A Force Majeure definition

A Force Majeure means any event arising from causes beyond the control of a party that causes a delay in or prevents the performance of any obligation under this agreement, including but not limited to,
Sample 1
A Force Majeure means any event arising from causes beyond the control of the Party that causes a delay in or prevents the performance of any obligation under this Agreement, including but not limited to, acts of God; fire; war; insurrection; civil disturbance; explosion; unanticipated breakage or accident to machinery, equipment or lines of pipe despite reasonably diligent maintenance; adverse weather conditions that could not be reasonably anticipated; unusual delay in transportation; restraint by court order or order of public authority; inability to obtain, at reasonable cost and after exercise of reasonable diligence, any necessary authorizations, approvals, permits or licenses due to action or inaction of any governmental agency or authority other than the Air Force; delays caused by compliance with applicable statutes or regulations governing contracting, procurement or acquisition procedures, despite the exercise of reasonable diligence; and insufficient availability of appropriated funds, if the Air Force shall have made a timely request for such funds as a part of the budgetary process as set forth in Section XXIV, Funding, of this Agreement. Force Majeure shall also include any strike or other labor dispute, whether or not within control of the parties affected thereby. Force Majeure shall not include increased costs or expenses of response actions, whether or not anticipated at the time such response actions were initiated.
Sample 1Sample 2
A Force Majeure occurrence shall mean any of the following occurrences beyond the control and without the fault or negligence of the party affected and which by the exercise of reasonable diligence the said party is unable to prevent or provide against and which delays the construction of the Vessel: 13.1.1 Act of God, fire, inclement weather of abnormal severity and/or duration; 13.1.2 war (whether declared or not), riots, insurrections or malicious damage; 13.1.3 damage to Vessel which constitutes a partial loss and is repaired from the proceeds of insurance under the provisions of Clauses 10.5 and 10.6.1; 13.1.4 requisition order, control, direction, intervention or requirement by or of any Government or body acting under the authority of any Government; 13.1.5 cessation, curtailment or interruption of fuel, power, gas, water or any other essential services; and 13.1.6 except where due to the fault or negligence of the Builder or its Subcontractors or Suppliers, any delay in or short delivery of, or defects in materials machinery services or equipment for the Vessel (provided that the Builder demonstrates that they are critical to construction of the Vessel at the time of delay and that they were ordered in due time); PROVIDED HOWEVER THAT the Builder shall not be entitled to rely upon any of the causes of delay listed in Clause 13.1 unless the Builder has taken all reasonable steps to mitigate their effect upon the construction of the Vessel.
Sample 1Sample 2

Examples of A Force Majeure in a sentence

  • A Force Majeure event does not include an act of negligence or intentional wrongdoing.

  • A Force Majeure event does not include acts of negligence or intentional wrongdoing by the Party claiming Force Majeure.

  • A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party.

  • A Force Majeure Event does not include an act of negligence or intentional wrongdoing.” For the purposes of this article, this definition of Force Majeure shall supersede the definitions of Force Majeure set out in Section 32.10.1 of the ISO OATT.

  • A Force Majeure Event may arise due to causes and events out of Homefield Energy’s reasonable control, including but not limited to acts of God; acts of any governmental authority; accidents; strikes; labor disputes; required maintenance work; inability to access DSP’s system; and non-performance by your DSP.

  • A Force Majeure Event shall not constitute a breach of the contract.

  • A Force Majeure event does not include an act of negligence or Intentional Wrongdoing by a Party.

  • A Force Majeure Event will not give rise to any cause of action or liability based on default of the provision that the party has failed to comply with or observe due to the Force Majeure Event.

  • A Force Majeure Event does not include an act of negligence or intentional wrongdoing.

  • A Force Majeure Event may arise due to causes and events out of DES’S reasonable control, including but not limited to acts of God; acts of any governmental authority; accidents; strikes; labor disputes; required maintenance work; inability to access DSP’s system; and non- performance by your DSP.


