for
incomplete Work, retainage applicable to such work and unsettled
claims; and (Subparagraph 9.8.5 of AIA Document A201-1997
requires release of applicable retainage upon Substantial
Completion of Work with consent of surety, if any)
4
.2 Add, if final completion of Work is thereafter materially delayed
through no fault of the Contractor, any additional amounts
payable in accordance with Subparagraph 9.10.3 of AIA Document
A201-1997.
5.1.8 Reduction or limitation of retainage, if any, shall be as follows:
(If it is intended, prior to Substantial Completion of the entire Work, to
reduce or limit the retainage resulting from the percentages inserted in
Clauses 5.1.6.1 and 5.1.6.2 above, and this is not explained elsewhere in
the Contract Documents, insert here provisions for such reduction or
limitation.
Upon completion of 50 percent of the Work including materials stored,
retainage shall be reduced to 5 percent provided the Work is reasonably on
schedule and workmanship meets the intent of the Contract Documents.
5.1.9 Except with the Owner's prior approval, the Contractor shall not make
advance payments to suppliers for materials or equipment, which have not
been delivered and stored at the site.
5.2 FINAL PAYMENT
5.2.1 Final payment, constituting the entire unpaid balance of the Contract
Sum, shall be made by the Owner to the Contractor when:
.1 the Contractor has fully performed the Contract except for the
Contractor's responsibility to correct Work as provided in
Subparagraph 12.2.2 of AIA Document A201-1997, and to satisfy
other requirements, if any, which extend beyond final payment;
and
.2 a final Certificate for Payment has been issued by the Architect.
5.2.2 The Owner's final payment to the Contractor shall be made no later
than 30 days after the issuance of the Architect's final Certificate for
Payment, or as follows:
ARTICLE 6 TERMINATION OR SUSPENSION
6.1 The Contract may be terminated by the Owner or the Contractor as
provided in Article 14 of AIA Document A201-1997.
6.2 The Work may be suspended by the Owner as provided in Article 14 of
AIA Document A201-1997.
ARTICLE 7 MISCELLANEOUS PROVISIONS
7.1 Where reference is made in this Agreement to a provision of AIA
Document A201-1997 or another Contract Document, the reference refers to
that provision as amended or supplemented by other provisions of the
Contract Documents.
5
7.2 Payments due and unpaid under the Contract shall bear interest from
the date payment is due at the rate stated below, or in the absence
thereof, at the legal rate prevailing from time to time at the place where
the Project is located.
(Insert rate of interest agreed upon, if any.)
(Usury laws and requirements under the Federal Truth in Lending Act,
similar state and local consumer credit laws and other regulations at the
Owner's and Contractor's principal places of business, the location of the
Project and elsewhere may affect the validity of this provision. Legal
advice should be obtained with respect to deletions or modifications, and
also regarding requirements such as written disclosures or waivers.)
7.3 The Owner's representative is:
(Name, address and other information)
▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇
Sun Bancshares, Inc.
▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇
▇▇▇▇▇▇▇▇ ▇▇▇▇▇, ▇▇ ▇▇▇▇▇
7.4 The Contractor's representative is:
(Name, address and other information)
▇▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇, Project Manager
Chancel Construction Group, Inc.
▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇
▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇
7.4.1 The Contractor's representative does not have authority to commit
or bind the Contractor to any agreement that is not within the Contract
Documents and which will require a Change Order as required by the Contract
Documents. All Change Orders and Release of Liens must be approved in
writing by an officer of the Contractor.
7.5 Neither the Owner's nor the Contractor's representative shall be
changed without ten days' written notice to the other party.
7.6 Other provisions:
ARTICLE 8 ENUMERATION OF CONTRACT DOCUMENTS
8.1 The Contract Documents, except for Modifications issued after
execution of this Agreement, are enumerated as follows:
8.1.1 The Agreement is this executed 1997 edition of the Standard Form of
Agreement Between Owner and Contractor, AIA Document A101-1997.
8.1.2 The General Conditions are the 1997 edition of the General
Conditions of the Contract for Construction, AIA Document A201-1997.
8.1.3 The Supplementary and other Conditions of the Contract are those
contained in the Project Manual dated , and are as follows:
6
Document Title Pages
8.1.4 The Specifications are those contained in the Project Manual dated
as in Subparagraph 8.1.3, and are as follows:
(Either list the Specifications here or refer to an exhibit attached to
this Agreement.)
Document Title Pages
8.1.5 The Drawings are as follows, and are dated unless a different date
is shown below:
(Either list the Drawings here or refer to an exhibit attached to this
Agreement.)
Document Title Pages
See Attachment A.
8.1.6 The Addenda, if any, are as follows:
Document Title Pages
1 March 4, 2002 1
2 March 21, 2002 3
Portions of Addenda relating to bidding requirements are not part of the
Contract Documents unless the bidding requirements are also enumerated in
this Article 8.
8.1.7 Other documents, if any, forming part of the Contract Documents are
as follows:
(List here any additional documents that are intended to form part of the
Contract Documents AIA Document A201-1997 provides that bidding
requirements such as advertisement or invitation to bid, Instructions to
Bidders, sample forms and the Contractor's bid are not part of the Contract
Documents unless enumerated in this Agreement. They should be listed here
only if intended to be part of the Contract Documents.)
7
This Agreement is entered into as of the day and year first written above
and is executed in at least there original copies, of which one is to be
delivered to the Contractor, one to the Architect for use in the administration
of the Contract, and the remainder to the Owner.
/s/ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ /s/ ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇
------------------------------------ --------------------------------
OWNER CONTRACTOR
▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇, President ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇, President
------------------------------------ --------------------------------
(Printed name and title) (Printed name and title)
8
STANDARD FORM OF AGREEMENT
BETWEEN
SUN BANCSHARES, INC.
AND
CHANCEL CONSTRUCTION GROUP, INC.
ATTACHMENT A
------------
8.1.5 The Drawings are as follows:
Number Title Date
------ ----- ----
CV-1 Cover Sheet 2/20/02
▇▇-▇ ▇▇▇▇▇▇▇▇ "▇" - ▇▇▇▇▇▇▇▇ Code Summary 2/20/02
C-1 Site Development Plan 2/20/02
C-2 Existing & Landscaping 2/20/02
C-3 Drainage Plan 2/20/02
C-4 Erosion & Sedimentation Control Plan 2/20/02
C-5 Site Details 2/20/02
C-6 Dimension Plan 2/20/02
C-7 Site Utilities 2/20/02
C-8 Site WL Details 8/10/01
C-9 Site WWL Details 2/20/02
A-01 First Floor Plan 2/20/02
A-02 Second Floor Plan 2/20/02
A-03 First Floor Reflected Ceiling Plan 2/20/02
A-3A Second Floor Reflected Ceiling Plan 2/20/02
A-04 Exterior Elevations 2/20/02
A-05 Wall Sections 2/20/02
A-06 Roof Plan 9/26/01
A-07 First Floor Interior Elevations 2/20/02
A-7A Second Floor Interior Elevations 2/20/02
▇-▇▇ ▇▇▇▇▇▇▇▇▇: Dumbwaiter Installation 2/5/02
A-08 Interior Finish Schedules 2/20/02
A-09 Door Elevations, Schedules & Details 2/20/02
A-10 Details 2/20/02
A-11 Dormer Details 2/20/02
A-12 Front Porch Sections and Details 2/20/02
A-13 Canopy Sections & Details 2/20/02
A-14 Building Section & Details 2/20/02
S-1 General Notes & Design Criteria 10/11/01
S-2 Foundation Plan 10/11/01
S-3 Second Floor Framing Plan 10/11/01
S-4 Roof Framing Plan 10/11/01
S-5 Foundation Sections & Details 10/11/01
S-6 Floor Sections 10/11/01
9
ATTACHMENT A
------------
Page 2
Number Title Date
------ ----- ----
S-7 Roof Sections & Details 10/11/01
S-8 Roof Framing Sections 10/11/01
S-9 Truss Framing Sections 10/11/01
P-1 1st Flr. Waste & Vent Plan 2/20/02
P-2 2nd Flr. Waste & Vent Plan 2/20/02
P-3 Risers & Details 2/20/02
P-4 Schedules-Notes-Details 2/20/02
▇-▇ ▇▇▇ ▇▇▇. ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇/▇▇/▇▇
