Advisory Milestones definition

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Advisory Milestones. [To include in Development Schedule otherset forth herein. In the event that the completion of the Transmission Interconnection Procedures, the execution of a Transmission Project Interconnection Agreement, or receipt of regulatory approvals materially affect a milestone set forth in this Appendix C, the Parties shall review the milestones (e.g., periodic project review meetings)and the Developer shall seek to amend the milestone(s), as necessary, pursuant to the terms of this Agreement. For purposes of these milestones, a milestone that are not determined to be on the critical path, but that will be monitored by the Developer and reported to NYISO.] [Example Milestones: • Interconnection studies (e.g. Optional Feasibility Study, System Impact Study, Facilities Study) • Siting activities (e.g. locating line routing, access roads, and substation site location options) • Environmental impact studies (relative to siting options) • Engineering (initial) • Permitting and regulatory activities (e.g. Certificate of Environmental Compatibility and Public Need) • Public outreach plan • Initiation of negotiation of key contracts and financing • Acquisition of all necessary approvals and authorizations of Governmental Authorities, including identification of all is required regulatory approvals • Closing of project financing • Completion of key contracts • Engineering (detailed) • Procurement of major equipment and materials • Environmental management & construction plan (for Article VII certification) • Acquisition of [all or %] required rights of way and property / demonstration of site control • Surveying and geotechnical assessment (relative to line and station layouts) • Execution, or filing of unexecuted version, of interconnection agreement • Engineering (to be completed) by the Developer may be completed by either LS Power or NYPA, as applicable; provided, however, completion of a milestone by either LS Power or NYPA shall not affect the obligations under Article 3.13 of the Agreement. • Delivery of major electrical equipment • Line and substation site work including milestones for foundations, towers, conductor stringing, equipment delivery and installation, substation controls and communication, security, etc. • Construction outage and restoration coordination plan • Completion, verification and testing • Operating and maintenance agreements and instructions • In-Service Date • Required Project In-Service Date] No. Milestone Description Responsible Party(ie...

Examples of Advisory Milestones in a sentence

If the suspension will impact the Transmission Developer’s ability to meet any Advisory Milestones or Critical Path Milestones in the Development Agreement, Transmission Developer shall notify the NYISO in accordance with the requirements in Article 3.3 of the Development Agreement.
The milestones for obtaining the required authorizations and approvals shall be included in the Development Schedule as Critical Path Milestones and Advisory Milestones, as designated by the Parties under Article 3.
Development Schedule shall mean the schedule of Critical Path Milestones and Advisory Milestones set forth in Appendix C to this Agreement.
The Developer shall demonstrate to the NYISO that it timely meets the following Critical Path Milestones and Advisory Milestones contained herein and that such milestones remain in good standing.
The Developer shall demonstrate to the NYISO that it timely meets the following Critical Path Milestones and Advisory Milestones and that such milestones remain in good standing.
The Designated Entity shall demonstrate to the NYISO that it timely meets the following Critical Path Milestones and Advisory Milestones and that such milestones remain in good standing.
Advisory Milestones shall mean the milestones set forth in the Development Schedule in Attachment C to this Agreement that are not Critical Path Milestones.
The milestones for obtaining the required authorizations and approvals shall be included in the Development Schedule as Critical Path Milestones and Advisory Milestones, as designated by the Parties under Article 3.3.
The Developer shall demonstrate to the NYISO that it timely meets the below Critical Path Milestones and Advisory Milestones contained herein and that such milestones remain in good standing.
Prior to executing and/or filing this Agreement with FERC, the NYISO and the Developer shall agree to the Critical Path Milestones and Advisory Milestones set forth in the Development Schedule in Appendix C to this Agreement for the development, construction, and operation of the Transmission Project SERVICE AGREEMENT NO.

More Definitions of Advisory Milestones

Advisory Milestones means the milestones set forth in the Development Schedule in Attachment C to this Agreement that are not Critical Path Milestones. Applicable Laws and Regulations shall mean: (i) all duly promulgated applicable federal, state and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders, permits and other duly authorized actions of any Governmental Authority, and (ii) all applicable requirements of the ISO Tariffs, ISO Procedures, and ISO Related Agreements. Applicable Reliability Organizations shall mean the NERC, the NPCC, and the NYSRC. Applicable Reliability Requirements shall mean the requirements, criteria, rules, standards, and guidelines, as they may be amended and modified and in effect from time to time, of: (i) the Calendar Day shall mean any day including Saturday, Sunday, or a federal holiday. Change of Control shall mean a change in ownership of more than 50% of the membership or ownership interests or other voting securities of the Developer to a third party in one or more related transactions, or any other transaction that has the effect of transferring control of the Developer to a third party. Confidential Information shall mean any information that is defined as confidential by Article 11.2. Critical Path Milestones shall mean the milestones identified as such in the Development Schedule in Attachment C to this Agreement that must be met for the Transmission Project to be constructed and operating by the Required Project In-Service Date. Developer shall have the meaning set forth in the introductory paragraph. Development Schedule shall mean the schedule of Critical Path Milestones and Advisory Milestones set forth in Appendix C to this Agreement. Distribution System shall mean the Transmission Owner’s facilities and equipment used to distribute electricity that are subject to FERC jurisdiction, and are subject to the NYISO’s

