Initial Tenant Finish definition

Initial Tenant Finish means the Premises in its as-is condition as modified by all work, if any, performed by Landlord at its expense prior to the Commencement Date in accordance with the Work Letter. Except as provided in the Work Letter, Landlord has no obligation for the completion or remodeling of the Premises, and Tenant accepts the Premises in its "as is" condition on the Commencement Date. If Landlord is delayed in delivering the Premises to Tenant in accordance with the Work Letter then the Commencement Date will be postponed to the date Landlord delivers the Premises to Tenant. If delivery is on other than the first day of the month, then the Commencement Date will be the first day of the month following the delivery date but all provisions hereof, including Tenant's obligation to pay Rent (prorated for a partial month), will be in effect as of the delivery date. The postponement of Tenant's obligation to pay Rent is in full settlement of all claims which Tenant may otherwise have by reason of such delay. If the Commencement Date is delayed, the Expiration Date shall be extended so that the Term will continue for the full period set forth in Section 1.3. As soon as the Term commences, Landlord and Tenant agree to execute a commencement agreement in the form attached as EXHIBIT C, setting forth the exact Commencement Date and Expiration Date.
Sample 1Sample 2
Initial Tenant Finish means the Premises in its as is condition as modified by all work, if any, performed by Landlord at its expense in accordance with the Work Letter. Except as provided in the Work Letter, Landlord has no obligation for the completion or remodeling of the Premises, and Tenant accepts the Premises in its "as is" condition upon delivery in accordance with the Work Letter. If Landlord is delayed in delivering the Premises to Tenant in accordance with the Work Letter beyond the Commencement Date, then the Commencement Date will be postponed to the date Landlord delivers the Premises to Tenant. If delivery is on other than the first day of the month, then the Commencement Date will be the first day of the month following the delivery date but all provisions hereof, including Tenant's obligation to pay Rent (prorated for a partial month), will be in effect as of the delivery date. The postponement of Tenant's obligation to pay Rent is in full settlement of all claims which Tenant may otherwise have by reason of such delay. If the Commencement Date is delayed, the Expiration Date shall be extended so that the Term will continue for the full period set forth in Section 1.3. As soon as the Term commences, Landlord and Tenant agree to execute a commencement agreement in the form attached as Exhibit D, setting forth the exact Commencement Date and Expiration Date and the date the Premises were delivered Ready for Occupancy in accordance with the Work Letter. In accordance with the Work Letter, upon notice from Landlord that the Premises have been substantially completed in accordance with the Work Letter (which completion is currently estimated to be on or about September 1, 1999), Tenant may occupy the Premises from the date of notice of substantial completion until January 1, 2000 for purposes of installing its furniture, fixtures and equipment and conducting its business. During such period, all terms of the Lease, except for the payment of Base Rent and Tenant's Pro Rata Share of increases in Operating Expenses, shall be in effect with regard to Tenant's occupancy thereof.
Sample 1
Initial Tenant Finish means the Premises in its as-is condition as modified by all work, if any, performed by Landlord at its expense prior to the Commencement Date in accordance with the Work Letter. Except as provided in the Work Letter, Landlord has no obligation for the completion or remodeling of the Premises, and Tenant accepts the Premises in its “as is” condition on the Commencement Date. If Landlord is delayed in delivering the Premises to Tenant in accordance with the Work Letter or due to the failure of a prior occupant to vacate, then the Commencement Date will be postponed to the Deemed Delivery Date. If the Deemed Delivery Date is a date other than the first day of the month, then the Commencement Date will be the first day of the month following the delivery date but all provisions hereof, excluding Tenant’s obligation to pay Rent will be in effect as of the actual delivery date and Tenant’s obligation to pay Rent (prorated for a partial month), will be in effect as of the Deemed Delivery Date. The postponement of Tenant’s obligation to pay Rent is in full settlement of all claims which Tenant may otherwise have by reason of such delay. If the Commencement Date is delayed, the Expiration Date shall be extended so that the Term will continue for the full period set forth in Section 1.3. As soon as the Term commences, Landlord and Tenant agree to execute a commencement agreement in the form attached as Exhibit D, setting forth the exact Commencement Date and Expiration Date.
Sample 1

Examples of Initial Tenant Finish in a sentence

  • All such work relating to Alterations shall be performed in a good and workmanlike manner, using new materials and equipment at least equal in quality to the Initial Tenant Finish.

