Initial Commercial Operation Test definition

Initial Commercial Operation Test means tests performed in accordance with the testing procedures, requirements, and protocols set forth in Exhibit C in advance of Commercial Operation.
Sample 1Sample 2Sample 3
Initial Commercial Operation Test means, the testing procedures, requirements, and protocols set forth in Appendix 7.
Sample 1Sample 2Sample 3
Initial Commercial Operation Test means, for Demand Response Projects only, the demonstration described in Section 5.03.
Sample 1Sample 2

Examples of Initial Commercial Operation Test in a sentence

  • The Initial Commercial Operation Test shall verify the Contract Capacity for purposes of calculating the Total Compensation Amount and shall be deemed an Owner Initiated Test.

  • The contract power capacity of the Project shall be equal to [number to be inserted] MW (“Contract Capacity”), as confirmed at the Initial Commercial Operation Test and reaffirmed through Performance Testing.

  • Such Initial Commercial Operation Test shall be scheduled and conducted in accordance with Appendix 7.

  • At least thirty (30) days prior to the Expected Initial Delivery Date, Seller shall schedule and complete an Initial Commercial Operation Test for each Storage Unit.

  • At least thirty (30) days before the target Commercial Operation Date, Owner shall schedule and complete an Initial Commercial Operation Test, which test shall be conducted using the procedures set forth in Exhibit C.

  • At least thirty (30) Business Days before the target Commercial Operation Date, Owner shall schedule and complete an Initial Commercial Operation Test, which test shall be conducted using the procedures set forth in Exhibit C.

  • The contract power capacity of the Project shall be equal to [●] MW (“Contract Capacity”), as confirmed at the Initial Commercial Operation Test and reaffirmed through Performance Testing.

  • At least thirty (30) Calendar Days before the target Commercial Operation Date, Owner shall schedule and complete an Initial Commercial Operation Test, which test shall be conducted using the procedures set forth in Exhibit C.

  • The Parties shall use the same instrumentation and metering as was used in the Initial Commercial Operation Test, unless the Parties otherwise agree in writing.

  • The judgment of Developer in the expenditure of funds for Association expenses shall be final and without liability to the Developer so long as such judgment is exercised in good faith.


More Definitions of Initial Commercial Operation Test

Initial Commercial Operation Test means the demonstration described in Section 5.03.
Sample 1Sample 2
Initial Commercial Operation Test or “ICOT” means, the testing procedures, requirements, and protocols set forth in Appendix 7.
Sample 1Sample 2
Initial Commercial Operation Test means tests performed in accordance with the testing procedures, requirements, and protocols set forth in Exhibit O in advance of Commercial Operation.
Sample 1
Initial Commercial Operation Test means, the testing procedures, requirements, and protocols set forth in Exhibit C.
Sample 1

Related to Initial Commercial Operation Test

  • Commercial Operation means the condition of operation in which the complete equipment covered under the Contract is officially declared by the Owner to be available for continuous operation at different loads up to and including rated capacity. Such declaration by the Owner, however, shall not relieve or prejudice the Contractor of any of his obligations under the Contract.

  • Commercial Operations Upon satisfaction of the following conditions, the Facility shall be considered to have achieved Commercial Operations on the Day specified in Seller's written notice described below: (i) the Acceptance Test has been passed, (ii) all generating units have passed Control System Acceptance Tests, (iii) the Transfer Date has occurred, (iv) Seller has (1) provided to Company the Required Models (as defined in Section 6(a) (Seller's Obligation to Provide Models) of Attachment B (Facility Owned by Seller)) in the form of Source Code, (2) placed the current version of the Source Code for the Required Models with the Source Code Escrow Agent as required in Section 6(b)(i)(A) (Establishment of Source Code Escrow) of Attachment B (Facility Owned by Seller), or (3) if Seller is unable to arrange for the placement of the appropriate Source Code into the Source Code Escrow account, placed the required funds with the Monetary Escrow Agent as required in Section 6(b)(ii)(A) (Establishment of Monetary Escrow) of Attachment B (Facility Owned by Seller), and (v) Seller provides Company with written notice that (aa) Seller is ready to declare the Commercial Operations Date and (bb) the Commercial Operations Date will occur within 24 hours (i.e., the next Day).

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Commence commercial operation means, with regard to a unit that serves a generator, to have begun to produce steam, gas, or other heated medium used to generate electricity for sale or use, including test generation subject to the following:

  • Commercial Operations Date or "COD": The date on which Facility first achieves Commercial Operations.

  • Initial Operation means the first integral operation of the complete equipment covered under the Contract with the sub-system and supporting equipment in service or available for service.

  • Date of Commercial Operation means the date on which the (nuclear or non-nuclear) power plant has successfully passed all performance and operational tests required by the end customer for commercial operation. In all other cases the warranty shall apply for twenty-four (24) months from delivery of the goods or performance of the services, or such longer period of time as customarily provided by Supplier, plus delays such as those due to non-conforming goods and services. The warranties shall apply to Buyer, its successors, assigns and the users of goods and services covered by this Order.

  • Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.

  • Scheduled Commercial Operation Date shall have the meaning ascribed to it in Clause 5.4.1;

  • Guaranteed Commercial Operation Date has the meaning set forth in Section 3.9(c)(i).

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Operational Acceptance Tests means the tests specified in the Technical Requirements and Agreed Project Plan to be carried out to ascertain whether the System, or a specified Sub system, is able to attain the functional and performance requirements specified in the Technical Requirements and Agreed Project Plan, in accordance with the provisions of GCC Clause 27.2 (Operational Acceptance Test).

  • Initial compliance period means the three-year compliance period that begins January 1, 1993, except for the MCLs for dichloromethane, 1,2,4-trichlorobenzene, 1,1,2-trichloroethane, benzo(a)pyrene, dalapon, di(2-ethylhexyl)adipate, di(2-ethyl- hexyl)phthalate, dinoseb, diquat, endothall, endrin, glyphosate, hexachlorobenzene, hexachlorocyclopentadiene, oxamyl, picloram, simazine, 2,3,7,8-TCDD, antimony, beryllium, cyanide, nickel, and thallium, as they apply to a supplier whose system has fewer than 150 service connections, for which it means the three-year compliance period that began on January 1, 1996.

  • Percolation test means a subsurface soil test at the depth of a proposed absorption system or similar component of an OWTS to determine the water absorption capability of the soil, the results of which are normally expressed as the rate at which one inch of water is absorbed. The rate is expressed in minutes per inch.

  • Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.

  • site development plan means a dimensioned plan drawn to scale that indicates details of the proposed land development, including the site layout, positioning of buildings and structures, property access, building designs and landscaping;

  • Sales assessment ratio studies means sales assessment ratio studies

  • Final Completion Date means the date on which Final Completion occurs.

  • Commissioning test means tests applied to a distributed generation facility by the applicant after construction is completed to verify that the facility does not create adverse system impacts and performs to the submitted specifications. At a minimum, the scope of the commissioning tests performed shall include the commissioning test specified in Institute of Electrical and Electronics Engineers, Inc. (IEEE) Standard 1547 Section 5.4 "Commissioning tests".

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Initial Development Plan has the meaning set forth in Section 3.2(b).

  • Commercial Development Plan means the written commercialization plan attached as Appendix E.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Normal operation means all periods of operation except start-up and shutdown operations and maintenance of equipment;

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.