Partial Condemnation means any Condemnation which does not constitute a Termination Event.
Premises Building Partial Damage shall herein mean damage or destruction to the building of which the Premises are a part to the extent that the cost of repair is less than 50% of the then replacement cost of such building as a whole.
Condemnation Event means any act of taking by a public or quasi-public authority through condemnation, reverse condemnation or eminent domain.
Net Casualty Proceeds means, with respect to any Casualty Event, the amount of any insurance proceeds or condemnation awards received by the Borrower or any of its U.S. Subsidiaries in connection with such Casualty Event (net of all collection or similar expenses related thereto), but excluding any proceeds or awards required to be paid to a creditor (other than the Lenders) which holds a first priority Lien permitted by clause (d) of Section 7.2.3 on the property which is the subject of such Casualty Event.
Premises Partial Damage means damage or destruction to the improvements on the Premises, other than Lessee Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than 50% of the then Replacement Cost of the Premises immediately prior to such damage or destruction, excluding from such calculation the value of the land and Lessee Owned Alterations and Utility Installations.
Insurance and Condemnation Event means the receipt by any Credit Party or any of its Subsidiaries of any cash insurance proceeds or condemnation award payable by reason of theft, loss, physical destruction or damage, taking or similar event with respect to any of their respective Property.
Loss Occurrence means the sum of all individual losses directly occasioned by any one disaster, accident or loss or series of disasters, accidents or losses arising out of one event which occurs within the area of one state of the United States or province of Canada and states or provinces contiguous thereto and to one another. However, the duration and extent of any one "loss occurrence" shall be limited to all individual losses sustained by the Company occurring during any period of 168 consecutive hours arising out of and directly occasioned by the same event, except that the term "loss occurrence" shall be further defined as follows:
Major Casualty means, in relation to a Ship, any casualty to that Ship in respect of which the claim or the aggregate of the claims against all insurers, before adjustment for any relevant franchise or deductible, exceeds $500,000 or the equivalent in any other currency;
Casualty Loss has the meaning set forth in Section 5.06.
Material Casualty has the meaning set forth in Section 14.1.1.
Landlord Default shall have the meaning given such term in Article 14.
Premises Building Total Destruction means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is fifty percent (50%) or more of the then Replacement Cost of the Building.
Insured Casualty has the meaning set forth in Section 5.1(x)(iv)(B).
Untenantable means that Tenant shall be unable to occupy and shall not be occupying the Premises or the applicable portion thereof for the conduct of business ordinarily conducted in the Premises as a result of the Casualty.
Partial Taking means the taking of only a portion of the Premises which does not constitute a Total Taking; (4) "Date of Taking" means the date upon which the title to the Premises, or a portion thereof, passes to and vests in the condemnor or the effective date of any order for possession if issued prior to the date title vests in the condemnor; and (5) "Award" means the amount of any award made, consideration paid, or damages ordered as a result of a Taking.
Building, structure, facility, or installation means all of the pollutant-emitting activities which belong to the same industrial grouping, are located on one or more contiguous or adjacent properties, and are under the control of the same person (or persons under common control) except the activities of any vessel. Pollutant-emitting activities shall be considered as part of the same industrial grouping if they belong to the same major group (i.e., which have the same two-digit code) as described in the Standard Industrial Classification Manual, 1972, as amended by the 1977 Supplement (U.S. Government Printing Office stock numbers 4101-0066 and 003-005-00176-0, respectively).
Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.
Partial Loss means any Physical Damage loss which is not a Total Loss.
Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).
Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.
Casualty Amount means five hundred thousand Dollars (USD500,000) (or the equivalent in any other currency);
Substantial Completion Date means the date on which Substantial Completion occurs.
Casualty shall have the meaning set forth in Section 6.2 hereof.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Casualty Proceeds means, with respect to any Casualty Event, the amount of any insurance proceeds or condemnation awards received by the Borrower, any Parent Guarantor or any of their respective Subsidiaries in connection therewith, but excluding any proceeds or awards required to be paid to a creditor (other than the Lenders) which holds a first-priority Lien permitted by Section 7.2.3 on the property which is the subject of such Casualty Event.
Premises Total Destruction means damage or destruction to the Premises, other than Lessee Owned Alterations and Utility Installations and Trade Fixtures, which cannot reasonably be repaired in six (6) months or less from the date of the damage or destruction. Lessor shall notify Lessee in writing within thirty (30) days from the date of the damage or destruction as to whether or not the damage is Partial or Total.