Lender Direct Agreement definition

Lender Direct Agreement means a direct agreement entered into between the Lender, the Project Company and the O&M Contractor substantially in the form specified in Schedule 7 (Form of Lender Direct Agreement) or any replacement thereof.
View Source
Lender Direct Agreement means agreement between the Parties and the Lenders in the form set out in Attachment G, subject to such amendments thereto as the Lenders may reasonably require and as are agreed by the Employer.
View Source
Lender Direct Agreement means this lender’s direct agreement.
View Source

Examples of Lender Direct Agreement in a sentence

  • The rights of the Contractor to terminate the Contract under this Sub-Clause 8.11 shall be subject to the terms of the Lender Direct Agreement.

  • Without prejudice to the generality of any other provision of the Contract, the Employer shall be entitled to assign and/or transfer all and any rights acquired on the basis of this sub-Clause to any Lender or pursuant to the terms of the Lender Direct Agreement.

  • The rights of the Contractor to terminate the Contract under this sub-clause 19.6 shall be subject to the terms of the Lender Direct Agreement.

  • The Contractor hereby agrees that the Employer's rights and obligations, title and interest resulting from the Contract (or any part thereof) may be assigned and transferred to any Lender without the consent of the Contractor and otherwise transferred as described in the Lender Direct Agreement.

  • The Contractor shall from time to time enter into other agreements, substantially in the same form as the Lender Direct Agreement, subject to such amendments thereto as the Lenders may reasonably require and as are agreed by the Employer for the purpose of refinancing or the further financing of the Works or the Equipment or any part thereof.

  • If identified as applicable in the Key Information Table, the O&M Contractor shall no later than ten (10) Business Days of the request by the Project Company, enter into and deliver to the Project Company a Lender Direct Agreement with such amendments as the Project Company or Lender may reasonably request and agree with the O&M Contractor, provided that in no event shall any changes be made that could materially alter the scope of the obligations and liabilities of the O&M Contractor under this Agreement.

  • If identified as applicable in the Key Information Table, the Supplier shall not later than ten (10) Business Days after the Project Company's request, enter into and deliver to the Project Company a Lender Direct Agreement with such amendments as the Project Company or Lender may reasonably request and agree with the Supplier, provided that in no event shall any changes be made that could materially alter the scope of the Supplier's obligations and liabilities under this Agreement.

  • Delay Liquidated Damages Cap4 12.4 [●] Commercial Operation Longstop Date 12.5 [●] Minimum Guaranteed Capacity 15.2 [●] Default Rate 23.1(f) [●] Termination Fee 26.3 [●] Maximum Liability 24.1(a)(vi) [●] Cost or Savings Threshold 1.1 [●] Governing Law5 37.15 [●] Mediation Rules 38.2 [●] Expert Appointing Authority6 38.3(c) [●] Arbitration Language 38.4(b) [●] Arbitration Seat7 38.4(c) [●] Lender Direct Agreement 4.4(a) [Applicable] [Not Applicable].

  • It is anticipated the certain Material Agreements, including the Lender Direct Agreement, will be completed following closing.

  • Delay Liquidated Damages Cap4 12.4 [●] Commercial Operation Longstop Date 12.5 [●] Minimum Guaranteed Capacity 15.2 [●] Default Rate 23.1(f) [●] Termination Fee 26.3 [●] Maximum Liability 24.1(a)(vi) [●] Cost or Savings Threshold 1.1 [●] Governing Law5 37.14 [●] Mediation Rules 38.2 [●] Expert Appointing Authority6 38.3(c) [●] Arbitration Language 38.4(b) [●] Arbitration Seat7 38.4(c) [●] Lender Direct Agreement 4.4(a) [Applicable] [Not Applicable].

Related to Lender Direct Agreement

  • Co-Lender Agreement With respect to any Loan Combination, the co-lender agreement, intercreditor agreement, agreement among noteholders or similar agreement, dated as of the date set forth in the Loan Combination Table under the column heading “Date of Co-Lender Agreement” and governing the relative rights of the holders of the related Mortgage Loan and Companion Loan(s), as the same may be amended, restated or otherwise modified from time to time in accordance with the terms thereof. A Co-Lender Agreement exists with respect to each Loan Combination as of the Closing Date.

  • DIP Credit Agreement means the credit agreement with respect to the DIP Facility.

  • Senior Credit Agreement means that Credit Agreement dated as of December 1, 2006 (as amended, supplemented or otherwise modified from time to time), among the Issuer, Holdings, IV, Holdings V, Holdings III, each lender from time to time party thereto and the Administrative Agent.

  • U.S. Credit Agreement means that certain credit agreement dated as of even date herewith by and among the U.S. Borrower, as borrower, the lenders party thereto, as lenders, and the U.S. Administrative Agent, as administrative agent.

  • Senior Secured Credit Agreement means that certain Credit Agreement, dated as of September 27, 2018, among the Borrowers, the lenders from time to time party thereto, JPMCB as administrative agent, JPMCB as collateral agent, and the other parties thereto, as amended, restated, amended, restated, extended, supplemented, refinanced or otherwise modified from time to time.