EXHIBIT 10.133
CERTAIN INFORMATION IN THIS AGREEMENT HAS BEEN OMITTED AND FILED SEPARATELY WITH
THE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THE
OMITTED PORTION. OMITTED INFORMATION HAS BEEN REPLACED BY [*].
-----------------------------------------------------------------------------------------------------------
[GRAPHIC OMITTED]
[GRAPHIC OMITTED] FINANCIAL ASSISTANCE AWARD
-----------------------------------------------------------------------------------------------------------
1 AWARD TYPE 2 AWARD NUMBER 3 PROCUREMENT REQUEST NUMBER
-----------------------------------------------------------------------------------------------------------
__ Grant
X Cooperative Agreement HSTS04-04-G-RED941 PREQ-04-RED106.1 and
-----
PREQ-04-RED106
-----------------------------------------------------------------------------------------------------------
4 RECIPIENT 5 ISSUED BY
-----------------------------------------------------------------------------------------------------------
Xx. Xxxxx XxXxxxx Transportation Security Administration
HiEnergy Technologies, Inc. Office of Acquisition
1601 Xxxxx Parkway, Xxxx X Xxxx Xxxxx, 00xx Xxxxx
Xxxxxx, XX 00000-0000 000 Xxxxx 00xx Xxxxxx
(000) 000-0000 Xxxxxxxxx, XX 00000-0000
Attn: Xxxxx Xxxxxx
-----------------------------------------------------------------------------------------------------------
6 APPLICATION TITLE & DATE
-----------------------------------------------------------------------------------------------------------
The Manhattan-II Project of the TSA's NexGen Checked Baggage Program (STOXOR)
-----------------------------------------------------------------------------------------------------------
7 AWARD PERIODS 8a FISCAL DATA
-----------------------------------------------------------------------------------------------------------
Effective Date: Date of Signature by TSA Grants Project No. Fed. Share $ Non-Fed. Total $
Officer Share $
Stage 1 Period: 9 Months Stage 1 $ 367,141 $ 0 $ 367,141
Stage 2 Period: 6 Months, if authorized by TSA Stage 2 $ 145,381 $ 0 $ 145,381
Total $ 512,222 $0.00 $ 512,222
-----------------------------------------------------------------------------------------------------------
8b FISCAL DATA continued.
-----------------------------------------------------------------------------------------------------------
Appropriation No:
05RD000000-2004-803FREDA39-3F20000000-25102 (P)
Amount Obligated: $367,141 for Performance of Stage 1 Only
-----------------------------------------------------------------------------------------------------------
9 RECIPIENT PROJECT DIRECTOR 10 TSA PROGRAM MANAGER
-----------------------------------------------------------------------------------------------------------
Name: Xxxx Xxx
Address: The Transportation Security Laboratory
Xx. Xxxxx XxXxxxx Xxxxxxx X Xxxxxx Technical Center
Xxxxxx, XX 00000
Phone: 000-000-0000
E-mail: Xxxx.Xxx@xxx.xxx
-----------------------------------------------------------------------------------------------------------
11 ADMINISTRATIVE DATA 12 FAADS DATA
CFDA Number: 97-2 TIN: 912022980
Program Office: Transportation Security DUNS: 120585299
Laboratory
Program: NexGen Checked Baggage - Manhattan-II
-----------------------------------------------------------------------------------------------------------
13 AUTHORIZED SIGNATURES - See Separate Page.
-----------------------------------------------------------------------------------------------------------
COOPERATIVE AGREEMENT
Between
HiENERGY TECHNOLOGIES, INC.
and the
TRANSPORTATION SECURITY ADMINISTRATION
Cooperative Agreement Letter
The Transportation Security Administration hereby enters into Cooperative
Agreement No. HSTS04-04-G-RED941 with HiENERGY TECHNOLOGIES, INC. in accordance
with the contributions designated in this document in Section E.2 Funding. The
total funded amount of this Agreement is:
$ 367,141 (Stage 1)
This Cooperative Agreement is awarded in support of the Manhattan II Project,
which seeks to identify and support development of technologies into deployable
systems that will provide enhanced automated threat detection and discrimination
capabilities. The Proof of Concept is the first phase of the Manhattan II
Project, which will be performed under this Cooperative Agreement.
The period of performance for this Cooperative Agreement extends from the final
signature date below through 28 June 2005 for Stage 1. This change is effected
at no additional cost to the Government. The terms and conditions of this
Cooperative Agreement are described in the following pages. HiEnergy and the
Transportation Security Administration acknowledge acceptance of this
Cooperative Agreement and agree to abide by all of the terms and conditions set
forth herein. In WITNESS WHEREOF, the parties hereto affix their signatures as
follows:
/s/ X.X. Xxxxxxx /s/ Xxxxx X. Xxxxxx/
------------------------- -------------------------
For Recipient For the TSA
X.X. Xxxxxxx Xxxxx X. Xxxxxx/
------------------------- -------------------------
Name Name
Date of Signature 3/31/05 Date of Signature 3/31/05
------- -------
Modification 1 is effective 3.28.05.
2
SECTION A - TABLE OF CONTENTS
Section A - Face Page and Table of Contents
Section B - Scope
Section C - Project Description
Section D - Project Period and Required Reports
Section E - Administrative Data
Section F - General Provisions
Section G - Special Provisions
Section H - Documents Incorporated by Reference
Section I - Attachments
3
SECTION B - SCOPE
This award is to provide support for the Manhattan II Project. The Recipient
shall perform all work in accordance with the application identified in Page 1,
Block 6.
SECTION C - PROJECT DESCRIPTION
The Recipient shall perform all work in accordance with HiEnergy Proposal dated
28 May 2004 and Revisions dated 24 August 2004, and update of 7 March 2005 for
Stage 1 only.
4
SECTION D - PROJECT PERIOD AND REQUIRED REPORTS
D.1. Project Period
The project period for Stage 1 is through 28 June 2005. Stage 2 is projected to
last 6 months, if authorized.
D.2. Deliverables
The Recipient shall submit a Project Schedule, the Required Reports, and the
Presentations to the TSA as specified in this Terms and Conditions document and
the Attachments identified in Section I in addition to the following
deliverables listed below.
a. The Project Schedule
The Recipient shall develop and maintain a project schedule using Microsoft
Project, version 2000 or later, to track and manage all the tasks and milestones
required to successfully complete the Manhattan-II Proof-of-Concept activities.
This schedule shall be utilized for the life of this project and shall be as
defined in Attachment C, the Manhattan-II Proof-of-Concept Cooperative Agreement
Data Item Description (DID). An updated Project Schedule shall be submitted to
the Program Manager, in hardcopy and electronic format, as a part of the Monthly
Status Reports, Stage 1 and Stage 2 Results Reports, and the Final
Proof-of-Concept Findings Report.
b. Required Reports
The following reports shall be submitted as follows:
----------------------- ------------------- ------------------------ ------------------------------
Reports/Document Number of copies Submit to: Due Date
----------------------- ------------------- ------------------------ ------------------------------
Monthly Status One electronic o Primary TSA Within 10 working days after
Reports copy submitted Project Technical the end of each 1-month
via email Monitor period, beginning with the
o Alternate TSA date of award.
Project Technical
Monitor
o TSA Program
Manager
o TSA Project
Support
----------------------- ------------------- ------------------------ ------------------------------
Monthly Status Telcon N/A N/A Within 5 working days of the
submittal of the Monthly
Status Report
----------------------- ------------------- ------------------------ ------------------------------
Stage 1 Results Report One electronic o Primary TSA Within 10 working days after
copy submitted Project Technical the completion of the Stage
via email Monitor 1 project period.
o Alternate TSA
Project Technical
Monitor
o TSA Program
Manager
o TSA Project
Support
----------------------- ------------------- ------------------------ ------------------------------
5
----------------------- ------------------- ------------------------ ------------------------------
Reports/Document Number of copies Submit to: Due Date
----------------------- ------------------- ------------------------ ------------------------------
Stage 2 Results Report One electronic o Primary TSA Within 10 working days after
copy submitted Project Technical the completion of the Stage
via email Monitor 2 project period.
o Alternate TSA
Project Technical
Monitor
o TSA Program
Manager
o TSA Project
Support
----------------------- ------------------- ------------------------ ------------------------------
Final One electronic o Primary TSA Within 20 working days
Proof-of-Concept copy submitted Project Technical after the completion of the
Findings Report via email Monitor Stage 2 project period.
o Alternate TSA
Project Technical
Monitor
o TSA Program
Manager
o TSA Project
Support
----------------------- ------------------- ------------------------ ------------------------------
c. Required Presentations
The presentations listed below shall be developed and presented by the
Recipient.
----------------- -------------------- ------------------------ ------------------------ ---------------
Presentation Number of copies Submit to: Date Location
----------------- -------------------- ------------------------ ------------------------ ---------------
Stage 1 Results 1 electronic copy o Primary TSA 10 working days prior N/A
Presentation submitted via Project Technical to the scheduled Stage
(Draft) Email Monitor 2 Results Presentation
o Alternate TSA
Project Technical
Monitor
o TSA Program
Manager
o TSA Project
Support
----------------- -------------------- ------------------------ ------------------------ ---------------
Stage 1 Results 1 electronic copy o Primary TSA Within 10 working days The
Presentation and 10 hardcopies Project Technical after the completion Recipient's
(Final) submitted at the Monitor of the Stage 1 project Facility
presentation. o Alternate TSA period. Project
Technical Monitor
o TSA Program
Manager
o TSA Project
Support
----------------- -------------------- ------------------------ ------------------------ ---------------
Stage 2 Results 1 electronic copy o Primary TSA 10 working days prior N/A
Presentation submitted via Project Technical to the scheduled Stage
(Draft) Email Monitor 2 Results Presentation
o Alternate TSA
Project Technical
Monitor
o TSA Program
Manager
o TSA Project
Support
----------------- -------------------- ------------------------ ------------------------ ---------------
Stage 2 Results 1 electronic copy o Primary TSA Within 10 working days The
Presentation and 10 hardcopies Project Technical after the completion Recipient's
(As Presented) submitted at the Monitor of the Stage 2 project Facility
presentation. o Alternate TSA period. Project
Technical Monitor
o TSA Program
Manager
o TSA Project
Support
----------------- -------------------- ------------------------ ------------------------ ---------------
6
----------------- -------------------- ------------------------ ------------------------ ---------------
Presentation Number of copies Submit to: Date Location
----------------- -------------------- ------------------------ ------------------------ ---------------
Final Proof-of- 1 electronic copy o Primary TSA 10 working days prior N/A
Concept submitted via Project Technical to the scheduled
Findings Email Monitor Finds Presentation
Presentation o Alternate TSA
(Draft) Project Technical
Monitor
o TSA Program
Manager
o TSA Project
Support
----------------- -------------------- ------------------------ ------------------------ ---------------
Final Proof-of- 1 electronic copy o Primary TSA Within 20 working days The TSL
Concept and 10 hardcopies Project Technical after the completion Atlantic City,
Findings submitted at the Monitor of the Stage 2 project New Jersey
Presentation presentation. o Alternate TSA period.
(As Presented) Project Technical
Monitor
o TSA Program
Manager
o TSA Project
Support
----------------- -------------------- ------------------------ ------------------------ ---------------
d. Additional Deliverables
1. A list of "commercial off the shelf" components and at least
one source from which they can be acquired.
2. A listing of non-proprietary, but specialized parts.
3. A listing of proprietary parts, including firmware.
4. Computer software in executable format only.
The Recipient shall deliver Items d.1, d.2, and d.3 with unlimited rights.
The Recipient shall deliver Item d.4 with limited rights.
SECTION E - ADMINISTRATIVE DATA
E.1. Administration
This award will be administered by:
a. Grants Officer:
Xxxxx Xxxxxx
TSA HQ, Office of Acquisition
West Tower, 10th Floor
000 Xxxxx 00xx Xxxxxx
Xxxxxxxxx, XX 00000-0000
Phone: (000) 000-0000
Fax: (000) 000-0000
The Grants Officer is the sole authority designated to obligate federal funds
and to create terms and conditions of the awards.
7
Written communications shall make reference to Cooperative Agreement No.
HSTS04-04-G-RED941 and mailed to the address in Block 5.
b. TSA Program Manager
See Page 1, Block 10
c. TSA Project Technical Monitor
Primary Xxx Xxxxxxxxx
The Transportation Security Administration (TSA)
Transportation Security Laboratory (TSL)
Xxxxxxx X Xxxxxx Technical Center
Xxxxxxxx Xxxx Xxxxxxxxxxxxx Xxxxxxx
Xxx Xxxxxx, 00000
(000) 000-0000
Xxx.Xxxxxxxxx@xxx.xxx
Alternate To be Announced
The Transportation Security Administration (TSA)
Transportation Security Laboratory (TSL)
Xxxxxxx X Xxxxxx Technical Center
Atlantic City International Airport
New Jersey, 08405
(609) 813-XXXX
d. TSA Project Support
Primary Xxx Xxxx
The Transportation Security Administration (TSA)
Transportation Security Laboratory (TSL)
Xxxxxxx X Xxxxxx Technical Center
Atlantic City International Xxxxxxx
Xxx Xxxxxx, 00000
(000) 000-0000
Xxxxxxx.XXX.Xxxx@xxx.xxx
8
e. Recipient Project Director
See Page 1, Block 9
f. Recipient Project Officer
Recipient Project Officer. The Recipient Project Officer is the individual
designated by the Recipient with concurrence from the TSA who is
responsible for the technical direction of the project. Neither the
Project Director nor the Project Officer(s) can be changed or become
substantially less involved than was indicated in the Recipient's
application without the prior written approval of the Grants Officer.
g. Neither the Recipient Project Director and Project Officer(s), nor the TSA
Program Manager has the authority to: a) issue any technical direction that
constitutes an assignment of additional work outside the scope of the award; b)
in any manner cause a change in the total cost or the time required for
performance of the award; nor c) make changes to any of the terms and conditions
or general provisions of the award.
E.2. Funding
a. The total estimated cost of the TSA share for the Recipient's performance
under this Cooperative Agreement is Costs reimbursed hereunder shall in no event
exceed that amount without prior written approval of the Grants Officer.
b. The funding for this Cooperative Agreement will be provided in two parts (if
both Stages are authorized) - the first for the completion of Stage 1
-Technology/Concept Development, and Stage 2 -System Concept Development. Unless
otherwise specified in this document, the Recipient shall be authorized to work
only those tasks and activities that are directly identified for the Stage that
is funded. Funding is provided solely for Stage 1 at time of award. The
Government reserves the right not to fund Stage 2.
c. Prior written approval of the Grants Officer is required for transfer of
funds between direct cost categories when the cumulative amount of the transfers
during the performance period exceeds ten percent (10%) of the total TSA award.
E.3. Method of Payment
a. Payment under this award will be authorized by the advance or reimbursement
payment method (using the SF 270, "Request for Advance or Reimbursement") in
compliance with information provided in the SF 424A and/or SF424C, budget
information forms. Advances or reimbursements will be provided by TSA to the
recipient after receipt and approval of SF 270s per project.
9
b. The SF 270s shall be submitted no more frequently than monthly to the
following address:
United States Coast Guard Finance Center
TSA Commercial Invoices
P. O. Xxx 0000
Xxxxxxxxxx, XX 00000-0000
c. The original signature document should be provided to the address listed in
para. b. above, with a copy to the Grants Officer and Program Manager.
d. Payments due for amounts properly invoiced or budgeted in accordance with the
terms and conditions specified elsewhere in the award shall be made by
electronic funds transfers to a financial institution designated by the
recipient. A completed SF-3881, "Payment Information Form - ACH Vendor Payment
System," shall be mailed to the address stated above in para. b.
E.4. Involvement Statement
One of the objectives of awarding a Cooperative Agreement for this
Proof-of-Concept effort is to allow the TSA to participate in the design and
development of the various project activities. This participation will take the
form of providing comments and input on test, experimentation, and evaluation
procedures before they are run. The purpose of input is to ensure that final
results are in concert with the TSA's overall strategy for the NexGen Checked
Baggage Program. With respect to this Cooperative Agreement, the main topics of
interest to the TSA include, but are not limited to, the following:
1)[*].
a) [*]
b) [*]
c) [*]
d) [*]
e) [*]
f) [*]
2) [*]
a) [*]
b) [*]
c) [*]
d) [*]
10
The TSA intends to provide input and comments on these items via one of the
following:
a. The Kick-Off Meeting. At, or near, the start of the Manhattan-II
Proof-of-Concept Cooperative Agreement performance period, the representative
from the Recipient and the TSA shall meet in a Kick-Off meeting. Typically, the
Kick-Off Meeting is the first event of a Cooperative Agreement and serves as the
first significant event. However, due to TSA personnel availability and travel
constraints, it is possible for the Kick-Off Meeting to be held via a telcon.
The TSA Program Manager will be responsible for making the determination which
type of meeting will be used for this Cooperative Agreement. The main objectives
of this meeting are to:
1) Allow the Key Participants from the TSA and the Recipient to meet
2) Review these Terms and Conditions
3) Establish both formal and informal reporting mechanisms
b. Monthly Status Reporting Teleconference. One of the objectives of this
Cooperative Agreement is to allow the TSA to participate in and influence the
result of the Proof-of-Concept activities. To support this, the Recipient shall
participate in a monthly status telcon with the TSA. A Monthly Status Telcon
shall be held within 10 working days of the delivery of the Monthly Status
Report. The purpose of the Monthly Status Telcon is to provide the TSA and the
Recipient with a means to discuss in detail the contents of the Monthly Status
Report. The format and content of the Month Status Telcon is defined in
Attachment C.
E.5. Project Extension
a. A request for change in the project period requires advance written approval
by the Grants Officer. The request must be submitted in writing, stating the
basis for the request, to the Grants Officer at least 30 calendar days prior to
the expiration of the award. The Recipient shall submit a revised budget
indicating the planned use of all unexpended funds during the extension period.
b. The Grants Officer will notify the Recipient in writing within 15 calendar
days after receipt of the request for revision or adjustment whether the request
has been approved.
E.6. Modification
The scope of work and terms and conditions of the award may be modified at any
time by mutual consent.
SECTION F - GENERAL PROVISIONS
Non-Federal Recipients of funds received under this award shall be subject to
the following OMB circulars as applicable. Circulars can be obtained directly
from the Internet at: xxx.xxxxxxxxxx.xxx/XXX, click on "Circulars".
11
F.1. Educational Institutions
a. OMB Circular A-21, Cost Principles for Educational Institutions;
b. OMB Circular A-110, Uniform Administrative Requirements for Grants and Other
Agreements with Institutions of Higher Education, Hospitals and Other Non-Profit
Organizations; and,
c. OMB Circular A-133, Audits of States, Local Governments and Non- Profit
Organizations.
F.2. State and Local Governments
a. OMB Circular A-87, Cost Principles for State, Local and Indian Tribal
Governments;
b. OMB Circular A-102, Grants and Cooperative Agreements with state and Local
Governments; and,
c. OMB Circular A-133, Audits of States, Local Governments and Non-Profit
Organizations.
F.3. Nonprofit Organizations
a. OMB Circular A-110, Uniform Administrative Requirements for Grants and other
Agreements with Institutions of Higher Education, Hospitals, and other
Non-Profit Organizations.
b. OMB Circular A-122, Cost Principles for Non-Profit Organizations; and
c. OMB Circular A-133, Audits of States, Local Governments and Non-Profit
Organizations.
F.4. Organizations for Profit
a. General administration requirements will be in accordance with the Federal
Acquisition Regulation Parts 29, 30 and 31.
F.5. Patents--Small Business and Non-profit Organizations
Subject to the provisions set forth in 37 CFR 401, 35 U.S.C. 203 and 00 X.X.X,
000, a recipient may retain the entire right, title, and interest throughout the
world to each subject invention. With respect to any subject invention in which
the recipient retains title, the federal government will have a nonexclusive,
nontransferable, irrevocable, paid-up license to practice or have practiced on
behalf of the United States the subject invention throughout the world.
12
F.6. Metric Conversion
All progress and final reports, other reports, or publications produced under
this award shall employ the metric system of measurements to the maximum extent
practicable. Both metric and inch-pound units (dual units) may be used if
necessary during any transition period(s). However, the recipient may use
nonmetric measurements to the extent the recipient has supporting documentation
that the use of metric measurements is impractical or is likely to cause
significant inefficiencies or loss of markets to the recipient, such as when
foreign competitors are producing competing product in non-metric.
F.7. Resource Conservation and Recovery Act (RCRA)
Any state agency or agency of a political subdivision of a State which is using
appropriated federal funds must comply with Section 6002 of RCRA, (P. L. 94-580
codified at 42 U.S.C 6962).
F.8. Anti-Lobbying
The Recipient shall not use any part of the Department of Homeland Security
provided hereunder for any activity or the publication or distribution of
literature that in any way tends to promote public support or opposition to any
legislative proposal on which Congressional action is not complete.
F.9. Release of Information
Recipient shall not publicize or otherwise circulate, promotional material (such
as advertisements, sales brochures, press releases, speeches, still and motion
pictures, articles, manuscripts or other publications) which states or implies
governmental, departmental, bureau, or government employee endorsement of a
product, service, or position which the recipient represents. No release of
information relating to this award may state or imply that the government
approves of the recipient's work products, or considers the recipient's work
product to be superior to other products or services. All information submitted
for publication or other public releases of information regarding this award
shall carry the following disclaimer:
"The views and conclusions contained in this document are those of the authors
and should not be interpreted as representing the opinions or policies of the
U.S. Government. Mention of trade names or commercial products does not
constitute their endorsement by the U.S. Government."
The recipient must obtain prior government approval for any public information
releases concerning this award which refer to the Department of Homeland
Security or any bureau or employee (by name or title). The specific text, layout
photographs, etc., of the proposed release must be submitted with the request
for approval.
13
The recipient further agrees to include this provision in a sub-award to any
sub-recipient, except for a sub-award to a state government, a local government,
or to a federally-recognized Indian tribal government.
F.10. Common Rule
49 Code of Regulations (CFR) Parts 17 - 21, 26, and 29, which cover
administrative requirements for federal financial assistance awards, are herein
incorporated by reference.
F.11. Seat Belt Provision
Recipients of grants/cooperative agreements and/or sub-awards are encouraged to
adopt and enforce on-the job seat belt use policies and programs for their
employees when operating company-owned, rented or personally owned vehicles.
These measures include, but are not limited to, conducting education, awareness,
and other appropriate programs for their employees about the importance of
wearing seat belts and the consequences of not wearing them.
SECTION G - SPECIAL TERMS AND CONDITIONS
G.1. Sensitive Security Information
a. Although records held by Federal agencies are subject to the Freedom of
Information Act (FOIA), information submitted by applicants under the Manhattan
II Project Cooperative Agreement will be considered "Sensitive Security
Information" for FOIA purposes. Information on the "Sensitive Security
Information" FOIA category is contained in 49 CFR Part 1520, published in the
Federal Register (67 FR 8340, dated February 22, 2002). Applications may also
contain "trade secret and commercial or financial information" which would not
be publicly released under Exemption 4.
b. Under 49 U.S.C. 40119 and 49 CFR Part 1520, sensitive security information is
not available for public inspection or copying, and information in these records
will not be released to the public. Information that may not be released may
include, but is not limited to, references to vulnerabilities, risk,
safeguards/mitigation (countermeasures), threats or any other information or
data referred to in 49 CFR 1520.
c. Applicants must place the following legend on their proposals and any
supporting information submitted under the Manhattan II Project Cooperative
Agreement which contains information of the type described above:
14
SENSITIVE SECURITY INFORMATION/FOR OFFICIAL USE ONLY
WARNING: THIS DOCUMENT CONTAINS SENSITIVE SECURITY INFORMATION THAT IS
CONTROLLED UNDER THE PROVISIONS OF 49 CFR PART 1520. NO PART OF THIS DOCUMENT
MAY BE RELEASED WITHOUT THE WRITTEN PERMISSION OF THE UNDER SECRETARY OF
TRANSPORTATION FOR SECURITY, XXXXXXXXXX, XX 00000. UNAUTHORIZED RELEASE MAY
RESULT IN CIVIL PENALTY OR OTHER ACTION. FOR U.S. GOVERNMENT AGENCIES, PUBLIC
AVAILABILTIY IS TO BE DETERMINED UNDER 5 U.S.C. 552.
d. Information identified as sensitive security information will be handled
according to procedures for handling sensitive but unclassified (SBU)
information, company proprietary information, including applications, or source
selection sensitive information.
G.2. Audits
a. Basic Requirements. All non-Federal entities that expend $300,000 or more of
federal funds in a year are required to obtain an annual audit in accordance
with the Single Audit Act Amendments of 1996 (Office of Management and Budget
(OMB) Circular A-133, "Audits of States, Local Governments and Non-Profit
Organizations," and OMB Circular A-133 Compliance Supplement and Government
Auditing Standards).
b. Submitting the audit reporting package and Data Collection Form (SF-SAC) to
the Federal Audit Clearinghouse (FAC) and pass-through entities. It is the
recipient's responsibility to submit the SF-SAC together with the appropriate
number (per SF-SAC instructions) of reporting packages to the FAC within 30 days
of the receipt of the auditor's reports, but no later than 9 months after the
end of the recipient's fiscal year. The FAC distributes the reporting package to
Federal agencies and maintains an archival copy. Information from the data
collection form is captured by the FAC in an electronic database, which is
publicly accessible via its web site.
G.3. Grants Officer
The Grants Officer (GO) is the sole individual authorized to modify the award
document including: terms and conditions, required delivery dates and
obligations of funds for the project.
G.4. Rights in Technical Data, Computer Data, and Software
(See Table in Attachment D)
The Recipient shall provide government purpose rights to existing technical
data, computer data, and software necessary for the Government to prepare a
performance specification for a competitive solicitation. This does not include
existing algorithms, source code, process, formulae, and flow charts of the
software.