  • Tenant shall pay for all work done on the Premises by Tenant or at its request (other than the Initial Tenant Finish) of a character which may result in liens on Landlord's or Tenant's interest and Tenant will keep the Premises free of all construction liens, and other liens on account of such work.

  • Except with regard to Initial Tenant Finish, Landlord has no obligation for the completion or remodeling of the Premises, and Tenant accepts the Premises in its “as is” condition on the Commencement Date.

  • Tenant shall pay for all work done on the Premises by Tenant or at its request (other than the Initial Tenant Finish) of a character which may result in liens on Landlord's or Tenant's interest and Tenant will keep the Premises free of all mechanics' liens, and other liens on account of such work.

  • If during the first year of the Initial Term, Tenant discovers a defect in the Initial Tenant Finish that (a) was not reasonably discoverable during the Inspection; and (b) was not caused by the actions of Tenant or anyone acting by, through or under Tenant (each a “Latent Defect”), provided that Landlord is notified by Tenant of the Latent Defect within, five (5) days of Tenant's discovery thereof, Landlord shall correct such Latent Defect to the Parties reasonable satisfaction.

  • Notwithstanding any provision in this Lease to the contrary, the Commencement Date and Tenant's Rent obligations will not be delayed or extended by any delay in completion of the Initial Tenant Finish (as defined in Article 5, below) unless such delay is caused by “Net Landlord Delay”.

  • Landlord shall notify Tenant of the pending substantial completion of the Initial Tenant Finish; whereupon the Parties shall schedule an inspection of the Premises to be conducted prior to the Commencement Date, at which Tenant and Landlord shall inspect only the components of the Initial Tenant Finish (the “Inspection”) and shall mutually agree upon items of work from the Initial Tenant Finish that are not satisfactorily completed (The “Punch List Items”).

  • The term “Landlord Delay” means any delay, other than due to Force Majeure Events), Tenant Delay or completion of Punch List items, caused by solely by Landlord's failure to substantially complete the Initial Tenant Finish.

  • All such work relating to Alterations shall be performed in a good and workmanlike manner, using materials and equipment at least equal in quality to the Initial Tenant Finish, and shall comply with the rules and regulations relating to construction activities in the Building promulgated from time to time by Landlord for the Building.

  • Tenant shall maintain throughout the Term "all risk" or "multi-peril" insurance for the full replacement cost of Tenant's property and betterments in the Premises, including tenant finish in excess of the Initial Tenant Finish.


More Definitions of Initial Tenant Finish

Initial Tenant Finish means the Premises in its as-is condition as modified by all work, if any, performed by Landlord at its expense prior to the Commencement Date in accordance herewith. Except as provided herein, Landlord has no obligation for the completion or remodeling of the Premises, and Xxxxxx accepts the Premises in its "as is" condition on the Commencement Date. The Initial Lease Term shall commence on February 1, 2000, regardless if the Finish Work is completed.
Sample 1
Initial Tenant Finish means the Premises in its as-is condition as modified by all work, if any, performed by Landlord at its expense prior to the Commencement Date in accordance with the Work Letter. Except as provided in the Work Letter, Landlord has no obligation for the completion or remodeling of the Premises, and Tenant accepts the Premises in its "as is" condition on the Delivery Date. If delivery is on other than the first day of the month, then the Commencement Date will be the first day of the month following the delivery date but all provisions hereof, including Tenant's obligation to pay Rent (prorated for a partial month), will be in effect as of the delivery date. The postponement of Tenant's obligation to pay Rent is in full settlement of all claims which Tenant may otherwise have by reason of such delay. If the Commencement Date is delayed, the Expiration Date shall be extended so that the Term will continue for the full period set forth in Section 1.3. As soon as the Term commences, Landlord and Tenant agree to execute a commencement agreement in the form attached as Exhibit C, setting forth the exact Commencement Date and Expiration Date.
Sample 1
Initial Tenant Finish means the Premises in its as-is condition as modified by all work, if any, performed by Landlord at its expense prior to the Commencement Date in accordance with the Work Letter or paid for by Landlord from the Allowance in accordance with the Work Letter, as applicable. Except as provided in the Work Letter, Landlord has no obligation for the completion or remodeling of the Premises, and Tenant accepts the Premises in its "as is" condition on the Commencement Date, subject to the provisions of the Work Letter. If Landlord is delayed in delivering the Premises or a portion thereof to Tenant in accordance with the Work Letter, the provisions of the Work Letter shall control delivery of such space, the commencement of Rent and the determination of the Commencement Date. The postponement of Tenant's obligation to pay Rent is in full settlement of all claims which Tenant may otherwise have by reason of such delay. If the Commencement Date is delayed in accordance with the Work Letter, the Expiration Date shall be extended so that the Term will continue for the full period set forth in Section 1.3. As soon as the Term commences, Landlord and Tenant agree to execute a commencement agreement in the form attached as Exhibit D, setting forth the exact Commencement Date and Expiration Date.
Sample 1

