Commissioning before Functional Completion definition

Commissioning before Functional Completion means those commissioning duties of the Owner and of the EPCM Contractor that shall take place before Functional Completion and which are described in the Owner’s Requirements and allocated to either the Owner or the EPCM Contractor;
Sample 1Sample 2
Commissioning before Functional Completion means those commissioning duties of the Owner and of the Contractor that shall take place before Functional Completion and which are described in the Owner’s Requirements and allocated to either the Owner or the Contractor; Compensation means the compensation which the Owner shall pay for performance of the Work in accordance with Appendix B – Compensation; Confidential Information means all information relating to the Work and any process or technology relating thereto, and information relating to the nature of the Contractor’s and the Owner’s business and affairs, which either party directly or indirectly receives or acquires from the other party, or the other party’s representative, either in writing or verbally, including information in the Contract, or through observation of the Owner’s Site, the Work Site, the Work or work performed by Other Contractors, except information falling into any one or more of the following categories: information which the receiving party can show was in its possession on a non-confidential basis before receipt or acquisition of the information from the other party; information which is lawfully in the public domain at the time of the receiving party’s receipt or acquisition of the information from the other party, other than from the Owner’s Requirements or through the process of proposal calls or performing the Work; information which, after the receiving party’s receipt or acquisition of the information from the other party, becomes part of the public domain through no act of the receiving party or of any third party under an obligation of confidence with respect to such information, but only after such information becomes part of the public domain; or information which, after receipt or acquisition of the information from the other party, is lawfully obtained by the receiving party from a third party, but only after such information is so received or acquired, and provided such third party is under no obligation of confidence with respect to such information. Construction Work means delivery, fabrication, assembly, construction, testing, commissioning and correction, including professional and technical personnel, labour, supervision, administration, materials, transportation, supplies, tools, equipment, and such other work and materials necessary to be performed or supplied to meet the requirements of the Contract, including any work which is not expressly described in the Contract but which is nevertheless necessary...
Sample 1
Commissioning before Functional Completion means those commissioning duties of the Owner and of the Contractor that shall take place before Functional Completion and which are described in the Owner’s Requirements and allocated to either the Owner or the Contractor;
Sample 1Sample 2

Examples of Commissioning before Functional Completion in a sentence

  • The duties of the Owner and of the EPCM Contractor in relation to Commissioning before Functional Completion and Commissioning after Functional Completion, together with the Milestones to be reached for commissioning, shall be performed as set out in the Owner’s Requirements.

  • The duties of the Owner and of the Contractor in relation to Commissioning before Functional Completion and Commissioning after Functional Completion, together with the Milestones to be reached for commissioning, are as set out in the Owner’s Requirements.

Related to Commissioning before Functional Completion

  • Commissioning means the process for determining the need for and for obtaining the supply of healthcare and related services by the Trust within available resources.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Commissioning Date means that date when construction of the contemplated Project is complete, and the Maintenance Term commences;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Commissioning test means tests applied to the Generating Facility, after completion of the construction of the Generating Facility, in order to verify that the Generating Facility may be released for Operation.

  • Commissioning Tests means all of the procedures and tests which, in accordance with the Reasonable and Prudent Standard, and in compliance with industry guidelines, practices and standards, are:

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Application Review Start Date means the later date of either the date on which the District issues its written notice that the Applicant has submitted a completed Application or the date on which the Comptroller issues its written notice that the Applicant has submitted a completed Application and as further identified in Section 2.3.A of this Agreement.

  • Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.

  • Penetration Testing means security testing in which assessors mimic real-world attacks to identify methods for circumventing the security features of an application, system, or network. (NIST SP 800-115)

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Final Completion Date means the date on which Final Completion occurs.

  • Subprojects means more than one such Subproject.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Pre-commissioning means the testing, checking, and any other required activity that may be specified in the Technical Requirements that are to be carried out by the Supplier in preparation for Commissioning of the System as provided in GCC Clause 26 (Installation).

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Start means the relevant Compounded Index value on the day falling the Relevant Number of Index Days prior to the first day of the relevant Interest Period.

  • Construction Phase Services means the coordination, implementation and execution of the Work required by this Agreement, which are further defined in Article 8.