The Recipient shall provide existing Technical Data, Computer Data, and Software
necessary to support installation, operation, maintenance and training purposes.
15
Government Purpose Rights, as used in this Cooperative Agreement shall mean the
rights to
i) use, modify, reproduce, release, perform, display, or disclose data,
computer software and computer software documentation within the
Government without restriction; and
ii) release or disclosure of computer software or computer software
documentation outside the Government and authorize persons to whom
release or disclosure has been made to use, modify, reproduce,
release, perform, display or disclose the software the software or
documentation for United States Government purposes.
iii) Government Purpose means any activity in which the United States
Government is a party, including Cooperative Agreements with
international or multi-national defense organizations or sales or
transfers by the United States Government to foreign governments or
international organizations. Government purposes include competitive
procurement, but do not include the rights to use, modify,
reproduce, release, perform, display, or disclose computer software
or computer software documentation for commercial purposes or
authorize others to do so.
Clauses regarding Rights in Technical Data, Computer Data, and Software are
included in full text in Attachment D to this Cooperative Agreement.
G.5. Intangible Property
a. The recipient may copyright any work that is subject to copyright and was
developed, or for which ownership was purchased, under an award. The federal
awarding agency reserves a royalty-free, nonexclusive and irrevocable right to
reproduce, publish, or otherwise use the work for Federal purposes, and to
authorize others to do so.
b. Recipients are subject to applicable regulations governing patents and
inventions, including government-wide regulations issued by the Department of
Commerce at 37 CFR Part 401, "Rights to Inventions Made by Nonprofit
Organizations and Small Business Firms Under Government Grants, Contracts and
Cooperative Agreements" (OMB Circular A-110).
G.6. Public Domain
All data, not subject to G.1. above, submitted to the TSA under this award will
become part of the public domain, and will be available in a non-proprietary
format, at the cost of reproduction, to any requesting organization or
individual.
16
G.7. Adherence to Original Project Objectives and Budget Estimates
a. Recipients shall not begin performance on the proposed project until receipt
of the completed official award document, signed by the Grants Officer.
Expenditures incurred prior to the effective date of an award cannot be charged
against award funds unless specifically authorized by the Grants Officer and
designated as pre-agreement costs in the award document. Any commitments or
expenditures incurred by the recipient in excess of the funds provided by an
award shall be the responsibility of the recipient.
b. Any proposed change, which requires the written approval of TSA, must be
submitted to the Grants Officer 30 days prior to the requested effective date of
the proposed change. No change to the award will be approved during the last 30
days of the award period
c. The following expenditures require advance written approval by the Grants
Officer and where applicable, shall require the submission of a revised
financial estimate and plan:
(i) Changes in the scope, objectives, or key personnel referenced in the
recipient's application;
(ii) Transfer of funds between direct costs categories when the cumulative
amount of transfers during the project period exceeds ten (10) percent of
the total award;
(iii) Acquisition of non-expendable property having a useful life of more
than two years and having an acquisition cost of $5,000 or more; and
(iv) Change in the project period. This request shall be received no later
than 30 calendar days prior to the end of the project period. The
recipient shall submit a revised budget indicating the planned use of all
unexpended funds during the extension period.
d. The Grants Officer will notify the recipient in writing within 30 calendar
days after receipt of the request for revision or adjustment whether the request
has been approved.
G.8. Violation of Award Terms
If a recipient has materially failed to comply with the terms of the award, the
Grants Officer may suspend, terminate, or take other measures as may be legally
available and appropriate under the circumstances.
G.9. Future TSA Awards
Future this awards between the TSA and the recipient depend upon the successful
completion of project activities and adherence to the Terms and Conditions of
previous awards.
17
G.10. Fly America
Fly America Requirement: Recipients of federal financial assistance funds are
required to comply with the provisions of the Fly America Act. The act requires
that foreign air travel funded with federal dollars be performed on U. S. flag
carriers. The Fly America Act was enacted under Section 5 of the International
Air Transportation Fair Competitive Practices Act of 1974 (P. L. 93-623), as
amended. The requirements of the Fly America Act are implemented in 41 Code of
Federal Regulations Part 301 (10.131-.143), which is part of the Federal Travel
Regulations as promulgated by the General Services Administration. Under current
regulations, the recipient will not be reimbursed for travelers who improperly
used a foreign air carrier and are not compliant with the Fly America Act.
Additionally, flyers should familiarize themselves with code share agreements
prior to scheduling flight reservations. There are general and specific
exceptions to the Fly America Act; however, they require a waiver. When
requesting use of a foreign air carrier, the recipient will need to provide the
Grants Officer with the proper certification stating the reason why they must be
used.
G.11 Property Acquired By The Recipient
The Government reserves the right to take title to any equipment, software, or
documentation acquired by the Recipient under this Cooperative Agreement at the
conclusion of performance.
G.12 Order of Precedence
Any inconsistency in this Cooperative Agreement shall be resolved by giv9ng
precedence in the following order:
a) Sections A, B, D, E, F, and G
b) Attachments C and D
c) Attachments A and B
d) Contractor Proposals identified in Sections C and H
SECTION H - DOCUMENTS INCORPORATED BY REFERENCE
The Recipient's Proposals dated 28 May 2004 and 24 August 2004.
18
SECTION I - ATTACHMENTS
Attachment Title
---------- -----
A SF 269A, "Financial Status Report (short form)"
B SF 3881, "ACH Vendor/Miscellaneous Payment Enrollment
Form"
C Manhattan-II Data Item Descriptions (DIDs)
D Articles
Note: Attachments A and B are incorporated by reference.
19
Attachment C
Data Item Descriptions
(DIDs)
20
--------------------------------------------------------------------------------
DATA ITEM DESCRIPTION
--------------------------------------------------------------------------------
1. TITLE 2. NUMBER
Master Project Schedule Chked-Bag-001
--------------------------------------------------------------------------------
3. DESCRIPTION/PURPOSE
The Master Project Schedule shall present the Recipient's schedule for
performing all major Proof-of-Concept activities. The Master Project Schedule
shall be implemented using MS Project, Version 2000 or later.
--------------------------------------------------------------------------------
4. DATA REQUIREMENTS
Contents:
The Master Program Schedule shall include all major Manhattan-II
Proof-of-Concept Cooperative Agreement activities. The approved schedule will be
maintained on tabular reports/listings, milestone charts, and logic networks for
comparison with the current planning/performance dates. After the TSA approves
schedule changes, these changes shall be updated in the next monthly delivery.
Schedules shall be consistent with the EVMS schedules. The Master Project
Schedule shall be delivered as a soft copy file in a Microsoft Project
compatible format. The Master Project Schedule shall include the following:
a) Summary Schedule. This schedule shall be a summary of all intermediate
schedules.
b) Intermediate Schedule. These schedules shall provide major milestones and
events consistent with the Contractor's transition approach. Schedules
shall include the following:
1) For each event or milestone, the baseline start and completion
dates; the current expected start and completion dates; the number
of work days required to complete the task; the amount of float or
slack in work days; and a description of the event.
2) The critical path will be derived from the intermediate schedules.
c) Detail Schedule. These schedules shall support the intermediate schedules
and will provide a summary schedule for all activities and milestones.
1) The detail schedules shall be verified against the intermediate
schedules at regular intervals to ensure full consistency.
d) Schedule Content:
1) Relationships between and among events and milestones
2) Time duration of all phases and tasks
3) Planned start and completion dates for events and milestones
4) Scheduled stack and float
5) Actual start and complete dates for all events and tasks.
6) Resource usage of Recipient resources. This shall include, at a
minimum, resource usage of Recipient personnel and their associated
rates.
7) Identify required TSA Resources. This shall include, at a minimum,
personnel, equipment, and lab space/time.
--------------------------------------------------------------------------------
21
--------------------------------------------------------------------------------
DATA ITEM DESCRIPTION
--------------------------------------------------------------------------------
1. TITLE 2. NUMBER
Monthly Status Report Chked-Bag-002
--------------------------------------------------------------------------------
3. DESCRIPTION/PURPOSE
The Monthly Status Report shall provide the accomplishments within the reporting
period, schedule changes, issues, concerns and action items. The Recipient shall
submit a Monthly Status Report to the TSA within 5 working days of the end of
each calendar month for the duration of the project.
--------------------------------------------------------------------------------
22
--------------------------------------------------------------------------------
4. DATA REQUIREMENTS
Contents:
The Monthly Status Report shall contain the following, at a minimum:
a) Accomplishments: Describe the accomplishments during the last reporting
period, including the current status of major events and milestones. The
report shall compare the status of the current month with the prior
month's projections. The report shall discuss any problems associated with
each milestone as well as their resolutions.
b) Upcoming Activities: The report shall include discussion of the upcoming
activities. This discussion shall include, as a minimum, the following:
1) A Summary Description of the significant activities that are
expected to take place in the next 30-days.
2) A Detail Technical Discussion of the activities listed in the
Summary description. The purpose of this discussion is to provide a
sufficient level of understanding of the purpose, plans, objective,
procedures, parameters, and characteristics of the upcoming
activities to allow the TSA to comment on and provide input to these
activities. This detailed discussion shall be included as an
attachment to the Monthly Report.
c) Schedule The report shall provide the overall MANHATTAN-II
Proof-Of-Concept Cooperative Agreement key milestone dates and their
status. If there are schedule delays, discuss the impact, risks, and risk
mitigation actions planned or taken. The Monthly Report shall include
copies of the project schedule in both hardcopy and electronic format to
the TSA.
d) Issues and Concerns. Each issue or concern shall be identified and
discussed separately. For each issue or concern identified, the report
shall provide a description of the issue or concern, an assessment of the
criticality and time sensitivity of the issue or concern, and actions
planned to address them. For each action plan proposed, the report shall
indicate involvement by the Government or subcontractors.
e) Action Items. The report shall include the status of all formally assigned
action items since the start of the project. The status will indicate
actions as open or closed. If open, the status shall contain the actions
necessary to close the Action item and the planned date. If closed, the
status shall briefly describe the action taken and date closed. Action
items remaining open between reporting periods will be reported.
f) Cost. The report shall include the following cost related data items:
1) For the reporting period - the Total Expected Cost and the Total
Actual Cost.
2) For the project spending to date - the Total Expected Cost and the
Total Actual Cost.
3) A chart summarizing the expected vs. actual cost, on a monthly
basis, since the start of the project.
g) Earned Value Management Report. The Earned Value Management Report is
prepared by the Recipient, using MS Project, and provides summarized cost
and schedule status of Recipient's activities on the Proof-of-Concept
Cooperative Agreement.
--------------------------------------------------------------------------------
23
--------------------------------------------------------------------------------
DATA ITEM DESCRIPTION
--------------------------------------------------------------------------------
1. TITLE 2. NUMBER
Monthly Status Teleconference Agenda, Chked-Bag-003
Minutes, Action Items
--------------------------------------------------------------------------------
3. DESCRIPTION/PURPOSE
The Monthly Status Teleconference (telcon) shall review the items presented in
the Monthly Status Report. The purpose of these telecons is to provide a forum
in which the TSA and the Recipient can discuss technical and managerial status
of the project. The Monthly Status Telcon Minutes shall provide documentation of
technical information provided, decisions, and agreements reached. The Action
Items resulting from the telcon shall be tracked and managed by the Recipient
using an Action Item Database.
--------------------------------------------------------------------------------
4. DATA REQUIREMENTS
Contents:
a) Telcon agenda. The agenda shall be provided along with the Monthly Status
Report and will include as a minimum the following, where applicable:
1) The purpose and objective of the Telcon.
2) The date/time and Telephony number(s) to be used (and meeting
location if needed)
3) A chronological listing of each major topic or subtopic to be
discussed and the time to be devoted to each.
4) A list of the current open action items.
b) Telcon minutes. The minutes shall be delivered within 10 days after the
meeting and include at least the following information:
1) Type of meeting, date and location.
2) A list of attendees with name, organization, telephone number, email
and facsimile number.
3) Summary of discussion, decisions, agreements reached, and directions
of the meeting or individual subcommittees.
c) Action Items - The information associated with the action items generated
as a result of the project tasks and activities include, as a minimum, the
following items:
1. Date the Action was generated
2. The name(s) of the person(s) assigned to complete the action
3. A brief description of the action
4. The required completion date
5. The status of the work completed to close the action. This item
should allow for multiple entries as there can be more than one
assignee reporting status, and the completion of an action item may
be iterative in nature.
--------------------------------------------------------------------------------
24
--------------------------------------------------------------------------------
DATA ITEM DESCRIPTION
--------------------------------------------------------------------------------
1. TITLE 2. NUMBER End of Stage
Results Presentation
Chked-Bag-004
--------------------------------------------------------------------------------
3. DESCRIPTION/PURPOSE
An End of Stage Results Presentation shall be presented to the TSA Manhattan-II
Project Management Team at the end of each of the two stages of the Manhattan-II
Proof-of-Concept Corporative agreement. Each End of Stage Results Presentation
shall present and document the technical results/finding, status, issues, and
open actions for that stage.
