Activity Completion definition

Activity Completion means that the Funded Activity is complete to the reasonable satisfaction of the District based on review of reports and other documentation as deemed appropriate by the District. If the Funded Activity is an Infrastructure Program Project on District Right-of-Way a separate use and maintenance agreement is required.
Sample 1Sample 2Sample 3
Activity Completion means that the Funded Activity is complete to the reasonable satisfaction of the District based on review of reports and other documentation as deemed appropriate by the District. If the Funded Activity is an Infrastructure Program Project on District Right-of-Way a separate use and maintenance agreement is required. “Activity Costs” means the total costs necessary to achieve Activity Completion. The Activity Costs for the Funded Activity are described in Exhibit A.
Sample 1Sample 2Sample 3

Examples of Activity Completion in a sentence

  • Duration of the Grant The Activity starts on <project start date> and ends on <project end date>, which is the Activity Completion Date.

  • Activity Completion Date means the date or event specified in the Grant Details.

  • The Recipient shall submit an overview of the benefits achieved upon the Activity Completion.

  • The Activity starts on 31 August 2021 and ends on 31 August 2022, which is the Activity Completion Date.

  • Funded Activity Access When the Funded Activity involves an Infrastructure Program Project the Recipient shall, upon receipt of reasonable advance notice from the District, ensure that the District or any authorized representative of the foregoing, will have safe and suitable access to the site of the Funded Activity at all reasonable times through Activity Completion.

  • The Activity starts on and ends on, which is the Activity Completion Date.

  • The Recipient shall at all times maintain its current legal existence and preserve and keep in full force and effect its legal rights and authority through Activity Completion.

  • The Recipient is duly organized and existing and in good standing under the laws of the State of California and will remain so through Activity Completion.

  • The Activity starts on [Activity Start Date] and ends on 30 June 2023, which is the Activity Completion Date.

  • The Recipient shall retain for a period of seven (7) years after Activity Completion, all records necessary in accordance with Generally Accepted Accounting Principles to determine the amounts expended, and eligibility of Projects implemented using SCW Program Contributions.

Related to Activity Completion

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Commercial Operations Upon satisfaction of the following conditions, the Facility shall be considered to have achieved Commercial Operations on the Day specified in Seller's written notice described below: (i) the Acceptance Test has been passed, (ii) all generating units have passed Control System Acceptance Tests, (iii) the Transfer Date has occurred, (iv) Seller has (1) provided to Company the Required Models (as defined in Section 6(a) (Seller's Obligation to Provide Models) of Attachment B (Facility Owned by Seller)) in the form of Source Code, (2) placed the current version of the Source Code for the Required Models with the Source Code Escrow Agent as required in Section 6(b)(i)(A) (Establishment of Source Code Escrow) of Attachment B (Facility Owned by Seller), or (3) if Seller is unable to arrange for the placement of the appropriate Source Code into the Source Code Escrow account, placed the required funds with the Monetary Escrow Agent as required in Section 6(b)(ii)(A) (Establishment of Monetary Escrow) of Attachment B (Facility Owned by Seller), and (v) Seller provides Company with written notice that (aa) Seller is ready to declare the Commercial Operations Date and (bb) the Commercial Operations Date will occur within 24 hours (i.e., the next Day).

  • Commercial Operation means the condition of operation in which the complete equipment covered under the Contract is officially declared by the Owner to be available for continuous operation at different loads up to and including rated capacity. Such declaration by the Owner, however, shall not relieve or prejudice the Contractor of any of his obligations under the Contract.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Commence commercial operation means, with regard to a unit that serves a generator, to have begun to produce steam, gas, or other heated medium used to generate electricity for sale or use, including test generation subject to the following:

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Construction Completion Date means date of the completion of the Construction Period, which shall be at the expiry of a period of 24 (Twenty Four) months from the Compliance Date or such other date (with the consent of the Authority) by which the overall development of the Project is completed in accordance with the provisions of this Concession Agreement and when the Construction Completion Certificate is issued by Authority as per Article 14.1.

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Commercial Operations Date or "COD": The date on which Facility first achieves Commercial Operations.

  • Completion means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Initial Operation means the first integral operation of the complete equipment covered under the Contract with the sub-system and supporting equipment in service or available for service.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Tests on Completion means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Start Date means the first Milestone Start Date specified in Schedule B;