Substantially Completed shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 270 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided that Tenant will have a second right to terminate this Lease in the event Landlord has still not Delivered the Premises within 365 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, which right will be exercisable for a period of 10 business days after such 365 day period. The “Commencement Date” shall be the earlier of: (i) the date Landlord Delivers the Premises to Tenant; or (ii) the date Landlord could have Delivered the Premises but for Tenant Delays. Notwithstanding anything to the contrary contained in this Lease, but provided Tenant is not in Default hereunder, Landlord hereby grants Tenant an abatement of the Base Rent payable during the period beginning on the Commencement Date and ending 10 months after the Commencement Date (“Base Rent Abatement”). Subject to the terms of Section 3(a) below, the first day of the 11th month after the Commencement Date shall be the “Rent Commencement Date.” In the event Landlord Delivers the Premises to Tenant more than 180 days after the Target Commencement Date (as extended for Force Majeure delays and Tenant Delays), the period of Base Rent Abatement and the Rent Commencement Date (and all subsequent rent increase dates) will be extended by an equivalent number of days that Delivery is delayed beyond the Target Commencement Date. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease and any Extension Terms which Tenant may elect pursuant to Section 39 hereof. Except as set forth in the Work Letter or otherwise expressly set forth in this Lease: (i) Tenant shall accept the Premises in their condition as of the Commencement Date with all Landlord’s Work Substantially Complete; (ii) Landlord shall have no liability for any defects in the Premises, except as set forth herein or in the Work Letter; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Tenant will not be permitted occupancy of the Premises prior to the date upon which the Premises are Delivered to Tenant with Landlord’s Work Substantially Completed. Except as otherwise expressly set forth in this Lease (including the Work Letter), Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease (including all exhibits attached hereto and any side letters entered into by and between Landlord and Tenant in connection with this Lease) constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein.
Substantially Complete or “Substantial Completion” shall mean that (a) the Base Building Improvements that are required to permit Tenant to enter the Premises for purposes of performing the Tenant Improvement have been completed in accordance with the Building Plans, the correction or completion of which items, collectively, will not substantially interfere with Tenant’s ability to commence the Tenant Improvement Work and (b) Tenant is legally permitted to enter the Premises for purposes of performing the Tenant Improvement Work. Landlord and Tenant shall then arrange a mutually convenient time, no later than ten (10) Business Days after the anticipated Substantial Completion Date specified in Landlord’s notice, for Tenant and/or Tenant’s Architect (as defined below) and Landlord and/or Landlord’s Architect to conduct a walk-through inspection of the Base Building Improvements. During the inspection, Landlord’s Architect shall compile a punchlist of items yet to be completed. If Tenant or Tenant’s Architect shall fail to inspect the Base Building Improvements within ten (10) Business Days after the Substantial Completion Date specified in Landlord’s notice, the Base Building Improvements shall be deemed completed and satisfactory in all respects, and the Substantial Completion Date shall be the date set forth in Landlord’s notice. Landlord shall use commercially reasonable efforts to cause the remaining Base Building Improvements to have been completed on or before the Term Commencement Date in accordance with the Building Plans, the correction or completion of which items, collectively, will not substantially interfere with Tenant’s ability to occupy the Premises to commence the Tenant Improvement Work
Not Typically Combined Network Elements shall mean that the particular Network Elements requested by ONS are not elements that BellSouth combines for its use in its network.
Acre-foot means the amount of water necessary to cover one acre of land one foot deep, or about 325,851 U. S. gallons of water.
Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.
Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and
domestic premises means any premises used wholly or partly as a dwelling or intended for such use;
Tenant Improvements Defined in Exhibit B, if any.
Premises Building Total Destruction means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is fifty percent (50%) or more of the then Replacement Cost of the Building.
Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.
Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);
Construction Work means any work in connection with⎯
Landlord’s Work means the work of constructing the Tenant Improvements.
Building Drain means that part of the lowest horizontal piping of a drainage system which receives the discharge from soil, waste, and other drainage pipes inside the walls of the building and conveys it to the building sewer, beginning five (5) feet (1.5 meters) outside the inner face of the building wall.
Construction in Progress means each Property that is either (a) new ground up construction or (b) under renovation in which (i) greater than thirty percent (30%) of the square footage of such Property is unavailable for occupancy due to renovation and (ii) no rents are being paid on such square footage. A Property will cease to be classified as “Construction in Progress” on the earlier to occur of (A) the time that such Property has an Occupancy Rate of greater than eighty percent (80%), or (B) one hundred eighty (180) days after completion of construction or renovation of such Property, as applicable.
Ready for Occupancy means the date upon which (i) the Leased Premises are available for Tenant's occupancy in a broom clean condition and (ii) the improvements, if any, to be made to the Leased Premises by Landlord as a condition to Tenant's obligation to accept possession of the Leased Premises have been substantially completed and the appropriate governmental building department (i.e., the City building department, if the Property is located within a City, or otherwise the County building department) shall have approved the construction of such improvements as substantially complete or is willing to so approve the construction of the improvements as substantially complete subject only to compliance with specified conditions which are the responsibility of Tenant to satisfy or is willing to allow Tenant to occupy subject to its receiving assurances that specified work will be completed.
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Minimum Improvements means the acquisition of land and construction of a 64-unit market rate residential apartment building and related improvements. The Minimum Improvements are more fully depicted in Exhibit B, which is attached hereto and incorporated herein.
Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.
On-premises sign means a sign advertising activities conducted or maintained on the property on which it is located. The boundary of the property shall be as determined by tax rolls, deed registrations, and apparent land use delineations. If a sign consists principally of brand name or trade name advertising and the product or service advertised is only incidental to the principal activity conducted or maintained on the property, or if the sign brings rental income to the property owner or sign owner, it shall be considered the business of outdoor advertising and not an on-premises sign. On-premises sign does not include a sign on a narrow strip of land contiguous to the advertised activity, or a sign on an easement on adjacent property, when the purpose is clearly to circumvent the intent of this act.
Building Plans mean the general building plans and specifications in respect of the Development or in respect of any part or parts of the Development prepared by the Authorized Person and approved by the Building Authority and include any approved amendments thereto;
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
job work means any treatment or process undertaken by a person on goods belonging to another registered person and the expression “job worker” shall be construed accordingly;
Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;
Unoccupied means the dwelling is not being inhabited as a residence.
Owner-occupied means property that is the principal