--------------------------------------------------------------------------------
25
--------------------------------------------------------------------------------
4. DATA REQUIREMENTS
Contents:
a) Location and duration. The End of Stage Results Presentation shall be
conducted at a location designated by the TSA at a mutually agreed upon
time and shall not exceed 2 hours.
b) Documentation: Documentation and briefing slides shall be provided for all
review participants.
c) Participants. The contractor's Manhattan-II Proof-Of-Concept Cooperative
Agreement project technical staff and management will participate in the
review to present the current status of the Manhattan-II Proof-Of-Concept
Cooperative Agreement project activities.
d) Agenda. The presentation shall include all aspects of the Manhattan-II
Proof-Of-Concept Cooperative Agreement project for the stage of interest.
The Recipient shall provide an agenda to the TSA 5 days prior to the
scheduled date for the Stage Results Presentation. The following items
shall be presented as a minimum:
1) A one page high-level synopsis of the results of the stage of
interest that summarizes items 2, 3, and 7.
2) Major program milestone and event status.
3) The Technical Findings or Results of the stage, include a
description of the findings to date of the proposed technology as it
would be used. This description shall include, at a minimum, a
technical discussion of: (Note, it is anticipated that this will
make up the bulk of the presentation)
a. The technical capabilities as well as the detection and/or
discrimination capabilities of the proposed concept or
technology.
b. Potential improvements to current aviation baggage screening
systems and operations that will improve security or reduce
cost by such measures as improving throughput, reducing the
false alarm rate, facilitating alarm resolution, improved
maintainability and reliability, and/or increased automation.
c. Potential impacts, positive and negative, to the current
aviation baggage screening environment.
d. Potential technical and operational risks of the proposed
concept or technology. 4) Updated Proof-of-Concept Schedule -
Show the status of the Vendor's planned tasks and milestones
and indicate percentage(s) complete, significant Recipient
tasks and milestones achieved, tasks in-progress, and planned
tasks or milestones not completed. The End of Stage Report
shall include copies of the project schedule in both hardcopy
and electronic format to the TSA.
5) Updated Risk Assessment - Updates to the identified risks, any newly
identified risks, and an updated mitigation plan.
6) Issues/Concerns - Include a list of any potential problems and/or
issues that may impact cost, schedule, and the risk assessment.
7) Program financial status - A description of the financial standing
of the project, which shall include, as a minimum:
a. Cost. The report will include the following cost related data
items:
1) For the reporting period - the Total Expected Cost and
the Total Actual Cost.
2) A chart summarizing the expected vs. actual cost, on a
monthly basis, since the start of the project.
b. Earned Value Management Report. The Earned Value Management
Report is prepared by the Recipient, using MS Project, and
provides summarized cost and schedule status of the
Recipient's activities on the Proof-of-Concept Cooperative
Agreement.
8) For the Stage 1 Results Presentation, a schedule of major activities
and events for the next quarter.
e) Minutes. The Recipient shall provide minutes of the Stage Results
Presentation. The minutes shall be delivered within 10 days after the
Presentation and shall include:
1) Meeting date and location.
2) A list of attendees with name, organization, telephone number, and
facsimile number.
3) Summary of discussions, decisions, agreements reached, and
directions of the meeting or individual subcommittees.
4) Updated Action Item Report containing the results of the meeting.
--------------------------------------------------------------------------------
26
--------------------------------------------------------------------------------
DATA ITEM DESCRIPTION
--------------------------------------------------------------------------------
1. TITLE 2. NUMBER
Meeting Agenda, Minutes, and Action Items Chked-Bag-005
--------------------------------------------------------------------------------
3. DESCRIPTION/PURPOSE
The Meeting Agenda shall provide information concerning purpose, location, and
schedule of conferences, meetings, reviews, audits, and evaluations required to
manage the acquisition of Manhattan-II Proof-Of-Concept Cooperative Agreement.
The Meeting Minutes shall provide documentation of technical information
provided, decisions, and agreements reached at conferences, meetings, reviews,
audits, and evaluations. The Action Items resulting from the various meetings
and teleconferences that take place during the life of the project shall be
tracked and managed by the Recipient using an Action Item Database.
--------------------------------------------------------------------------------
4. DATA REQUIREMENTS
Contents:
d) Meeting Agenda. The Agenda shall be provided 5 days prior to the scheduled
date of the meeting and include as a minimum the following, where
applicable:
5) The purpose and objective of the meeting.
6) The meeting location, date, and location.
7) A chronological listing of each major topic or subtopic to be
discussed and the time to be devoted to each.
8) A list of the current open action items.
e) Meeting minutes. The minutes shall be delivered within 10 days after the
meeting and include at least the following information:
4) Type of meeting, date and location.
5) A list of attendees with name, organization, telephone number, email
and facsimile number.
6) Summary of discussion, decisions, agreements reached, and directions
of the meeting or individual subcommittees.
f) Action Items - The information associated with the action items generated
as a result of the project tasks and activities shall include, as a
minimum, the following items:
6. Date the Action was generated
7. The name(s) of the person(s) assigned to complete the action
8. A brief description of the action
9. The required completion date
10. The status of the work completed to close the action. This item
should allow for multiple entries as there can be more than one
assignee reporting status, and the completion of an action item may
be iterative in nature.
--------------------------------------------------------------------------------
27
ATTACHMENT D - ARTICLES
3.3.2-1 TSA Cost Principles (February 2003)
(a) Transportation Security Administration (TSA) "Contracting Cost Principles"
shall be used for:
(1) The pricing of contracts, subcontracts, and modifications to contracts
and subcontracts whenever cost analysis is performed; and
(2) the determination, negotiation, or allowance of cost when required by
a contract clause.
(b) TSA Cost Principles are incorporated by reference in this contract as the
basis for:
(1) Determining reimbursable costs under:
(i) Cost-reimbursement contracts and cost-reimbursement subcontracts
under these contracts preformed by commercial organizations, and
(ii) The cost-reimbursement portion of time-and -materials contracts
except when material is priced on a basis other than at cost;
(2) Negotiating indirect cost rates, when:
(i) TSA has division or corporate contract administration
responsibilities;
(ii) Quick Close-out procedures are used; or
(iii) Indirect rate caps are negotiated in the contract.
(3) Proposing, negotiating, or determining costs under terminated
contracts;
(4) Price revision of fixed-price incentive contracts;
(5) Price redetermination of price redetermination contracts; and
(6) Pricing changes and other contract modifications.
(c) When contract administration responsibilities rest with another Government
agency, the TSA will apply the cost principles of the administering agency for
the determination or negotiation of indirect rates not covered by (2)(ii) or
(2)(iii) above.
(d) Upon request, the Contracting Officer will provide a copy of the TSA
"Contract Cost Principles." Until TSA develops its own Contract Cost Principles,
TSA will adopt FAA's Contract Cost Principles, available at:
xxxx://xxxx.xxx.xxx/xxxxxxxxxxx-xxxxx/xxxx/0-0-0.xxx.
(End of Clause)
28
RIGHTS IN TECHNICAL DATA--NONCOMMERCIAL ITEMS
(a) Definitions. As used in this clause:
(1) "Computer data base" means a collection of data recorded in a form
capable of being processed by a computer. The term does not include
computer software.
(2) "Computer program" means a set of instructions, rules, or routines
recorded in a form that is capable of causing a computer to perform a
specific operation or series of operations.
(3) "Computer software" means computer programs, source code, source code
listings, object code listings, design details, algorithms, processes,
flow charts, formulae and related material that would enable the software
to be reproduced, recreated, or recompiled. Computer software does not
include computer data bases or computer software documentation.
(4) "Computer software documentation" means owner's manuals, user's
manuals, installation instructions, operating instructions, and other
similar items, regardless of storage medium, that explain the capabilities
of the computer software or provide instructions for using the software.
(5) "Detailed manufacturing or process data" means technical data that
describe the steps, sequences, and conditions of manufacturing, processing
or assembly used by the manufacturer to produce an item or component or to
perform a process.
(6) "Developed" means that an item, component, or process exists and is
workable. Thus, the item or component must have been constructed or the
process practiced. Workability is generally established when the item,
component, or process has been analyzed or tested sufficiently to
demonstrate to reasonable people skilled in the applicable art that there
is a high probability that it will operate as intended. Whether, how much,
and what type of analysis or testing is required to establish workability
depends on the nature of the item, component, or process, and the state of
the art. To be considered "developed," the item, component, or process
need not be at the stage where it could be offered for sale or sold on the
commercial market, nor must the item, component, or process be actually
reduced to practice within the meaning of Title 35 of the United States
Code.
(7) "Developed exclusively at private expense" means development was
accomplished entirely with costs charged to indirect cost pools, costs not
allocated to a government contract, or any combination thereof.
(i) Private expense determinations should be made at the lowest
practicable level.
(ii) Under fixed-price contracts, when total costs are greater than
the firm-fixed-price or ceiling price of the contract, the
additional development costs necessary to complete development shall
not be considered when determining whether development was at
government, private, or mixed expense.
29
(8) "Developed exclusively with government funds" means development was
not accomplished exclusively or partially at private expense.
(9) "Developed with mixed funding" means development was accomplished
partially with costs charged to indirect cost pools and/or costs not
allocated to a government contract, and partially with costs charged
directly to a government contract.
(10) "Form, fit, and function data" means technical data that describes
the required overall physical, functional, and performance characteristics
(along with the qualification requirements, if applicable) of an item,
component, or process to the extent necessary to permit identification of
physically and functionally interchangeable items.
(11) "Government purpose" means any activity in which the United States
Government is a party, including cooperative agreements with international
or multi-national defense organizations, or sales or transfers by the
United States Government to foreign governments or international
organizations. Government purposes include competitive procurement, but do
not include the rights to use, modify, reproduce, release, perform,
display, or disclose technical data for commercial purposes or authorize
others to do so.
(12) "Government purpose rights" means the rights to-
(i) Use, modify, reproduce, release, perform, display, or disclose
technical data within the Government without restriction; and
(ii) Release or disclose technical data outside the Government and
authorize persons to whom release or disclosure has been made to
use, modify, reproduce, release, perform, display, or disclose that
data for United States government purposes.
(13) "Limited rights" means the rights to use, modify, reproduce, release,
perform, display, or disclose technical data, in whole or in part, within
the Government. The Government may not, without the written permission of
the party asserting limited rights, release or disclose the technical data
outside the Government, use the technical data for manufacture, or
authorize the technical data to be used by another party, except that the
Government may reproduce, release or disclose such data or authorize the
use or reproduction of the data by persons outside the Government if
reproduction, release, disclosure, or use is-
(i) Necessary for emergency repair and overhaul; or
(ii) A release or disclosure of technical data (other than detailed
manufacturing or process data) to, or use of such data by, a foreign
government that is in the interest of the Government and is required
for evaluational or informational purposes;
30
(iii) Subject to a prohibition on the further reproduction, release,
disclosure, or use of the technical data; and
(iv) The contractor or subcontractor asserting the restriction is
notified of such reproduction, release, disclosure, or use.
(14) "Technical data" means recorded information, regardless of the form
or method of the recording, of a scientific or technical nature (including
computer software documentation). The term does not include computer
software or data incidental to contract administration, such as financial
and/or management information.
(15) "Unlimited rights" means rights to use, modify, reproduce, perform,
display, release, or disclose technical data in whole or in part, in any
manner, and for any purpose whatsoever, and to have or authorize others to
do so.
(b) Rights in technical data. The Contractor grants or shall obtain for the
Government the following royalty free, world-wide, nonexclusive, irrevocable
license rights in technical data other than computer software documentation (see
the Rights in Noncommercial Computer Software and Noncommercial Computer
Software Documentation clause of this contract for rights in computer software
documentation):
(1) Unlimited rights. The Government shall have unlimited rights in
technical data that are-
(i) Data pertaining to an item, component, or process which has been
or will be developed exclusively with Government funds;
(ii) Studies, analyses, test data, or similar data produced for this
contract, when the study, analysis, test, or similar work was
specified as an element of performance;
(iii) Created exclusively with Government funds in the performance
of a contract that does not require the development, manufacture,
construction, or production of items, components, or processes;
(iv) Form, fit, and function data;
(v) Necessary for installation, operation, maintenance, or training
purposes (other than detailed manufacturing or process data);
(vi) Corrections or changes to technical data furnished to the
Contractor by the Government;
(vii) Otherwise publicly available or have been released or
disclosed by the Contractor or subcontractor without restrictions on
further use, release or disclosure, other than a release or
disclosure resulting from the sale, transfer, or other assignment of
interest in the technical data to another party or the sale or
transfer of some or all of a business entity or its assets to
another party;
31
(viii) Data in which the Government has obtained unlimited rights
under another Government contract or as a result of negotiations; or
(ix) Data furnished to the Government, under this or any other
Government contract or subcontract hereunder, with-
(A) Government purpose license rights or limited rights and
the restrictive condition(s) has/have expired; or
(B) Government purpose rights and the Contractor's exclusive
right to use such data for commercial purposes has expired.
