Approved Change Order definition

Approved Change Order is defined in Section 1.5(f) below.
Sample 1Sample 2
Approved Change Order has the meaning given to it in Clause 2.9.
Sample 1Sample 2
Approved Change Order means any Change Order that has been approved, or that is deemed to be approved, pursuant to Section 3.3 of this Agreement.
Sample 1

Examples of Approved Change Order in a sentence

  • An Approved Change Order becomes binding upon City and Contractor when fully executed by both parties.

  • Approved Change Order amounts may be adjusted later to correct the impact of inaccurate labor cost components if the agreed upon labor cost components are determined to be inaccurate.

  • A Change Order will not become effective until approved in writing and signed by the District, hereinafter referred to as an "Approved Change Order." An approved Change Order signed by the Contractor is hereinafter referred to as an "Executed Change Order." Common Carrier: Everyone who offers to the public to carry persons, property, or messages, excepting only telegraphic messages, is a common carrier of whatever he thus offers to carry.

  • Approved Change Order Requests and Changes directed by a Field Order, including adjustments to Contract Sum and Contract Price, shall be incorporated into a Change Order for approval by the City.

  • Approved Change Order (CO) costs shall be included in the Pay Application corresponding to the month during which the CO was approved.

  • Force Account: Force Account work shall be undertaken only after receipt of an Approved Change Order, stating a maximum dollar amount (Stipulated Maximum Sum) beyond which no change work may be undertaken subject to amendment, for funding all costs of the Change Order as prescribed in Article 3.2.7.3 of the Contract.

  • Failure of the Contractor to submit a quotation in the timeframe or form specified by the Engineer shall limit the effect of any protest to an Approved Change Order as set forth in Section G4.09.

  • The Contract Sum shall also be adjusted by the amount of any unused Allowance that was specifically and expressly included in the original Contract Sum.7.2.11 Change Orders: Approved Change Order Requests and Changes directed by a Field Order, including adjustments to Contract Sum and Contract Price, shall be incorporated into a Change Order for approval by the City.

  • Access to agricultural extension and other technical assistance to assist women and poor households to improve the productivity of their agricultural activities.

  • A Change Order will not become effective until approved in writing and signed by the District, hereinafter referred to as an "Approved Change Order." An approved Change Order signed by the Contractor is hereinafter referred to as an "Executed Change Order." Common Carrier: One who holds itself out to the general public to transport property and passengers, intrastate, interstate or in foreign commerce, for compensation.


More Definitions of Approved Change Order

Approved Change Order means any Change Order required to comply with applicable law or contractual obligations of Seller, to account for weather conditions or the discovery of unknown conditions during construction, to correct or adjust for material errors or omissions in Modified Phase V A Plans and Specifications (the scope of any such Change Order shall be subject to the prior written approval of Purchaser, which approval shall not be unreasonably withheld or delayed) or which otherwise are approved in writing by Seller and the Purchaser.
Sample 1
Approved Change Order means a Seller Change Order approved or deemed approved by Buyer as provided herein, an Approved Buyer Change Order (as hereinafter defined), and subject to the terms of Section 19(d)(iv) any Change Orders required by any
Sample 1
Approved Change Order has the meaning set forth in Section 9.1. "Arbitration Notice" has the meaning set forth in Section 18.3(b)(i). "Automation System" means an automated system to be designed, manufactured, constructed and/or installed by ACRO for the Project. "Background Intellectual Property Rights" means HI-POWER'S Intellectual Property or ACRO'S Intellectual Property, as applicable, except for any Foreground Intellectual Property Rights. "Bailed Property" has the meaning set forth in Section 6.1(a). "Basic Purchase Order Terms" means, collectively, any one or more of the following terms specified by HI-POWER in a Purchase Order pursuant to Section 2.3: (a) an itemized list of the Equipment being purchased and sold under the Purchase Order; and the applicable Automated System the Equipment is a component of; (b) the price for each itemized Equipment; (c) the Services to be provided; (d) the price for such Services; (e) Guaranteed Milestones, if any; (f) the expected Delivery Date for the Equipment; (g) the Site where the Equipment are to be delivered, installed, and commissioned; (g) the total Price; and (h) the Payment Schedule. For the avoidance of doubt, the term "Basic Purchase Order Terms" do not include any general terms or conditions of any Purchase Order. "Business Day" means any day other than a Saturday, Sunday, or a United States of America Federal Reserve Bank holiday. "Change" means (i) any material addition to, deletion from or other modification to the quality, function, quantity, or method for performing the Work, including any such addition, deletion or other modification that requires a change in the Price, Payment Schedule, Guaranteed Milestone or (ii) any extension of the Payment Schedule, or any Guaranteed Milestone or increase in the Price. "Change in Law" means an amendment, modification or change of Applicable Law (including any such change that delays the issuance of any Governmental Approval) that: (i) is enacted, adopted, or promulgated after the Effective Date by a Governmental Authority; (ii) materially adversely affects the performance of the Work in accordance with a Project Schedule and that cannot be mitigated by the affected Party using commercially reasonable efforts; and (iii) requires a material variation from the underlying assumptions upon which the Technical Specifications have been used. Notwithstanding the foregoing, a "Change in Law" excludes any amendment to, modification of or change in Applicable Law: (a) relating to Taxes or ...
Sample 1

Related to Approved Change Order

  • Proposed Change Order (PCO means a document that informs Contractor of a proposed change in the Work and appropriately describes or otherwise documents such change including Contractor’s response of pricing for the proposed change.