Related to Initial Tenant Finish

  • Customer Premises means premises owned, controlled or occupied by the Customer which are made available for use by the Supplier or its Sub-Contractors for the provision of the Goods and/or Services (or any of them);

  • Parking space leasing data means the following government data on an application for, or lease of, a parking space: residence address, home telephone number, beginning and ending work hours, place of employment, location of parking space, and work telephone number.

  • Tenant Improvements Defined in Exhibit B, if any.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • residential premises means a house, building, structure, shelter, or mobile home, or portion thereof, used as a dwelling, home, residence, or living place by 1 or more human beings. “Residential premises” includes an apartment unit, a boardinghouse, a rooming house, a mobile home, a mobile home space, and a single or multiple family dwelling, but does not include a hotel, a motel, motor home, or other tourist accommodation, when used as a temporary accommodation for guests or tourists, or premises used as the principal place of residence of the owner and rented occasionally during temporary absences including vacation or sabbatical leave.

  • Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • bicycle parking space – visitor means an area that is equipped with a bicycle rack for the purpose of parking and securing bicycles, and:

  • Storage Space means a space where goods of non-hazardous nature are stored and includes cold storage and banking safe vaults;

  • Customer Premises Equipment or "CPE" means equipment employed on the premises of a Person other than a Carrier to originate, route or terminate Telecommunications (e.g., a telephone, PBX, modem pool, etc.).

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Leasehold Improvements means all buildings, structures, improvements and fixtures located on any Leased Real Property which are owned by any Group Company, regardless of whether title to such buildings, structures, improvements or fixtures are subject to reversion to the landlord or other third party upon the expiration or termination of the Lease for such Leased Real Property.

  • Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and

  • Parking Space The County shall attempt to provide adequate free parking facilities for employees within a reasonable distance of their work locations.

  • industrial premises means any place or premises (not being a private dwelling house), including the precincts thereof, in which or in any part of which any industry, trade, business, occupation or manufacturing is being ordinarily carried on with or without the aid of power and includes a godown attached thereto;

  • Major Tenants has the meaning ascribed to such term in Section 7.2.

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • bicycle parking space – occupant means an area that is equipped with a bicycle rack, locker or bicycle stacker for the purpose of parking and securing bicycles, and:

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • On-premises sign means a sign advertising activities conducted or maintained on the property on which it is located. The boundary of the property shall be as determined by tax rolls, deed registrations, and apparent land use delineations. If a sign consists principally of brand name or trade name advertising and the product or service advertised is only incidental to the principal activity conducted or maintained on the property, or if the sign brings rental income to the property owner or sign owner, it shall be considered the business of outdoor advertising and not an on-premises sign. On-premises sign does not include a sign on a narrow strip of land contiguous to the advertised activity, or a sign on an easement on adjacent property, when the purpose is clearly to circumvent the intent of this act.

  • School premises means either of the following:

  • Grave space means a space of ground in a cemetery that is used or intended to be used for an in-ground burial.

  • Subleased Premises means all that portion of the Leased Premises referred to as airport lot as outlined on the site diagram attached as Schedule "A" to this Sublease; and

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • bicycle parking space means an area used for parking or storing a bicycle;

  • Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements in the form of Exhibit D attached hereto.

  • Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.