(2) Government purpose rights.
(i) The Government shall have government purpose rights for a
five-year period, or such other period as may be negotiated, in
technical data-
(A) That pertain to items, components, or processes developed
with mixed funding except when the Government is entitled to
unlimited rights in such data as provided in paragraphs
(b)(ii) and (b)(iv) through (b)(ix) of this clause; or
(B) Created with mixed funding in the performance of a
contract that does not require the development, manufacture,
construction, or production of items, components, or
processes.
(ii) The five-year period, or such other period as may have been
negotiated, shall commence upon execution of the contract,
subcontract, letter contract (or similar contractual instrument),
contract modification, or option exercise that required development
of the items, components, or processes or creation of the data
described in paragraph (b)(2)(i)(B) of this clause. Upon expiration
of the five-year or other negotiated period, the Government shall
have unlimited rights in the technical data.
(iii) The Government shall not release or disclose technical data in
which it has government purpose rights unless-
(A) Prior to release or disclosure, the intended recipient is
subject to a non-disclosure agreement or;
(B) The recipient is a Government contractor receiving access
to the data for performance of a Government contract that
contains the clause entitled "Limitations on the Use or
Disclosure of Government-Furnished Information Marked with
Restrictive Legends".
32
(iv) The Contractor has the exclusive right, including the right to
license others, to use technical data in which the Government has
obtained government purpose rights under this contract for any
commercial purpose during the time period specified in the
government purpose rights legend prescribed in paragraph (f)(2) of
this clause.
(3) Limited rights.
(i) Except as provided in paragraphs (b)(1)(ii) and (b)(1)(iv)
through (b)(1)(ix) of this clause, the Government shall have limited
rights in technical data-
(A) Pertaining to items, components, or processes developed
exclusively at private expense and marked with the limited
rights legend prescribed in paragraph (f) of this clause; or
(B) Created exclusively at private expense in the performance
of a contract that does not require the development,
manufacture, construction, or production of items, components,
or processes.
(ii) The Government shall require a recipient of limited rights data
for emergency repair or overhaul to destroy the data and all copies
in its possession promptly following completion of the emergency
repair/overhaul and to notify the Contractor that the data have been
destroyed.
(iii) The Contractor, its subcontractors, and suppliers are not
required to provide the Government additional rights to use, modify,
reproduce, release, perform, display, or disclose technical data
furnished to the Government with limited rights. However, if the
Government desires to obtain additional rights in technical data in
which it has limited rights, the Contractor agrees to promptly enter
into negotiations with the Contracting Officer to determine whether
there are acceptable terms for transferring such rights. All
technical data in which the Contractor has granted the Government
additional rights shall be listed or described in a license
agreement made part of the contract. The license shall enumerate the
additional rights granted the Government in such data.
(4) Specifically negotiated license rights. The standard license rights
granted to the Government under paragraphs (b)(1) through (b)(3) of this
clause, including the period during which the Government shall have
government purpose rights in technical data, may be modified by mutual
agreement to provide such rights as the parties consider appropriate but
shall not provide the Government lesser rights than are enumerated in
paragraph (a)(13) of this clause. Any rights so negotiated shall be
identified in a license agreement made part of this contract.
33
(5) Prior government rights. Technical data that will be delivered,
furnished, or otherwise provided to the Government under this contract, in
which the Government has previously obtained rights shall be delivered,
furnished, or provided with the pre-existing rights, unless-
(i) The parties have agreed otherwise; or
(ii) Any restrictions on the Government's rights to use, modify,
reproduce, release, perform, display, or disclose the data have
expired or no longer apply.
(6) Release from liability. The Contractor agrees to release the
Government from liability for any release or disclosure of technical data
made in accordance with paragraph (a)(13) or (b)(2)(iii) of this clause,
in accordance with the terms of a license negotiated under paragraph
(b)(4) of this clause, or by others to whom the recipient has released or
disclosed the data and to seek relief solely from the party who has
improperly used, modified, reproduced, released, performed, displayed, or
disclosed Contractor data marked with restrictive legends.
(c) Contractor rights in technical data. All rights not granted to the
Government are retained by the Contractor.
(d) Third party copyrighted data. The Contractor shall not, without the written
approval of the Contracting Officer, incorporate any copyrighted data in the
technical data to be delivered under this contract unless the Contractor is the
copyright owner or has obtained for the Government the license rights necessary
to perfect a license or licenses in the deliverable data of the appropriate
scope set forth in paragraph (b) of this clause, and has affixed a statement of
the license or licenses obtained on behalf of the Government and other persons
to the data transmittal document.
(e) Identification and delivery of data to be furnished with restrictions on
use, release, or disclosure.
(1) This paragraph does not apply to restrictions based solely on
copyright.
(2) Except as provided in paragraph (e)(3) of this clause, technical data
that the Contractor asserts should be furnished to the Government with
restrictions on use, release, or disclosure are identified in an
attachment to this contract (the Attachment). The Contractor shall not
deliver any data with restrictive markings unless the data are listed on
the Attachment.
(3) In addition to the assertions made in the Attachment, other assertions
may be identified after award when based on new information or inadvertent
omissions unless the inadvertent omissions would have materially affected
the source selection decision. Such identification and assertion shall be
submitted to the Contracting Officer as soon as practicable prior to the
scheduled date for delivery of the data, in the following format, and
signed by an official authorized to contractually obligate the Contractor:
34
Identification and Assertion of Restrictions on the Government's Use, Release,
or Disclosure of Technical Data.
The Contractor asserts for itself, or the persons identified below, that
the Government's rights to use, release, or disclose the following
technical data should be restricted-
Technical Data Name of Person
to be Furnished Basis for Asserted Rights Asserting
With Restrictions* Assertion** Category*** Restrictions****
(LIST) (LIST) (LIST) (LIST)
*If the assertion is applicable to items, components, or processes
developed at private expense, identify both the data and each such
item, component, or process.
**Generally, the development of an item, component, or process at
private expense, either exclusively or partially, is the only basis
for asserting restrictions on the Government's rights to use,
release, or disclose technical data pertaining to such items,
components, or processes. Indicate whether development was
exclusively or partially at private expense. If development was not
at private expense, enter the specific reason for asserting that the
Government's rights should be restricted.
***Enter asserted rights category (e.g., government purpose license
rights from a prior contract, rights in SBIR data generated under
another contract, limited or government purpose rights under this or
a prior contract, or specifically negotiated licenses).
****Corporation, individual, or other person, as appropriate.
Date _________________________________
Printed Name and Title _________________________________
_________________________________
Signature _________________________________
(End of identification and assertion)
35
(4) When requested by the Contracting Officer, the Contractor shall
provide sufficient information to enable the Contracting Officer to
evaluate the Contractor's assertions. The Contracting Officer reserves the
right to add the Contractor's assertions to the Attachment and validate
any listed assertion, at a later date, in accordance with the procedures
of the Validation of Restrictive Markings on Technical Data clause of this
contract.
(f) Marking requirements. The Contractor, and its subcontractors or suppliers,
may only assert restrictions on the Government's rights to use, modify,
reproduce, release, perform, display, or disclose technical data to be delivered
under this contract by marking the deliverable data subject to restriction.
Except as provided in paragraph (f)(5) of this clause, only the following
legends are authorized under this contract: the government purpose rights legend
at paragraph (f)(2) of this clause; the limited rights legend at paragraph
(f)(3) of this clause; or the special license rights legend at paragraph (f)(4)
of this clause; and/or a notice of copyright as prescribed under 17 U.S.C. 401
or 402.
(1) General marking instructions. The Contractor, or its subcontractors or
suppliers, shall conspicuously and legibly xxxx the appropriate legend on
all technical data that qualify for such markings. The authorized legends
shall be placed on the transmittal document or storage container and, for
printed material, each page of the printed material containing technical
data for which restrictions are asserted. When only portions of a page of
printed material are subject to the asserted restrictions, such portions
shall be identified by circling, underscoring, with a note, or other
appropriate identifier. Technical data transmitted directly from one
computer or computer terminal to another shall contain a notice of
asserted restrictions. Reproductions of technical data or any portions
thereof subject to asserted restrictions shall also reproduce the asserted
restrictions.
(2) Government purpose rights markings. Data delivered or otherwise
furnished to the Government with government purpose rights shall be marked
as follows:
GOVERNMENT PURPOSE RIGHTS
Contract No.
Contractor Name
Contractor Address
Expiration Date
The Government's rights to use, modify, reproduce, release, perform,
display, or disclose these technical data are restricted by paragraph
(b)(2) of the Rights in Technical Data-Noncommercial Items clause
contained in the above identified contract. No restrictions apply after
the expiration date shown above. Any reproduction of technical data or
portions thereof marked with this legend must also reproduce the markings.
(End of legend)
36
(3) Limited rights markings. Data delivered or otherwise furnished to the
Government with limited rights shall be marked with the following legend:
LIMITED RIGHTS
Contract No.
Contractor Name
Contractor Address
The Government's rights to use, modify, reproduce, release, perform,
display, or disclose these technical data are restricted by paragraph
(b)(3) of the Rights in Technical Data--Noncommercial Items clause
contained in the above identified contract. Any reproduction of technical
data or portions thereof marked with this legend must also reproduce the
markings. Any person, other than the Government, who has been provided
access to such data must promptly notify the above named Contractor.
(End of legend)
(4) Special license rights markings.
(i) Data in which the Government's rights stem from a specifically
negotiated license shall be marked with the following legend:
SPECIAL LICENSE RIGHTS
The Government's rights to use, modify, reproduce, release, perform,
display, or disclose these data are restricted by Contract No.
_____(Insert contract number)____, License No. ____(Insert license
identifier)____. Any reproduction of technical data or portions
thereof marked with this legend must also reproduce the markings.
(End of legend)
37
(ii) For purposes of this clause, special licenses do not include
government purpose license rights acquired under a prior contract
(see paragraph (b)(5) of this clause).
(5) Pre-existing data markings. If the terms of a prior contract or
license permitted the Contractor to restrict the Government's rights to
use, modify, reproduce, release, perform, display, or disclose technical
data deliverable under this contract, and those restrictions are still
applicable, the Contractor may xxxx such data with the appropriate
restrictive legend for which the data qualified under the prior contract
or license. The marking procedures in paragraph (f)(1) of this clause
shall be followed.
(g) Contractor procedures and records. Throughout performance of this contract,
the Contractor and its subcontractors or suppliers that will deliver technical
data with other than unlimited rights, shall-
(1) Have, maintain, and follow written procedures sufficient to assure
that restrictive markings are used only when authorized by the terms of
this clause; and
(2) Maintain records sufficient to justify the validity of any restrictive
markings on technical data delivered under this contract.
(h) Removal of unjustified and nonconforming markings.
(1) Unjustified technical data markings. The rights and obligations of the
parties regarding the validation of restrictive markings on technical data
furnished or to be furnished under this contract are contained in the
Validation of Restrictive Markings on Technical Data clause of this
contract. Notwithstanding any provision of this contract concerning
inspection and acceptance, the Government may ignore or, at the
Contractor's expense, correct or strike a marking if, in accordance with
the procedures in the Validation of Restrictive Markings on Technical Data
clause of this contract, a restrictive marking is determined to be
unjustified.
(2) Nonconforming technical data markings. A nonconforming marking is a
marking placed on technical data delivered or otherwise furnished to the
Government under this contract that is not in the format authorized by
this contract. Correction of nonconforming markings is not subject to the
Validation of Restrictive Markings on Technical Data clause of this
contract. If the Contracting Officer notifies the Contractor of a
nonconforming marking and the Contractor fails to remove or correct such
marking within sixty (60) days, the Government may ignore or, at the
Contractor's expense, remove or correct any nonconforming marking.
(i) Relation to patents. Nothing contained in this clause shall imply a license
to the Government under any patent or be construed as affecting the scope of any
license or other right otherwise granted to the Government under any patent.
(j) Limitation on charges for rights in technical data.
38
(1) The Contractor shall not charge to this contract any cost, including,
but not limited to, license fees, royalties, or similar charges, for
rights in technical data to be delivered under this contract when-
(i) The Government has acquired, by any means, the same or greater
rights in the data; or
(ii) The data are available to the public without restrictions.
(2) The limitation in paragraph (j)(1) of this clause-
(i) Includes costs charged by a subcontractor or supplier, at any
tier, or costs incurred by the Contractor to acquire rights in
subcontractor or supplier technical data, if the subcontractor or
supplier has been paid for such rights under any other Government
contract or under a license conveying the rights to the Government;
and
(ii) Does not include the reasonable costs of reproducing, handling,
or mailing the documents or other media in which the technical data
will be delivered.
(k) Applicability to subcontractors or suppliers.
(1) The Contractor shall ensure that the rights afforded its
subcontractors and suppliers under 10 U.S.C. 2320, 10 U.S.C. 2321, and the
identification, assertion, and delivery processes of paragraph (e) of this
clause are recognized and protected.