  • Change Order means a written instrument signed by Owner and Contractor stating their agreement upon all of the following: (1) a change in the Work; (2) the amount of the adjustment in the Contract Sum, if any, and (3) the extent of the adjustment in the Contract Time, if any.

  • Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.

  • approved proposal means a proposal approved or determined under this Agreement;

  • Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:

  • Approved Vendor means a person who has been approved for inclusion on an

  • Major modification means any physical change in or change in the method of operation of a major stationary source that would result in a significant emissions increase of a regulated NSR pollutant and a significant net emissions increase of that pollutant from the major stationary source.

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Proposed Change has the meaning assigned to such term in Section 9.02(c).

  • Benchmark Replacement Conforming Changes means, with respect to any Benchmark Replacement, any technical, administrative or operational changes (including changes to the definition of “Base Rate,” the definition of “Interest Period,” timing and frequency of determining rates and making payments of interest and other administrative matters) that the Administrative Agent decides may be appropriate to reflect the adoption and implementation of such Benchmark Replacement and to permit the administration thereof by the Administrative Agent in a manner substantially consistent with market practice (or, if the Administrative Agent decides that adoption of any portion of such market practice is not administratively feasible or if the Administrative Agent determines that no market practice for the administration of the Benchmark Replacement exists, in such other manner of administration as the Administrative Agent decides is reasonably necessary in connection with the administration of this Agreement).

  • Project Proposal is the final and written description of the Project as described in Exhibit A, to be undertaken by Sub-recipient for which the Project Funds is granted and performance is required and monitored pursuant to this PFA.

  • Approved Project Budget means the most recent statement, approved by the FTA, of the costs of the Project, the maximum amount of Federal assistance for which the TJPA is currently eligible, the specific tasks (including specified contingencies) covered, and the estimated cost of each task.

  • The Work Order means the order placed by the Purchaser on the Supplier signed by the Purchaser including all attachments and appendices thereto and all documents incorporated by reference therein. The Work order shall be deemed as "Contract" appearing in the document.

  • Approved List means Securities followed by the Global Fundamental Research Group and tracked on the Approved List. Securities may be added, removed, or undergo periodic ratings changes.

  • Approved/Approval means the approval in writing.

  • Product Schedule means PTC’s standard order form entitled “PTC Product Schedule” (including all schedules, attachments and other document(s) specifically referenced therein) or such alternative order form as may be submitted by Customer and accepted by PTC, in each case that specifies (i) the Licensed Products and/or Services ordered; and (ii) for Licensed Products, the installation address (including the Designated Country) and the Licence Term.

  • Work Order means an individually negotiated document that is executed by both Parties and which authorizes a Project, if any, in an indefinite quantity Contract.

  • Indirect cost rate proposal means the documentation prepared by a governmental unit or subdivision thereof to substantiate its request for the establishment of an indirect cost rate.

  • Substantial modification means modification of a relevant source that results in a significant increase in emissions, excluding any change in emissions resulting from by-product recovery. It shall be a matter for the Party to decide whether a modification is substantial or not;

  • Scope Change means any change to the scope of a contract to accommodate a need not originally provided for in the contract and which may include the acquisition of additional deliverables or the extension of the term of the contract and which may require an adjustment to the contract price;

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • Approved Contractor means an “Approved Contractor” specified in the Key Details.

  • Material Modification means any modification to an Interconnection Request that has a material adverse effect on the cost or timing of Interconnection Studies related to, or any Network Upgrades or Local Upgrades needed to accommodate, any Interconnection Request with a later Queue Position.

  • Unilateral Change Order (ULCO means a Change Order issued by Owner without the complete agreement of Contractor, as to cost and/or time.

  • Permit modification means a revision to a Title V operating permit that cannot be accomplished under the provisions for administrative permit amendments found at rule 567—22.111(455B). A permit modification for purposes of the acid rain portion of the permit shall be governed by the regulations pertaining to acid rain found at rules 567—22.120(455B) to 567—22.147(455B). This definition of “permit modification” shall be used solely for purposes of this chapter governing Title V operating permits.

  • Technical Proposal means the Contractor’s Technical Proposal dated (Technical Proposal date).