▇-▇ ▇▇▇ ▇▇▇. Mechanical Plan 2/20/02
M-3 Notes & Details 4/20/01
M-4 Schedules 2/20/02
E-1 Electrical Site Plan 2/20/02
E-2 1st Flr. Power Plan 2/20/02
▇-▇ ▇▇▇ ▇▇▇. ▇▇▇▇▇ ▇▇▇▇ ▇/▇▇/▇▇
▇-▇ ▇▇▇ ▇▇▇. Lighting Plan Revised 2/27/02
▇-▇ ▇▇▇ ▇▇▇. Lighting Plan Revised 2/27/02
E-6 Data & Communications 2/20/02
E-7 Details & Schedules 8/10/01
E-8 Riser & Panel Schedules 2/20/02
E-9 Typical Equipment Installation 4/24/01
ETS1 Drainage Plan 6/19/01
10
ADDENDUM TO AGREEMENT OF PURCHASE AND SALE
between
OWNER
and
CONTRACTOR
Dated: March 21, 2002
This Addendum to Agreement between Owner and Contractor is an integral
part of the agreement between Owner and Contractor dated of even date herewith
to which this addendum is attached.
1. Notwithstanding anything to the contrary in the Agreement which
this addendum is made and attached, the following provisions, terms and
conditions shall control.
2. Section 2.4.2 is added and reads as follows:
2.4.2 Performance of Work By Owner. It is understood and agreed by
and between the Owner and Contractor that Owner has the right to perform certain
work, including, but not limited to, installation of fixtures and equipment
during the construction, provided, however, said work will not unreasonably
interfere with the performance of the Contractor's work in connection with this
Agreement.
3. Section 4.3.10 entitled "Claims for Consequential Damages" is
deleted and the following is inserted:
4.3.10. Liquidated Damages. It is understood and agreed that in the
event the entire Work is not Substantially Completed and a Certificate of
Occupancy for the building is not obtained from Georgetown County on or before
January 1, 2003, Contractor agrees to pay to Owner liquidated damages in the
amount of One Hundred and No/100's ($100.00) Dollars per day until the entire
Work is Substantially Complete and a Certificate of Occupancy for the building
is obtained from Georgetown County in accordance with the contract document.
Provided, however, that if the entire Work is not Substantially Complete and a
Certificate of Occupancy for the building is not obtained from Georgetown County
by April 1, 2003, the liquidated damages will increase to Two Hundred Fifty and
No/100's ($250.00) Dollars per day and thereafter will increase to Five Hundred
and No/100's ($500.00) Dollars per day on July 1, 2003, until the entire Work is
Substantially Complete and a Certificate of Occupancy for the building is
obtained from Georgetown County in accordance with the contract documents.
4. Section 4.6.4 entitled "Limitation on Consolidation or Joinder" is
deleted and the following is inserted:
4.6.4 Limitation on Consolidation or Joinder. Joinder of Architect
and Contractor is permitted.
5. Section 4.6.7 entitled "Conduct of Arbitration" is added and reads
as follows:
4.6.7 Conduct of Arbitration. The venue for any mediation or
arbitration hearing will be Georgetown County, South Carolina. The prevailing
party in any arbitration hearing will be entitled to receive from the other
party all costs and expenses, including reasonable attorneys' fees incurred or
expended in connection therewith.
6. Section 9.9 entitled "PARTIAL OCCUPANCY OR USE" is deleted.
WITNESS OUR HANDS AND SEALS this 21st day of March, 2002.
WITNESSES: OWNER:
SUN BANCSHARES, INC.
Signature not legible By: /s/ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇
--------------------- --------------------------
▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇
Signature not legible Its: President
---------------------
WITNESS OUR HANDS AND SEALS this 21st day of March, 2002.
WITNESSES: CONTRACTOR:
CHANCEL CONSTRUCTION GROUP, INC.
Signature not legible By: /s/ ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇
--------------------- --------------------------
Signature not legible Its: President
--------------------- ---------------------