(2) Whenever any technical data for noncommercial items is to be obtained
from a subcontractor or supplier for delivery to the Government under this
contract, the Contractor shall use this same clause in the subcontract or
other contractual instrument, and require its subcontractors or suppliers
to do so, without alteration, except to identify the parties. No other
clause shall be used to enlarge or diminish the Government's, the
Contractor's, or a higher-tier subcontractor's or supplier's rights in a
subcontractor's or supplier's technical data.
(3) Technical data required to be delivered by a subcontractor or supplier
shall normally be delivered to the next higher-tier contractor,
subcontractor, or supplier. However, when there is a requirement in the
prime contract for data which may be submitted with other than unlimited
rights by a subcontractor or supplier, then said subcontractor or supplier
may fulfill its requirement by submitting such data directly to the
Government, rather than through a higher-tier contractor, subcontractor,
or supplier.
(4) The Contractor and higher-tier subcontractors or suppliers shall not
use their power to award contracts as economic leverage to obtain rights
in technical data from their subcontractors or suppliers.
(5) In no event shall the Contractor use its obligation to recognize and
protect subcontractor or supplier rights in technical data as an excuse
for failing to satisfy its contractual obligation to the Government.
(End of clause)
39
RIGHTS IN NONCOMMERCIAL COMPUTER SOFTWARE AND NONCOMMERCIAL
COMPUTER SOFTWARE DOCUMENTATION
(a) Definitions. As used in this clause:
(1) "Commercial computer software" means software developed or regularly
used for non-governmental purposes which-
(i) Has been sold, leased, or licensed to the public;
(ii) Has been offered for sale, lease, or license to the public;
(iii) Has not been offered, sold, leased, or licensed to the public
but will be available for commercial sale, lease, or license in time
to satisfy the delivery requirements of this contract; or
(iv) Satisfies a criterion expressed in paragraph (a)(1)(i), (ii),
or (iii) of this clause and would require only minor modification to
meet the requirements of this contract.
(2) "Computer database" means a collection of recorded data in a form
capable of being processed by a computer. The term does not include
computer software.
(3) "Computer program" means a set of instructions, rules, or routines,
recorded in a form that is capable of causing a computer to perform a
specific operation or series of operations.
(4) "Computer software" means computer programs, source code, source code
listings, object code listings, design details, algorithms, processes,
flow charts, formulae, and related material that would enable the software
to be reproduced, recreated, or recompiled. Computer software does not
include computer databases or computer software documentation.
(5) "Computer software documentation" means owner's manuals, user's
manuals, installation instructions, operating instructions, and other
similar items, regardless of storage medium, that explain the capabilities
of the computer software or provide instructions for using the software.
40
(6) "Developed" means that-
(i) A computer program has been successfully operated in a computer
and tested to the extent sufficient to demonstrate to reasonable
persons skilled in the art that the program can reasonably be
expected to perform its intended purpose;
(ii) Computer software, other than computer programs, has been
tested or analyzed to the extent sufficient to demonstrate to
reasonable persons skilled in the art that the software can
reasonably be expected to perform its intended purpose; or
(iii) Computer software documentation required to be delivered under
a contract has been written, in any medium, in sufficient detail to
comply with requirements under that contract.
(7) "Developed exclusively at private expense" means development was
accomplished entirely with costs charged to indirect cost pools, costs not
allocated to a government contract, or any combination thereof.
(i) Private expense determinations should be made at the lowest
practicable level.
(ii) Under fixed-price contracts, when total costs are greater than
the firm-fixed-price or ceiling price of the contract, the
additional development costs necessary to complete development shall
not be considered when determining whether development was at
government, private, or mixed expense.
(8) "Developed exclusively with government funds" means development was
not accomplished exclusively or partially at private expense.
(9) "Developed with mixed funding" means development was accomplished
partially with costs charged to indirect cost pools and/or costs not
allocated to a government contract, and partially with costs charged
directly to a government contract.
(10) "Government purpose" means any activity in which the United States
Government is a party, including cooperative agreements with international
or multi-national defense organizations or sales or transfers by the
United States Government to foreign governments or international
organizations. Government purposes include competitive procurement, but do
not include the rights to use, modify, reproduce, release, perform,
display, or disclose computer software or computer software documentation
for commercial purposes or authorize others to do so.
41
(11) "Government purpose rights" means the rights to-
(i) Use, modify, reproduce, release, perform, display, or disclose
computer software or computer software documentation within the
Government without restriction; and
(ii) Release or disclose computer software or computer software
documentation outside the Government and authorize persons to whom
release or disclosure has been made to use, modify, reproduce,
release, perform, display, or disclose the software or documentation
for United States government purposes.
(12) "Minor modification" means a modification that does not significantly
alter the nongovernmental function or purpose of the software or is of the
type customarily provided in the commercial marketplace.
(13) "Noncommercial computer software" means software that does not
qualify as commercial computer software under paragraph (a)(1) of this
clause.
(14) "Restricted rights" apply only to noncommercial computer software and
mean the Government's rights to-
(i) Use a computer program with one computer at one time. The
program may not be accessed by more than one terminal or central
processing unit or time shared unless otherwise permitted by this
contract;
(ii) Transfer a computer program to another Government agency
without the further permission of the Contractor if the transferor
destroys all copies of the program and related computer software
documentation in its possession and notifies the licensor of the
transfer. Transferred programs remain subject to the provisions of
this clause;
(iii) Make the minimum number of copies of the computer software
required for safekeeping (archive), backup, or modification
purposes;
(iv) Modify computer software provided that the Government may-
(A) Use the modified software only as provided in paragraphs
(a)(14)(i) and (iii) of this clause; and
(B) Not release or disclose the modified software except as
provided in paragraphs (a)(14)(ii), (v) and (vi) of this
clause;
(v) Permit contractors or subcontractors performing service
contracts in support of this or a related contract to use computer
software to diagnose and correct deficiencies in a computer program,
to modify computer software to enable a computer program to be
combined with, adapted to, or merged with other computer programs or
when necessary to respond to urgent tactical situations, provided
that-
42
(A) The Government notifies the party which has granted
restricted rights that a release or disclosure to particular
contractors or subcontractors was made;
(B) Such contractors or subcontractors are subject to the use
and non-disclosure agreement that will be provided by the TSA
or are Government contractors receiving access to the software
for performance of a Government contract that contains the
clause entitled "Limitations on the Use or Disclosure of
Government-Furnished Information Marked with Restrictive
Legends";
(C) The Government shall not permit the recipient to
decompile, disassemble, or reverse engineer the software, or
use software decompiled, disassembled, or reverse engineered
by the Government pursuant to paragraph (a)(14)(iv) of this
clause, for any other purpose; and
(D) Such use is subject to the limitation in paragraph
(a)(14)(i) of this clause; and
(vi) Permit contractors or subcontractors performing emergency
repairs or overhaul of items or components of items procured under
this or a related contract to use the computer software when
necessary to perform the repairs or overhaul, or to modify the
computer software to reflect the repairs or overhaul made, provided
that-
(A) The intended recipient is subject to the use of a
non-disclosure agreement to be provided by the TSA or is a
Government contractor receiving access to the software for
performance of a Government contract that contains the clause
entitled "Limitations on the Use or Disclosure of
Government-Furnished Information Marked with Restrictive
Legends"; and
(B) The Government shall not permit the recipient to
decompile, disassemble, or reverse engineer the software, or
use software decompiled, disassembled, or reverse engineered
by the Government pursuant to paragraph (a)(14)(iv) of this
clause, for any other purpose.
(15) "Unlimited rights" means rights to use, modify, reproduce, release,
perform, display, or disclose computer software or computer software
documentation in whole or in part, in any manner and for any purpose
whatsoever, and to have or authorize others to do so.
43
(b) Rights in computer software or computer software documentation. The
Contractor grants or shall obtain for the Government the following royalty free,
world-wide, nonexclusive, irrevocable license rights in noncommercial computer
software or computer software documentation. All rights not granted to the
Government are retained by the Contractor.
(1) Unlimited rights. The Government shall have unlimited rights in-
(i) Computer software developed exclusively with Government funds;
(ii) Computer software documentation required to be delivered under
this contract;
(iii) Corrections or changes to computer software or computer
software documentation furnished to the Contractor by the
Government;
(iv) Computer software or computer software documentation that is
otherwise publicly available or has been released or disclosed by
the Contractor or subcontractor without restriction on further use,
release or disclosure, other than a release or disclosure resulting
from the sale, transfer, or other assignment of interest in the
software to another party or the sale or transfer of some or all of
a business entity or its assets to another party;
(v) Computer software or computer software documentation obtained
with unlimited rights under another Government contract or as a
result of negotiations; or
(vi) Computer software or computer software documentation furnished
to the Government, under this or any other Government contract or
subcontract hereunder with-
(A) Restricted rights in computer software, limited rights in
technical data, or government purpose license rights and the
restrictive conditions have expired; or
(B) Government purpose rights and the Contractor's exclusive
right to use such software or documentation for commercial
purposes has expired.
(2) Government purpose rights.
(i) Except as provided in paragraph (b)(1) of this clause, the
Government shall have government purpose rights in computer software
developed with mixed funding.
(ii) Government purpose rights shall remain in effect for a period
of five years unless a different period has been negotiated. Upon
expiration of the five-year or other negotiated period, the
Government shall have unlimited rights in the computer software or
computer software documentation. The government purpose rights
period shall commence upon execution of the contract, subcontract,
letter contract (or similar contractual instrument), contract
modification, or option exercise that required development of the
computer software.
44
(iii) The Government shall not release or disclose computer software
in which it has government purpose rights to any other person
unless-
(A) Prior to release or disclosure, the intended recipient is
subject to the use and non-disclosure agreement that will be
provided by TSA; or
(B) The recipient is a Government contractor receiving access
to the software or documentation for performance of a
Government contract that contains the clause entitled
"Limitations on the Use or Disclosure of Government Furnished
Information Marked with Restrictive Legends".
(3) Restricted rights.
(i) The Government shall have restricted rights in noncommercial
computer software required to be delivered or otherwise provided to
the Government under this contract that were developed exclusively
at private expense.
(ii) The Contractor, its subcontractors, or suppliers are not
required to provide the Government additional rights in
noncommercial computer software delivered or otherwise provided to
the Government with restricted rights. However, if the Government
desires to obtain additional rights in such software, the Contractor
agrees to promptly enter into negotiations with the Contracting
Officer to determine whether there are acceptable terms for
transferring such rights. All noncommercial computer software in
which the Contractor has granted the Government additional rights
shall be listed or described in a license agreement made part of the
contract (see paragraph (b)(4) of this clause). The license shall
enumerate the additional rights granted the Government.
(4) Specifically negotiated license rights.
(i) The standard license rights granted to the Government under
paragraphs (b)(1) through (b)(3) of this clause, including the
period during which the Government shall have government purpose
rights in computer software, may be modified by mutual agreement to
provide such rights as the parties consider appropriate but shall
not provide the Government lesser rights in computer software than
are enumerated in paragraph (a)(14) of this clause or lesser rights
in computer software documentation than are enumerated in paragraph
(a)(13) of the Rights in Technical Data--Noncommercial Items clause
of this contract.
45
(ii) Any rights so negotiated shall be identified in a license
agreement made part of this contract.
(5) Prior government rights. Computer software or computer software
documentation that will be delivered, furnished, or otherwise provided to
the Government under this contract, in which the Government has previously
obtained rights shall be delivered, furnished, or provided with the
pre-existing rights, unless-
(i) The parties have agreed otherwise; or
(ii) Any restrictions on the Government's rights to use, modify,
reproduce, release, perform, display, or disclose the data have
expired or no longer apply.
(6) Release from liability. The Contractor agrees to release the
Government from liability for any release or disclosure of computer
software made in accordance with paragraph (a)(14) or (b)(2)(iii) of this
clause, in accordance with the terms of a license negotiated under
paragraph (b)(4) of this clause, or by others to whom the recipient has
released or disclosed the software, and to seek relief solely from the
party who has improperly used, modified, reproduced, released, performed,
displayed, or disclosed Contractor software marked with restrictive
legends.
(c) Rights in derivative computer software or computer software documentation.
The Government shall retain its rights in the unchanged portions of any computer
software or computer software documentation delivered under this contract that
the Contractor uses to prepare, or includes in, derivative computer software or
computer software documentation.
(d) Third party copyrighted computer software or computer software
documentation. The Contractor shall not, without the written approval of the
Contracting Officer, incorporate any copyrighted computer software or computer
software documentation in the software or documentation to be delivered under
this contract unless the Contractor is the copyright owner or has obtained for
the Government the license rights necessary to perfect a license or licenses in
the deliverable software or documentation of the appropriate scope set forth in
paragraph (b) of this clause, and prior to delivery of such-
(1) Computer software, has provided a statement of the license rights
obtained in a form acceptable to the Contracting Officer; or (2) Computer
software documentation, has affixed to the transmittal document a
statement of the license rights obtained.
46
(e) Identification and delivery of computer software and computer software
documentation to be furnished with restrictions on use, release, or disclosure.
(1) This paragraph does not apply to restrictions based solely on
copyright.
