Excuse for Nonperformance or Delayed Performance Clause Samples
POPULAR SAMPLE Copied 2 times
Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of subcontractors, Contractor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor has notified the DMH Executive Director or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the DMH Executive Director or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled “Termination for Convenience” in fixed price contracts and “Termination” in cost- reimbursement contracts.
Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of subcontractors, the Contractor shall not be in default by reason of any failure in performance of this Contract in accordance with its terms (including any failure by the Contractor to make progress in the prosecution of the work hereunder which endangers performance) if the Contractor has notified the MDFA within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or make progress, and if such failure arises out of causes similar to those set forth above, the Contractor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit the Contractor to meet the Contract requirements. Upon request of the Contractor, the MDFA shall ascertain the facts and extent of such failure, and, if the MDFA determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, the Contractor 's progress and performance would have met the terms of the Contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause of this Contract entitled “Termination for Convenience”. (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of subcontractors, Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Vendor has notified the MTC or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Vendor to meet the contract requirements. In such a case, MDOT may, upon the request of the Vendor, revise the delivery schedule accordingly.
Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of subcontractors, Contractor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor has notified the Agency Head or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its
Excuse for Nonperformance or Delayed Performance. The Contractor shall not be in default by reason of any failure in performance of this Contract in accordance with its terms (including any failure by the Contractor to make progress in the prosecution of the work hereunder which endangers such performance) if the Contractor has notified the MSPA within fifteen (1 S) days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather.
Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of sub-contractors, the Contractor shall not be in default by reason of any failure in performance of this Contract in accordance with its terms if the Contractor has notified the Contracting Officer within fifteen (15) days after the cause of the delay and the failure arises out of causes such as, acts of God, acts of the public enemy, acts of CUC and any other CUC entity in its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes or other labor disputes, freight embargo, or unusually severe weather. If the failure to perform is caused by the failure of a sub-contractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, the Contractor shall not be deemed to be in default, unless the supplies and/or services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit the Contractor to meet the Contract requirements. Upon request of the Contractor, the Contracting Officer shall ascertain the facts and extent of such failure, and if the Contracting Officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, the Contractor's progress and performance would have met the terms of this Contract, the delivery schedule shall be revised accordingly, subject to the rights of CUC under the "TERMINATION FOR CONVENIENCE" clause.