More Definitions of A Force Majeure

A Force Majeure occurrence shall mean an occurrence beyond the control and without the fault or negligence of the party affected and which by the exercise of reasonable diligence the said party is unable to prevent or provide against.
Sample 1
A Force Majeure means any event arising from causes beyond the control of a Party that causes a delay in or prevents the performance of any obligation by that Party under this Agreement, including, acts of God; fire; war; insurrection; civil disturbance; explosion; acts or a failure to act by the other Party; unanticipated breakage or accident to machinery, equipment or lines of pipe despite reasonably diligent maintenance; other circumstances that represent an imminent danger to human health, safety or the environment; adverse weather conditions that could not be reasonably anticipated; unusual delay in transportation; restraint by court order or order of public authority; delays caused by compliance with applicable statutes or regulations governing contracting, procurement or acquisition procedures, despite the exercise of reasonable diligence; and, in the case of performance by DOE, insufficient appropriated finds to perform its obligations under this Agreement, despite the exercise of reasonable diligence. Force Majeure shall not include increased costs or expenses.
Sample 1
A Force Majeure means any event or circumstance or combination of both including those stated below and on which the Affected Party has no control, that wholly or partly prevents or incapacitates the Affected Party in performing its obligations under this Agreement, even after the affected party having taken all reasonable care or it having complied with prudent utility practices: i) act of God, including, but not limited to lightning, drought, fire and explosion, accident, terrorist activities like sabotage, explosion or criminal damage, strike at National or State level, earthquake, volcanic eruption, landslide, flood, cyclone, typhoon, tornado; ii) any act of war (whether declared or undeclared), invasion, armed conflict or act of foreign enemy, blockade, embargo.
Sample 1
A Force Majeure means any event arising from causes beyond the control of a Party that causes a delay in or prevents the performance of any obligation by that Party under this Agreement, including, acts of God; fire; war; insurrection; civil disturbance; explosion; acts or a failure to act by the other Party; unanticipated breakage or accident to machinery, equipment or lines of pipe despite reasonably diligent maintenance; other circumstances that represent an imminent danger to human health, safety or the environment; adverse weather conditions that could not be reasonably anticipated; unusual delay in transportation; and restraint by court order or order of public authority. Force Majeure shall not include increased costs or expenses.
Sample 1

Related to A Force Majeure

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Event means an event beyond the reasonable control of any party including an outbreak of a serious disease or epidemic, or quarantine or other public health emergencies, fire, flood, earthquake, explosion or other casualty or accident or act of God, or war or other violence, strike, lock-out, labour dispute, acts of any governmental body, war, insurrection, sabotage, embargo, interruption of or delay in transportation, unavailability of or interruption or delay in telecommunications or inability to obtain raw materials, supplies or power.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Event of Force Majeure means one of the following events:

  • Force Majeure Exception means any failure or delay in the performance of the Fund’s reporting obligation pursuant to Section 2.3 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Fund shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Excusable Delays mean delays arising without the fault or negligence of Lessor and Lessor's subcontractors and suppliers at any tier, and shall include, without limitation: (1) acts of God or of the public enemy, (2) acts of the United States of America in either its sovereign or contractual capacity, (3) acts of another contractor in the performance of a contract with the Government, (4) fires, (5) floods, (6) epidemics, (7) quarantine restrictions, (8) strikes, (9) freight embargoes, (10) unusually severe weather, or (11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier.

  • Service Interruption means the cessation of electricity supply to an ICP for a period of 1 minute or longer, other than by reason of De-energisation of that ICP:

  • Unplanned Service Interruption means any Service Interruption where events or circumstances prevent the timely communication of prior warning or notice to the Trader or any affected Customer;

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Planned Service Interruption means a Service Interruption that has been scheduled to occur in accordance with Schedule 5;

  • Outage has the meaning set forth in the CAISO Tariff.

  • Excused Downtime means the number of minutes in the Charging Period that the LSP is unavailable due to:

  • Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of: (1) any unreasonable delay by Tenant in approving the Plans; (2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason; (3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant; (4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or (5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.

  • Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.

  • Essential functions means the fundamental job duties of the employment position the individual with a disability holds or desires. “Essential functions” does not include the marginal functions of the position.

  • Unavoidable means adverse impacts that remain after all appropriate and practicable avoidance and minimization have been achieved.

  • Act of God means a cataclysmic phenomenon of nature, including earthquake, flood or cyclone. Rain, snow, wind, high water or any other natural phenomenon, which might reasonably have been anticipated from historical records of the general locality of the City, shall be deemed not to be acts of God;