(2) Except as provided in paragraph (e)(3) of this clause, computer
software that the Contractor asserts should be furnished to the Government
with restrictions on use, release, or disclosure is identified in an
attachment to this contract (the Attachment). The Contractor shall not
deliver any software with restrictive markings unless the software is
listed on the Attachment.
(3) In addition to the assertions made in the Attachment, other assertions
may be identified after award when based on new information or inadvertent
omissions unless the inadvertent omissions would have materially affected
the source selection decision. Such identification and assertion shall be
submitted to the Contracting Officer as soon as practicable prior to the
scheduled date for delivery of the software, in the following format, and
signed by an official authorized to contractually obligate the Contractor:
Identification and Assertion of Restrictions on the
Government's Use, Release, or Disclosure of Computer Software.
The Contractor asserts for itself, or the persons identified below, that
the Government's rights to use, release, or disclose the following
computer software should be restricted:
Computer Software Name of Person
to be Furnished Basis for Asserted Rights Asserting
With Restrictions* Assertion** Category*** Restrictions****
(LIST) (LIST) (LIST) (LIST)
*Generally, development at private expense, either exclusively or
partially, is the only basis for asserting restrictions on the
Government's rights to use, release, or disclose computer software.
**Indicate whether development was exclusively or partially at
private expense. If development was not at private expense, enter
the specific reason for asserting that the Government's rights
should be restricted.
***Enter asserted rights category (e.g., restricted or government
purpose rights in computer software, government purpose license
rights from a prior contract, rights in SBIR software generated
under another contract, or specifically negotiated licenses).
****Corporation, individual, or other person, as appropriate.
47
Date ______________________________
Printed Name and Title ______________________________
______________________________
Signature ______________________________
(End of identification and assertion)
(4) When requested by the Contracting Officer, the Contractor shall
provide sufficient information to enable the Contracting Officer to
evaluate the Contractor's assertions. The Contracting Officer reserves the
right to add the Contractor's assertions to the Attachment and validate
any listed assertion, at a later date, in accordance with the procedures
of the Validation of Asserted Restrictions-Computer Software clause of
this contract.
(f) Marking requirements. The Contractor, and its subcontractors or suppliers,
may only assert restrictions on the Government's rights to use, modify,
reproduce, release, perform, display, or disclose computer software by marking
the deliverable software or documentation subject to restriction. Except as
provided in paragraph (f)(5) of this clause, only the following legends are
authorized under this contract: the government purpose rights legend at
paragraph (f)(2) of this clause; the restricted rights legend at paragraph
(f)(3) of this clause; or the special license rights legend at paragraph (f)(4)
of this clause; and/or a notice of copyright as prescribed under 17 U.S.C. 401
or 402.
(1) General marking instructions. The Contractor, or its subcontractors or
suppliers, shall conspicuously and legibly xxxx the appropriate legend on
all computer software that qualify for such markings. The authorized
legends shall be placed on the transmittal document or software storage
container and each page, or portions thereof, of printed material
containing computer software for which restrictions are asserted. Computer
software transmitted directly from one computer or computer terminal to
another shall contain a notice of asserted restrictions. However,
instructions that interfere with or delay the operation of computer
software in order to display a restrictive rights legend or other license
statement at any time prior to or during use of the computer software, or
otherwise cause such interference or delay, shall not be inserted in
software that will or might be used in combat or situations that simulate
combat conditions, unless the Contracting Officer's written permission to
deliver such software has been obtained prior to delivery. Reproductions
of computer software or any portions thereof subject to asserted
restrictions, shall also reproduce the asserted restrictions.
48
(2) Government purpose rights markings. Computer software delivered or
otherwise furnished to the Government with government purpose rights shall
be marked as follows:
GOVERNMENT PURPOSE RIGHTS
Contract No.
Contractor Name
Contractor Address
Expiration Date
The Government's rights to use, modify, reproduce, release, perform,
display, or disclose this software are restricted by paragraph
(b)(2) of the Rights in Noncommercial Computer Software and
Noncommercial Computer Software Documentation clause contained in
the above identified contract. No restrictions apply after the
expiration date shown above. Any reproduction of the software or
portions thereof marked with this legend must also reproduce the
markings.
(End of legend)
(3) Restricted rights markings. Software delivered or otherwise furnished
to the Government with restricted rights shall be marked with the
following legend:
RESTRICTED RIGHTS
Contract No.
Contractor Name
Contractor Address
The Government's rights to use, modify, reproduce, release, perform,
display, or disclose this software are restricted by paragraph
(b)(3) of the Rights in Noncommercial Computer Software and
Noncommercial Computer Software Documentation clause contained in
the above identified contract. Any reproduction of computer software
or portions thereof marked with this legend must also reproduce the
markings. Any person, other than the Government, who has been
provided access to such software must promptly notify the above
named Contractor.
(End of legend)
49
(4) Special license rights markings.
(i) Computer software or computer software documentation in which
the Government's rights stem from a specifically negotiated license
shall be marked with the following legend:
SPECIAL LICENSE RIGHTS
The Government's rights to use, modify, reproduce, release, perform,
display, or disclose these data are restricted by Contract No.
_____(Insert contract number)____, License No. ____(Insert license
identifier)____. Any reproduction of computer software, computer
software documentation, or portions thereof marked with this legend
must also reproduce the markings.
(End of legend)
(ii) For purposes of this clause, special licenses do not include
government purpose license rights acquired under a prior contract
(see paragraph (b)(5) of this clause).
(5) Pre-existing markings. If the terms of a prior contract or license
permitted the Contractor to restrict the Government's rights to use,
modify, release, perform, display, or disclose computer software or
computer software documentation and those restrictions are still
applicable, the Contractor may xxxx such software or documentation with
the appropriate restrictive legend for which the software qualified under
the prior contract or license. The marking procedures in paragraph (f)(1)
of this clause shall be followed.
(g) Contractor procedures and records. Throughout performance of this contract,
the Contractor and its subcontractors or suppliers that will deliver computer
software or computer software documentation with other than unlimited rights,
shall-
(1) Have, maintain, and follow written procedures sufficient to assure
that restrictive markings are used only when authorized by the terms of
this clause; and
(2) Maintain records sufficient to justify the validity of any restrictive
markings on computer software or computer software documentation delivered
under this contract.
50
(h) Removal of unjustified and nonconforming markings.
(1) Unjustified computer software or computer software documentation
markings. The rights and obligations of the parties regarding the
validation of restrictive markings on computer software or computer
software documentation furnished or to be furnished under this
contract are contained in the Validation of Asserted
Restrictions--Computer Software and the Validation of Restrictive
Markings on Technical Data clauses of this contract, respectively.
Notwithstanding any provision of this contract concerning inspection
and acceptance, the Government may ignore or, at the Contractor's
expense, correct or strike a marking if, in accordance with the
procedures of those clauses, a restrictive marking is determined to
be unjustified.
(2) Nonconforming computer software or computer software
documentation markings. A nonconforming marking is a marking placed
on computer software or computer software documentation delivered or
otherwise furnished to the Government under this contract that is
not in the format authorized by this contract. Correction of
nonconforming markings is not subject to the Validation of Asserted
Restrictions--Computer Software or the Validation of Restrictive
Markings on Technical Data clause of this contract. If the
Contracting Officer notifies the Contractor of a nonconforming
marking or markings and the Contractor fails to remove or correct
such markings within sixty (60) days, the Government may ignore or,
at the Contractor's expense, remove or correct any nonconforming
markings.
(i) Relation to patents. Nothing contained in this clause shall imply a license
to the Government under any patent or be construed as affecting the scope of any
license or other right otherwise granted to the Government under any patent.
(j) Limitation on charges for rights in computer software or computer software
documentation.
(1) The Contractor shall not charge to this contract any cost, including
but not limited to license fees, royalties, or similar charges, for rights
in computer software or computer software documentation to be delivered
under this contract when-
(i) The Government has acquired, by any means, the same or greater
rights in the software or documentation; or
(ii) The software or documentation are available to the public
without restrictions.
(2) The limitation in paragraph (j)(1) of this clause-
(i) Includes costs charged by a subcontractor or supplier, at any
tier, or costs incurred by the Contractor to acquire rights in
subcontractor or supplier computer software or computer software
documentation, if the subcontractor or supplier has been paid for
such rights under any other Government contract or under a license
conveying the rights to the Government; and
51
(ii) Does not include the reasonable costs of reproducing, handling,
or mailing the documents or other media in which the software or
documentation will be delivered.
(k) Applicability to subcontractors or suppliers.
(1) Whenever any noncommercial computer software or computer software
documentation is to be obtained from a subcontractor or supplier for
delivery to the Government under this contract, the Contractor shall use
this same clause in its subcontracts or other contractual instruments, and
require its subcontractors or suppliers to do so, without alteration,
except to identify the parties. No other clause shall be used to enlarge
or diminish the Government's, the Contractor's, or a higher tier
subcontractor's or supplier's rights in a subcontractor's or supplier's
computer software or computer software documentation.
(2) The Contractor and higher tier subcontractors or suppliers shall not
use their power to award contracts as economic leverage to obtain rights
in computer software or computer software documentation from their
subcontractors or suppliers.
(3) The Contractor shall ensure that subcontractor or supplier rights are
recognized and protected in the identification, assertion, and delivery
processes required by paragraph (e) of this clause.
(4) In no event shall the Contractor use its obligation to recognize and
protect subcontractor or supplier rights in computer software or computer
software documentation as an excuse for failing to satisfy its contractual
obligation to the Government.
(End of clause)
RIGHTS IN BID OR PROPOSAL INFORMATION
(a) Definitions.
(1) For contracts that require the delivery of technical data, the terms
"technical data" and "computer software" are defined in the Rights in
Technical Data--Noncommercial Item clause of this contract.
(2) For contracts that do not require the delivery of technical data, the
term "computer software" is defined in the Rights in Noncommercial
Computer and Noncommercial Computer Software Documentation clause of this
contract.
52
(b Government rights prior to contract award. By submission of its offer, the
Offeror agrees that the Government-
(1) May reproduce the bid or proposal, or any portions thereof, to the
extent necessary to evaluate the offer.
(2) Except as provided in paragraph (d) of this clause, shall use
information contained in the bid or proposal only for evaluational
purposes and shall not disclose, directly or indirectly, such information
to any person including potential evaluators, unless that person has been
authorized by the head of the agency, his or her designee, or the
Contracting Officer to receive such information.
(c) Government rights subsequent to contract award. The Contractor agrees-
(1) Except as provided in paragraphs (c)(2), (d), and (e) of this clause,
the Government shall have the rights to use, modify, reproduce, release,
perform, display, or disclose information contained in the Contractor's
bid or proposal within the Government. The Government shall not release,
perform, display, or disclose such information outside the Government
without the Contractor's written permission.
(2) The Government's right to use, modify, reproduce, release, perform,
display, or disclose information that is technical data or computer
software required to be delivered under this contract are determined by
the Rights in Technical Data--Noncommercial Items, Rights in Noncommercial
Computer Software and Noncommercial Computer Software Documentation clause
of this contract.
(d) Government-furnished information. The Government's rights with respect to
technical data or computer software contained in the Contractor's bid or
proposal that were provided to the Contractor by the Government are subject only
to restrictions on use, modification, reproduction, release, performance,
display, or disclosure, if any, imposed by the developer or licensor of such
data or software.
(e) Information available without restrictions. The Government's rights to use,
modify, reproduce, release, perform, display, or, disclose information contained
in a bid or proposal, including technical data or computer software, and to
permit others to do so, shall not be restricted in any manner if such
information has been released or disclosed to the Government or to other persons
without restrictions other than a release or disclosure resulting from the sale,
transfer, or other assignment of interest in the information to another party or
the sale or transfer of some or all of a business entity or its assets to
another party.
(f) Flowdown. The Contractor shall include this clause in all subcontracts or
similar contractual instruments and require its subcontractors or suppliers to
do so without alteration, except to identify the parties.
(End of clause)
53
VALIDATION OF ASSERTED RESTRICTIONS--COMPUTER SOFTWARE
(a) Definitions.
(1) As used in this clause, unless otherwise specifically indicated, the
term "Contractor" means the Contractor and its subcontractors or
suppliers.
(2) Other terms used in this clause are defined in the Rights in
Noncommercial Computer Software and Noncommercial Computer Software
Documentation clause of this contract.
(b) Justification. The Contractor shall maintain records sufficient to justify
the validity of any markings that assert restrictions on the Government's rights
to use, modify, reproduce, perform, display, release, or disclose computer
software delivered or required to be delivered under this contract and shall be
prepared to furnish to the Contracting Officer a written justification for such
restrictive markings in response to a request for information under paragraph
(d) or a challenge under paragraph (f) of this clause.
(c) Direct contact with subcontractors or suppliers. The Contractor agrees that
the Contracting Officer may transact matters under this clause directly with
subcontractors or suppliers at any tier who assert restrictions on the
Government's right to use, modify, reproduce, release, perform, display, or
disclose computer software. Neither this clause, nor any action taken by the
Government under this clause, creates or implies privity of contract between the
Government and the Contractor's subcontractors or suppliers.
