Common Contracts

Contract

February 10th, 2022

• Filed
  February 10th, 2022

Engineering and Construction Short Contract A contract between Ribble Catchment Conservation Trust Ltd (trading as Ribble Rivers Trust) and . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . for The construction design & build of a rock ramp fish pass at a Gathurst Weir on the River Douglas Contents Page Contract Forms Contract DataThe Contractor’s OfferThe Employer’s Acceptance Price ListWorks Information Site InformationConditions of Contract 2 4 4 5 6 9 CC1

Engineering and Construction Short Contract A contract between Ribble Catchment Conservation Trust Ltd (trading as Ribble Rivers Trust) and . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. . ....

May 20th, 2021

• Filed
  May 20th, 2021

Contract Data The Employer is Name Address TelephoneE-mail address The works are Ribble Catchment Conservation Trust Ltd.c/o Hanson Cement, Ribblesdale Works, Clitheroe, Lancashire, BB7 4QF 01200 444452adam.wheeler@ribbletrust.com The construction of a rock ramp type fish pass on the River Douglas The site is Pottery Terrace Weir (PTW) The starting date is 20th May 2021 The completion date is 30th September 2022 The period for reply is 4 weeks. The defects date is 52 weeks after Completion. The defect correction period is 4 weeks. The delay damages are n/a per day. The assessment day is the Last working day of each month. The retention is 5 %. Does the United Kingdom Housing Grants, Construction and Regeneration Act (1996) apply? Yes / No (delete as appropriate) The Adjudicator is Name To be selected by the President of the Institute of Civil Engineers Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .