Landlord Default shall have the meaning given such term in Article 14.
Seller Default has the meaning set forth in Section 12.1.
Lease Event of Default shall have the meaning specified in Section 17.1 of the Lease.
Lease Default means any event or condition which, with the lapse of time or the giving of notice, or both, would constitute a Lease Event of Default.
Buyer Default refers to nonpayment of the Xxxxxxx Money in accordance with the provisions of this Agreement (including nonpayment or dishonor of any check delivered for the Xxxxxxx Money) and/or the failure of this transaction to close due to nonperformance, breach and/or default with respect to the Buyer’s obligation(s) under this Agreement. In the event of a Buyer Default, the following provisions shall apply:
O & M Default means any default on the part of the Power Producer for a continuous period of ninety (90) days to (i) operate and/or (ii) maintain (in accordance with Prudent Utility Practices), the Project at all times.
Customer Default has the meaning set out in clause 8.3.
Lender Default means (a) the refusal or failure (which has not been cured) of a Lender to make available its portion of any Borrowing or to fund its portion of any Unpaid Drawing under Section 3.4 that it is required to make hereunder, (b) a Lender having notified the Administrative Agent and/or the Borrower that it does not intend to comply with its funding obligations under this Agreement or has made a public statement to that effect with respect to its funding obligations under this Agreement, (c) a Lender has failed to confirm (within one Business Day after a request for such confirmation is received by such Lender) in a manner reasonably satisfactory to the Administrative Agent, the Borrower and, in the case of a Revolving Credit Lender, each Revolving Letter of Credit Issuer that it will comply with its funding obligations under this Agreement, (d) a Lender being deemed insolvent or becoming the subject of a bankruptcy or insolvency proceeding or has admitted in writing that it is insolvent; provided that a Lender Default shall not be deemed to have occurred solely by virtue of the ownership or acquisition of any Stock in the applicable Lender or any direct or indirect parent company thereof by a Governmental Authority so long as such ownership interest does not result in or provide the applicable Lender with immunity from the jurisdiction of courts within the United States or from the enforcement of judgments or writs of attachment on its assets or permit the applicable Lender (or such Governmental Authority) to reject, repudiate, disavow or disaffirm any contracts or agreements made with the applicable Lender, or (e) a Lender that has, or has a direct or indirect parent company that has, become the subject of a Bail-In Action.
Default means any event which is, or after notice or passage of time or both would be, an Event of Default.
Owner Event of Default shall have the meaning set forth in Section 18.3.
Swap Default Any of the circumstances constituting an “Event of Default” under the Swap Agreement.
Minor Default means any Event of Default that is not a Major Default.
Purchaser Default has the meaning set forth in Section 11.2(a).
Event of Default has the meaning specified in Section 8.01.
Forbearance Default means any of: (A) the occurrence of any Default or Event of Default other than the Specified Defaults, (B) the failure of Borrower or any other Designated Company to timely and strictly comply with any term, condition, covenant, agreement or other obligation set forth in this Agreement, (C) the failure of any representation or warranty made by Borrower or any other Designated Company under or in connection with this Agreement to be true and complete in all material respects as of the date when made or any other material breach of any such representation or warranty, (D) the taking of any action by Borrower or any other Designated Company to in any way repudiate or assert a defense to any Obligation under the Credit Agreement, this Agreement or any of the other Loan Documents or the assertion of any claim or cause of action against Administrative Agent, Co-Administrative Agent or any Lender relating in any way thereto, (E) the date on which Administrative Agent, in its sole discretion or at the direction of the Required Lenders, delivers to Borrower a written notice terminating the Forbearance Period, which notice may be delivered at any time upon or after the delivery of any Proposed Vendor Payment Schedule Rejection Notice (as defined below) by the Administrative Agent in accordance with Section 3(c)(ii) hereof, or (F) Borrower fails to receive Inventory purchased with a CIA Payment (as defined below) within six (6) Business Days of the making of such CIA Payment. The occurrence of any Forbearance Default shall constitute an immediate Event of Default under the Credit Agreement and other Loan Documents. Upon the termination or expiration of the Forbearance Period, the agreement of Administrative Agent, Co-Administrative Agent and each Lender hereunder to forbear from exercising its default-related rights and remedies shall immediately terminate without the requirement of any demand, presentment, protest, or notice of any kind, all of which Borrower and each other Designated Company hereby waives. Borrower and each other Designated Company further agrees that any of Administrative Agent (upon direction of the Required Lenders to the extent provided in the Credit Agreement) and each Lender may at any time after the expiration or termination of the Forbearance Period proceed to exercise any and all of its rights and remedies under any or all of the Credit Agreement, any other Loan Document and/or applicable law, all of which rights and remedies are hereby fully reserved by Administrative Agent and each Lender. Any agreement by Administrative Agent and the Lenders to extend the Forbearance Period, if any, must be set forth in writing and signed by Administrative Agent and the Lenders. Borrower and each other Designated Company acknowledges that none of Administrative Agent or any Lender has made any assurances concerning any possibility of any extension of the Forbearance Period. Borrower and each other Designated Company acknowledges and agrees that any Loan or other financial accommodation which Administrative Agent, Co-Administrative Agent or any Lender makes to or for the benefit of Borrower or any other Designated Company on or after the Forbearance Effective Date has been made by such party in reliance upon, and is consideration for, among other things, the general releases and indemnities contained in Section 5 hereof and the other covenants, agreements, representations and warranties of Borrower and each other Designated Company hereunder.
Contractor Default shall have the meaning set forth in Clause 23.1;
Note Event of Default means any “Event of Default” specified in Section 5.1 of the Indenture.
Major Default means any Event of Default occurring under Sections 4.1(a), 4.1(c), 4.1(l), or 4.1(p).
Events of Default has the meaning specified in Section 6.01.
Employer default means having an outstanding balance or liability to the old fund or to the uninsured employers' fund or being in policy default, as defined in W. Va. Code § 23-2c-2, failure to maintain mandatory workers' compensation coverage, or failure to fully meet its obligations as a workers' compensation self-insured employer. An employer is not in employer default if it has entered into a repayment agreement with the Insurance Commissioner and remains in compliance with the obligations under the repayment agreement.
Senior Default means any Senior Payment Default or Senior Covenant Default.
Loan Default means any event, condition or failure which, with notice or lapse of time or both, would become a Loan Event of Default.
MI Default has the meaning given to it in paragraph 6.1 of Framework Schedule 9 (Management Information);
PTC Event of Default means, with respect to each Trust Agreement, the failure to pay within 10 Business Days after the due date thereof: (i) the outstanding Pool Balance of the applicable Class of Certificates on the Final Legal Distribution Date for such Class or (ii) interest due on such Certificates on any Distribution Date (unless the Subordination Agent shall have made an Interest Drawing or a withdrawal from the Cash Collateral Account relating to a Liquidity Facility for such Class, with respect thereto in an aggregate amount sufficient to pay such interest and shall have distributed such amount to the Trustee entitled thereto).
Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.
Default Right has the meaning assigned to that term in, and shall be interpreted in accordance with, 12 C.F.R. §§ 252.81, 47.2 or 382.1, as applicable.