Force Majeure Report definition

Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;
Sample 1Sample 2Sample 3
Force Majeure Report has the meaning ascribed to it in Clause 17.1;
Sample 1Sample 2Sample 3
Force Majeure Report has the meaning ascribed to it in Clause 17.1; "Full Opening Date" means the date on which revenue-earning passenger services first commence on the CCOS and which connect to and from both of:
Sample 1Sample 2Sample 3

Examples of Force Majeure Report in a sentence

  • In addition to the Force Majeure Report, Buyer may request, and Seller shall promptly provide, such related information pertaining to the Force Majeure Report as may be reasonable.


More Definitions of Force Majeure Report

Force Majeure Report. Has the meaning set out in Master TCs Section 31.4 (MTA Notice of Force Majeure Event). 261. MTA Funded Amounts Has the meaning set out in Master TCs Section 9.5.1 (MTA Funded Amounts). 262. MTA Privacy Policy The applicable privacy policy of the MTA.
Sample 1
Force Majeure Report has the meaning ascribed to it in Clause 17.1; "Initial Indexation Factor" means (RPI2017/RPI2016)2 where: RPI2017 is the RPI published or determined with respect to the month of November 2017; and RPI2016 is the RPI published or determined with respect to the month of November 2016;
Sample 1

Related to Force Majeure Report

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Event means an event beyond the affected party’s reasonable control, including (without limitation) accidents, severe weather events, acts of God, actions of any government agency, epidemic, pandemic, acts of terrorism, or the stability or availability of the Internet or a portion thereof.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Event of Force Majeure means one of the following events:

  • Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.

  • Service Interruption means the cessation of electricity supply to an ICP for a period of 1 minute or longer, other than by reason of De-energisation of that ICP: