Facility Completion Date definition

Facility Completion Date means that date on which Seller conducts a complete performance test at the Facility in accordance with Appendix F hereto.
Sample 1Sample 2Sample 3
Facility Completion Date means the date Substantial Completion is achieved.
Sample 1Sample 2
Facility Completion Date means the date on which an Acceptance Certificate for any Facility which has been signed by the Contractor is counter-signed or deemed to be counter-signed by the Council in accordance with Clause 20;
Sample 1

Examples of Facility Completion Date in a sentence

  • For all tests after the Facility Completion Date, Seller and Department shall use commercially reasonable efforts to schedule such tests during periods in which Department has Dispatched the Facility to operate.

  • If the Facility Completion Date has not occurred by the target Facility Completion Date set forth in Appendix E, Department may require Seller to supply progress reports more frequently as reasonably determined necessary by the Department in its sole discretion.

  • Notwithstanding Article VII or any other provision of this Agreement, and assuming no intentional breach by Seller hereunder, this Article IV shall provide Department's exclusive remedy in the event Seller fails to schedule, deliver or provide all or part of the Contract Capacity or Energy or if the Facility fails to achieve the Guaranteed Maximum Heat Rate, Facility Completion Date, or a particular Rated Capacity.

  • In addition, to the extent that the Facility Completion Date is delayed as a result of a Delivery Event which prevents testing of the Facility, then the Facility Completion Date shall be extended, in each case by the period of such Delivery Event.

  • From the date of execution of this Agreement through the Facility Completion Date, Seller shall supply progress reports to Department monthly, within fifteen (15) Days after the end of each month, describing progress toward completion of the Major Milestones.

  • Prior to the Base Term Commencement Date, Construction Agent may exercise the rights set forth at Section 12.1 of the Lease subject to the terms and conditions set forth in that section; provided that no such test, challenge, appeal, proceeding, waiver, extension, forbearance or noncompliance shall result in a delay in the Facility Completion Date beyond the Outside Completion Date.

  • A performance test shall be conducted upon the Facility Completion Date.

  • The Parties agree that Department's actual damages in the event Facility fails to achieve a particular availability or heat rate or Facility Completion Date would be extremely difficult or impracticable to determine and that, after negotiation, the Parties have agreed that the liquidated amounts set forth in Sections 4.01, 4.02 and 4.03 are a reasonable estimate of the damages that Department would incur as a result of such failures and delays.

  • Upon the Facility Completion Date, the Seller shall perform a Performance Test in accordance with this Appendix F to determine the Rated Capacity as described in Section 2.02 (c) of this Agreement, and to determine the Net Plant Heat Rate as described in Section 4.02 (b) of this Agreement.

  • No sales, use, excise, transfer or other similar tax, fee or imposition shall result from the sale, transfer, purchase of or holding title to the Leased Property, except such taxes, fees or impositions that will have been paid in full on or prior to the Facility Completion Date, with respect to the Site and Facility, and which are in each case described or provided for in the Project Budget, or that may be payable on the termination of the Lease.


More Definitions of Facility Completion Date

Facility Completion Date means December 31, 1996.
Sample 1
Facility Completion Date means, with respect to any Facility, a date no later than twenty four (24) months after Lessee leases the Property on which such Facility is to be built.
Sample 1
Facility Completion Date with respect to each Facility, the earlier to occur of (i) Completion of such Facility, (ii) the date which is 12 months after the Facility Commencement Date for such Facility, and (iii) the last day of the Construction Period.
Sample 1
Facility Completion Date means the date on which Facility Completion has occurred and the Company is ready to commence Local GAC Services.
Sample 1
Facility Completion Date means, for a Facility, the date when all criteria for Facility Completion that have not been waived have been satisfied for such Facility as certified by the Independent Certifier in accordance with Schedule 2 [Design and Construction Protocols];
Sample 1

Related to Facility Completion Date

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion Date means the date on which Final Completion occurs.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Commercial Operations Date or "COD": The date on which Facility first achieves Commercial Operations.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Increased Facility Closing Date any Business Day designated as such in an Increased Facility Activation Notice.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Loan Commencement Date means, with respect to each Growth Capital Loan: (a) the first day of the first full calendar month following the Borrowing Date of such Loan if such Borrowing Date is not the first day of a month; or (b) the same day as the Borrowing Date if the Borrowing Date is the first day of a month.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Commercial Operation means the condition of operation in which the complete equipment covered under the Contract is officially declared by the Owner to be available for continuous operation at different loads up to and including rated capacity. Such declaration by the Owner, however, shall not relieve or prejudice the Contractor of any of his obligations under the Contract.

  • Incremental Facility Closing Date has the meaning set forth in Section 2.14(d).

  • Improvement completion assurance means a surety bond, letter of credit,