Advisory Milestones means the milestones set forth in the Development Schedule in Attachment C to this Agreement that are not Critical Path Milestones. Applicable Laws and Regulations shall mean: (i) all duly promulgated applicable federal, state and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders, permits and other duly authorized actions of any Governmental Authority, and (ii) all applicable requirements of the ISO Tariffs, ISO Procedures, and ISO Related Agreements. Applicable Reliability Organizations shall mean the NERC, the NPCC, and the NYSRC. Calendar Day shall mean any day including Saturday, Sunday, or a federal holiday. Change of Control shall mean a change in ownership of more than 50% of the membership or ownership interests or other voting securities of the Developer to a third party in one or more related transactions, or any other transaction that has the effect of transferring control of the Developer to a third party. Confidential Information shall mean any information that is defined as confidential by Article 11.2. Critical Path Milestones shall mean the milestones identified as such in the Development Schedule in Attachment C to this Agreement that must be met for the Transmission Project to be constructed and operating by the Required Project In-Service Date. Developer shall have the meaning set forth in the introductory paragraph. Development Schedule shall mean the schedule of Critical Path Milestones and Advisory Milestones set forth in Appendix C to this Agreement.

Advisory Milestones means the milestones set forth in the Development Schedule in Attachment C to this Agreement that are not Critical Path Milestones. Affected System Operator shall mean any Affected System Operator(s) identified in connection with the Transmission Project pursuant to Attachment P of the ISO OATT. Applicable Laws and Regulations shall mean: (i) all duly promulgated applicable federal, state and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders, permits and other duly authorized actions of any Governmental Authority, and (ii) all applicable requirements of the ISO Tariffs, ISO Procedures, and ISO Related Agreements. Applicable Reliability Organizations shall mean the NERC, the NPCC, and the NYSRC. Applicable Reliability Requirements shall mean the requirements, criteria, rules, standards, and guidelines, as they may be amended and modified and in effect from time to time, of: (i) the Applicable Reliability Organizations, (ii) the Connecting Transmission Owner(s), (iii) [to insert the name(s) of any other Transmission Owners or developers whose transmission facilities the NYISO has determined may be impacted by the Transmission Project], and (iv) any Affected System Operator; provided, however, that no Party shall waive its right to challenge the applicability or validity of any requirement, criteria, rule, standard, or guideline as applied to it in the context of this Agreement. Breach shall have the meaning set forth in Article 7.1 of this Agreement. Breaching Party shall mean a Party that is in Breach of this Agreement. Business Day shall mean Monday through Friday, excluding federal holidays. Calendar Day shall mean any day including Saturday, Sunday, or a federal holiday. Change of Control shall mean a change in ownership of more than 50% of the membership or ownership interests or other voting securities of the Developer to a third party in one or more related transactions, or any other transaction that has the effect of transferring control of the Developer to a third party. Confidential Information shall mean any information that is defined as confidential by Article 11.2. Connecting Transmission Owner shall be the Connecting Transmission Owner(s) identified in connection with the Transmission Project pursuant to Attachment P of the ISO OATT. Critical Path Milestones shall mean the milestones identified as such in the Development Schedule in Attachment C to this Agreement that must b...

Advisory Milestones. [To include in Development Schedule other milestones (e.g., periodic project review meetings) that are not determined to be on the critical path, but that will be monitored by the Developer and reported to NYISO.] [Example Milestones:

Advisory Milestones means the milestones set forth in the Development Schedule in Attachment C to this Agreement that are not Critical Path Milestones. Affected System Operator shall mean any Affected System Operator(s) identified in connection with the Designated Project pursuant to Attachment P of the ISO OATT. Applicable Laws and Regulations shall mean: (i) all duly promulgated applicable federal, state and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders, permits and other duly authorized actions of any Governmental Authority, and (ii) all applicable requirements of the ISO Tariffs, ISO Procedures, and ISO Related Agreements. Applicable Reliability Organizations shall mean the NERC, the NPCC, and the NYSRC. Calendar Day shall mean any day including Saturday, Sunday, or a federal holiday. SERVICE AGREEMENT NO. 2855 Change of Control shall mean a change in ownership of more than 50% of the membership or ownership interests or other voting securities of the Designated Entity to a third party in one or more related transactions, or any other transaction that has the effect of transferring control of the Designated Entity to a third party. Confidential Information shall mean any information that is defined as confidential by Article 11.2. Connecting Transmission Owner shall be the Connecting Transmission Owner(s) identified in connection with the Designated Project pursuant to Attachment P of the ISO OATT. Critical Path Milestones shall mean the milestones identified as such in the Development Schedule in Attachment C to this Agreement that must be met for the Designated Project to be constructed and operating by the Required Designated Project In-Service Date. Default shall mean the failure of a Party in Breach of this Agreement to cure such Breach in accordance with Article 7.2 of this Agreement. Designated Entity shall have the meaning set forth in the introductory paragraph. Designated Network Upgrade Facilities shall mean the Network Upgrade Facilities identified through the Transmission Interconnection Procedures for a Public Policy Transmission Project selected under Attachment Y to the ISO OATT; that meet the definition of upgrade under Section 31.6.4 of Attachment Y to the ISO OATT; and that are designated to the Connecting Transmission Owner or Affected Transmission Owner in accordance with Section 22.9.6 of Attachment P to the ISO OATT, as described in the Project Description set forth in Appendi...