(d) Requests for information.
(1) The Contracting Officer may request the Contractor to provide
sufficient information to enable the Contracting Officer to evaluate the
Contractor's asserted restrictions. Such information shall be based upon
the records required by this clause or other information reasonably
available to the Contractor.
(2) Based upon the information provided, if the-
(i) Contractor agrees that an asserted restriction is not valid, the
Contracting Officer may-
(A) Strike or correct the unjustified marking at the
Contractor's expense; or
(B) Return the computer software to the Contractor for
correction at the Contractor's expense. If the Contractor
fails to correct or strike the unjustified restriction and
return the corrected software to the Contracting Officer
within sixty (60) days following receipt of the software, the
Contracting Officer may correct or strike the markings at that
Contractor's expense.
(ii) Contracting Officer concludes that the asserted restriction is
appropriate for this contract, the Contracting Officer shall so
notify the Contractor in writing.
54
(3) The Contractor's failure to provide a timely response to a Contracting
Officer's request for information or failure to provide sufficient
information to enable the Contracting Officer to evaluate an asserted
restriction shall constitute reasonable grounds for questioning the
validity of an asserted restriction.
(e) Government right to challenge and validate asserted restrictions.
(1) The Government, when there are reasonable grounds to do so, has the
right to review and challenge the validity of any restrictions asserted by
the Contractor on the Government's rights to use, modify, reproduce,
release, perform, display, or disclose computer software delivered, to be
delivered under this contract, or otherwise provided to the Government in
the performance of this contract. Except for software that is publicly
available, has been furnished to the Government without restrictions, or
has been otherwise made available without restrictions, the Government may
exercise this right only within three years after the date(s) the software
is delivered or otherwise furnished to the Government, or three years
following final payment under this contract, whichever is later.
(2) The absence of a challenge to an asserted restriction shall not
constitute validation under this clause. Only a Contracting officer's
final decision or the actions of the Office of Disputes Resolution for
Acquisition (ODRA) or a court of competent jurisdiction (see clause
3.9.1-1 Contract Disputes) that sustain the validity of an asserted
restriction constitute validation of the restriction.
(f) Challenge procedures.
(1) A challenge must be in writing and shall-
(i) State the specific grounds for challenging the asserted
restriction;
(ii) Require the Contractor to respond within sixty (60) days;
(iii) Require the Contractor to provide justification for the
assertion based upon records kept in accordance with paragraph (b)
of this clause and such other documentation that are reasonably
available to the Contractor, in sufficient detail to enable the
Contracting Officer to determine the validity of the asserted
restrictions; and
(iv) State that a Contracting Officer's final decision, during the
three-year period preceding this challenge, or the actions of the
Office of Disputes Resolution for Acquisition (ODRA) or a court of
competent jurisdiction (see clause 3.9.1-1 Contract Disputes) that
sustained the validity of an identical assertion made by the
Contractor (or a licensee) shall serve as justification for the
asserted restriction.
(2) The Contracting Officer shall extend the time for response if the
Contractor submits a written request showing the need for additional time
to prepare a response.
55
(3) The Contracting Officer may request additional supporting
documentation if, in the Contracting Officer's opinion, the Contractor's
explanation does not provide sufficient evidence to justify the validity
of the asserted restrictions. The Contractor agrees to promptly respond to
the Contracting Officer's request for additional supporting documentation.
(4) Notwithstanding challenge by the Contracting Officer, the parties may
agree on the disposition of an asserted restriction at any time prior to a
Contracting Officer's final decision or, if the Contractor has appealed
that decision, filed, or provided notice of an intent to file with the
ODRA.
(5) If the Contractor fails to respond to the Contracting Officer's
request for information or additional information under paragraph (f)(1)
of this clause, the Contracting Officer shall issue a final decision, in
accordance with the Contract Disputes clause of this contract, pertaining
to the validity of the asserted restriction.
(6) If the Contracting Officer, after reviewing the written explanation
furnished pursuant to paragraph (f)(1) of this clause, or any other
available information pertaining to the validity of an asserted
restriction, determines that the asserted restriction has-
(i) Not been justified, the Contracting Officer shall issue promptly
a final decision, in accordance with the Contract Disputes clause of
this Contract, denying the validity of the asserted restriction; or
(ii) Been justified, the Contracting Officer shall issue a final
decision, in accordance with the Contract Disputes clause of this
Contract, validating the asserted restriction.
(7) A Contractor receiving challenges to the same asserted restriction(s)
from more than one Contracting Officer shall notify each Contracting
Officer of the other challenges. The notice shall also state which
Contracting Officer initiated the first in time unanswered challenge. The
Contracting Officer who initiated the first in time unanswered challenge,
after consultation with the other Contracting Officers who have challenged
the restrictions and the Contractor, shall formulate and distribute a
schedule that provides the Contractor a reasonable opportunity for
responding to each challenge.
(g) Contractor appeal-Government obligation.
(1) The Government agrees that, notwithstanding a Contracting Officer's
final decision denying the validity of an asserted restriction and except
as provided in paragraph (g)(3) of this clause, it will honor the asserted
restriction-
(i) For a period of ninety (90) days from the date of the
Contracting Officer's final decision to allow the Contractor to
appeal to the ODRA or a court of competent jurisdiction;
56
(ii) For a period of one year from the date the Contracting
Officer's final decision if, within the first ninety (90) days
following the Contracting Officer's final decision the Contractor
has provided notice of an intent to file with the ODRA; or
(iii) Until final disposition by the ODRA or a court of competent
jurisdiction; if the Contractor has:
(A) appealed to the ODRA or sought judicial review;
B) submitted, within ninety (90) days, a notice of intent to
seek judicial review in a court of competent jurisdiction
within one year.
(2) The Contractor agrees that the Government may strike, correct, or
ignore the restrictive markings if the Contractor fails to-
(i) Appeal to the ODRA within ninety (90) days from the date of the
Contracting Officer's final decision;
(ii) Seek judicial review in a court of competent jurisdiction
within 90 (ninety) days from such date; or
(iii) File with the ODRA within one year after the date of the
Contracting Officer's final decision if the Contractor had provided
notice of intent to file with the ODRA within 90 (ninety) days
following the date of the Contracting Officer's final decision.
(3) The agency head, on a nondelegable basis, may determine that
emergency circumstances do not permit awaiting the filing with ODRA or the
rendering of a decision by a court of competent jurisdiction. In that event, the
agency head shall notify the Contractor of the circumstances of emergency.
Notwithstanding paragraph (g)(1) of this clause, the Contractor agrees that the
agency may use, modify, reproduce, release, perform, display, or disclose
computer software marked with (i) government purpose legends for any purpose,
and authorize others to do so; or (ii) restricted or special license rights for
government purposes only. The Government agrees not to release or disclose such
software unless, prior to release or disclosure, the intended recipient is
subject to the use and non-disclosure provided by the Transportation Security
Administration (TSA), or is a Government contractor receiving access to the
software for performance of a Government contract that contains the clause
entitled "Limitations on the Use or Disclosure of Government-Furnished
Information Marked with Restrictive Legends. The agency head's determination may
be made at any time after the date of the Contracting Officer's final decision
and shall not affect the Contractor's right to damages against the United State,
or other relief provided by law, if its asserted restrictions are ultimately
upheld.
(h) Final disposition of appeal or suit. If the Contractor files with the
ODRA or seeks judicial review in a court of competent jurisdiction, the
Contracting Officer's decision is:
57
(1) Sustained -
(i) Any restrictive marking on such computer software shall be
struck or corrected at the Contractor's expense or ignored; and
(ii) If the challenge by the Government is found not to be
substantially justified, the Contractor shall be liable to the Government for
payment of the cost to the Government of reviewing the asserted restriction and
the fees and other expenses (as defined in 28 U.S.C 2412(d)(2)(A)) incurred by
the Contractor in defending the restriction.
(2) Not sustained -
(i) The Government shall be bound by the asserted restriction; and
(ii) If the challenge by the Government is found not to have been
made in good faith, the Government shall be liable to the Contractor for payment
of fees and other expenses (as defined in 28 U.S.C.2412(d)(2)(A)) incurred by
the Contractor in defending the restriction.
(i) Flowdown. The Contractor shall insert this clause in all contracts,
purchase orders, and other similar instruments with its subcontractors or
suppliers, at any tier, who will be furnishing computer software to the
Government in the performance of this contract. The clause may not be
altered other than to identify the appropriate parties.
(End of clause)
LIMITATIONS ON THE USE OR DISCLOSURE OF GOVERNMENT-FURNISHED INFORMATION
MARKED WITH RESTRICTIVE LEGENDS
(a)(1) For contracts requiring the delivery of technical data, the terms
"limited rights" and "Government purpose rights" are defined in the Rights
in Technical Data--Noncommercial Items clause of this contract.
(2) For contracts that do not require the delivery of technical
data, the terms "government purpose rights" and "restricted rights"
are defined in the Rights in Noncommercial Computer Software and
Noncommercial Computer Software Documentation clause of this
contract.
(3) For Small Business Innovative Research program contracts, the
terms "limited rights" and "restricted rights" are defined in the
Rights in Noncommercial Technical Data and Computer Software--Small
Business Innovative Research (SBIR) Program clause of this contract.
(b) Technical data or computer software provided to the Contractor as
Government furnished information (GFI) under this contract may be subject
to restrictions on use, modification, reproduction, release, performance,
display, or further disclosure.
(1) GFI marked with limited or restricted rights legends. The
Contractor shall use, modify, reproduce, perform, or display
technical data received from the Government with limited rights
legends or computer software received with restricted rights legends
only in the performance of this contract. The Contractor shall not,
without the express written permission of the party whose name
appears in the legend, release or disclose such data or software to
any person.
58
(2) GFI marked with government purpose rights legends. The Contractor
shall use technical data or computer software received from the Government
with government purpose rights legends for government purposes only. The
Contractor shall not, without the express written permission of the party
whose name appears in the restrictive legend, use, modify, reproduce,
release, perform, or display such data or software for any commercial
purpose or disclose such data or software to a person other than its
subcontractors, suppliers, or prospective subcontractors or suppliers, who
require the data or software to submit offers for, or perform, contracts
under this contract. Prior to disclosing the data or software, the
Contractor shall require the persons to whom disclosure will be made to
complete and sign the non-disclosure agreement provided by the TSA.
(3) GFI marked with specially negotiated license rights legends. The
Contractor shall use, modify, reproduce, release, perform, or display
technical data or computer software received from the Government with
specially negotiated license legends only as permitted in the license.
Such data or software may not be released or disclosed to other persons
unless permitted by the license and, prior to release or disclosure, the
intended recipient has completed the non-disclosure agreement provided by
the TSA.
(c) Indemnification and creation of third party beneficiary rights. The
Contractor agrees-
(1) To indemnify and hold harmless the Government, its agents, and
employees from every claim or liability, including attorneys fees, court
costs, and expenses, arising out of, or in any way related to, the misuse
or unauthorized modification, reproduction, release, performance, display,
or disclosure of technical data or computer software received from the
Government with restrictive legends by the Contractor or any person to
whom the Contractor has released or disclosed such data or software; and
(2) That the party whose name appears on the restrictive legend, in
addition to any other rights it may have, is a third party beneficiary who
has the right of direct action against the Contractor, or any person to
whom the Contractor has released or disclosed such data or software, for
the unauthorized duplication, release, or disclosure of technical data or
computer software subject to restrictive legends.
(End of clause)
TECHNICAL DATA OR COMPUTER SOFTWARE PREVIOUSLY DELIVERED TO THE GOVERNMENT
The Offeror shall attach to its offer an identification of all documents
or other media incorporating technical data or computer software it
intends to deliver under this contract with other than unlimited rights
that are identical or substantially similar to documents or other media
that the Offeror has produced for, delivered to, or is obligated to
deliver to the Government under any contract or subcontract. The
attachment shall identify -
59
(a) The contract number under which the data or software were produced;
(b) The contract number under which, and the name and address of the
organization to whom, the data or software were most recently
delivered or will be delivered; and
(c) Any limitations on the Government's rights to use or disclose the
data or software, including, when applicable, identification of the
earliest date the limitations expire.
(End of Provision)
Rights in Technical Data and Computer Software (Foreign)
The United States may duplicate, use, and disclose in any manner for any
purposes whatsoever, including delivery to other governments for the
furtherance of mutual defense of the Unites States Government and other
governments, all technical data, including reports, drawings and
blueprints, and all computer software, specified to be delivered by the
Contractor to the United States Government under this contract.
Recipient to Complete For Purposes of G.4
--------------- ----------------- -------------- ------------- ----------------- ----------------
Rights Technical Data Computer Criteria Permitted Uses Permitted Uses
Category Computer Data Software for Within Outside
Applying Government Government
Rights
Define Whether Define Category
Commercial or whether
Non-Commercial Commercial
Or
Non-Commercial
--------------- ----------------- -------------- ------------- ----------------- ----------------
--------------- ----------------- -------------- ------------- ----------------- ----------------
--------------- ----------------- -------------- ------------- ----------------- ----------------
60