Mentally ill means having a mental illness.
Acutely mentally ill means a condition which is limited to a
Substantially Completed shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 270 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided that Tenant will have a second right to terminate this Lease in the event Landlord has still not Delivered the Premises within 365 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, which right will be exercisable for a period of 10 business days after such 365 day period. The “Commencement Date” shall be the earlier of: (i) the date Landlord Delivers the Premises to Tenant; or (ii) the date Landlord could have Delivered the Premises but for Tenant Delays. Notwithstanding anything to the contrary contained in this Lease, but provided Tenant is not in Default hereunder, Landlord hereby grants Tenant an abatement of the Base Rent payable during the period beginning on the Commencement Date and ending 10 months after the Commencement Date (“Base Rent Abatement”). Subject to the terms of Section 3(a) below, the first day of the 11th month after the Commencement Date shall be the “Rent Commencement Date.” In the event Landlord Delivers the Premises to Tenant more than 180 days after the Target Commencement Date (as extended for Force Majeure delays and Tenant Delays), the period of Base Rent Abatement and the Rent Commencement Date (and all subsequent rent increase dates) will be extended by an equivalent number of days that Delivery is delayed beyond the Target Commencement Date. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease and any Extension Terms which Tenant may elect pursuant to Section 39 hereof. Except as set forth in the Work Letter or otherwise expressly set forth in this Lease: (i) Tenant shall accept the Premises in their condition as of the Commencement Date with all Landlord’s Work Substantially Complete; (ii) Landlord shall have no liability for any defects in the Premises, except as set forth herein or in the Work Letter; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Tenant will not be permitted occupancy of the Premises prior to the date upon which the Premises are Delivered to Tenant with Landlord’s Work Substantially Completed. Except as otherwise expressly set forth in this Lease (including the Work Letter), Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease (including all exhibits attached hereto and any side letters entered into by and between Landlord and Tenant in connection with this Lease) constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein.
Substantially limits means the extent to which the impairment limits an individual’s ability to perform a major life activity as compared to most people in the general population, whether or not an individual chooses to forgo mitigating measures. 42 U.S.C. 126 §12102(4); 28 CFR §35.108(d); 28 CFR §35.105(d) The rules of construction when determining whether an impairment substantially limits performance of a major life activity include:
Substantially Complete or “Substantial Completion” shall mean that (a) the Base Building Improvements that are required to permit Tenant to enter the Premises for purposes of performing the Tenant Improvement have been completed in accordance with the Building Plans, the correction or completion of which items, collectively, will not substantially interfere with Tenant’s ability to commence the Tenant Improvement Work and (b) Tenant is legally permitted to enter the Premises for purposes of performing the Tenant Improvement Work. Landlord and Tenant shall then arrange a mutually convenient time, no later than ten (10) Business Days after the anticipated Substantial Completion Date specified in Landlord’s notice, for Tenant and/or Tenant’s Architect (as defined below) and Landlord and/or Landlord’s Architect to conduct a walk-through inspection of the Base Building Improvements. During the inspection, Landlord’s Architect shall compile a punchlist of items yet to be completed. If Tenant or Tenant’s Architect shall fail to inspect the Base Building Improvements within ten (10) Business Days after the Substantial Completion Date specified in Landlord’s notice, the Base Building Improvements shall be deemed completed and satisfactory in all respects, and the Substantial Completion Date shall be the date set forth in Landlord’s notice. Landlord shall use commercially reasonable efforts to cause the remaining Base Building Improvements to have been completed on or before the Term Commencement Date in accordance with the Building Plans, the correction or completion of which items, collectively, will not substantially interfere with Tenant’s ability to occupy the Premises to commence the Tenant Improvement Work
Not Typically Combined Network Elements shall mean that the particular Network Elements requested by ONS are not elements that BellSouth combines for its use in its network.
Substantially similar means substantially similar in function or capability or otherwise competitive to the products or services being developed, manufactured or sold by the Company during and/or at the end of Executive’s employment, or are marketed to substantially the same type of user or customer as that to which the products and services of the Company are marketed or proposed to be marketed.
Deadly weapon means any weapon, whether loaded or unloaded, from which a shot may be discharged, or a switchblade knife, gravity knife, billy, blackjack, bludgeon, or metal knuckles.
Other Loans Specially Mentioned Special Mention", "Substandard", "Doubtful", "Loss", "Classified", "Criticized", "Watch list" or words of similar import, together with the principal amount of and accrued and unpaid interest on each such Loan and the identity of the obligor thereunder, (4) where a reasonable doubt exists as to the timely future collectibility of principal and/or interest, whether or not interest is still accruing or the loans are less than 90 days past due, (5) where the interest rate terms have been reduced and/or the maturity dates have been extended subsequent to the agreement under which the loan was originally created due to concerns regarding the borrower's ability to pay in accordance with such initial terms, or (6) where a specific reserve allocation exists in connection therewith, and (G) all assets classified by Innes Street or Citizens Bank as real estate acquired through foreclosure or in lieu of foreclosure, including in-substance foreclosures, and all other assets currently held that were acquired through foreclosure or in lieu of foreclosure.
Physically incapacitated means that a person has a bodily impairment or handicap that substantially limits the person’s ability to resist or flee.
Officially Designated means designated by the Shareholder of Record:
Sexually motivated ’ means that one of the purposes for which the defendant committed the crime was for the purpose of the defendant’s sexual gratification.
Technically Feasible refers solely to technical or operational concerns, rather than economic, space, or site considerations.
Reconditioned means restored to the original normal operating condition by readjustments and material replacement.
Totally and Permanently Disabled means a person as defined in 42 U.S.C. section 416.
Physically helpless means that a person is unconscious or for any other reason is physically unable to communicate unwillingness to an act.
Residential facility for persons with a disability means a residence:
medically approved means certified by a medical practitioner;
Biologically-based mental illness means schizophrenia, schizoaffective disorder, major depressive disorder, bipolar disorder, paranoia and other psychotic disorders, obsessive-compulsive disorder, and panic disorder, as these terms are defined in the most recent edition of the diagnostic and statistical manual of mental disorders published by the American Psychiatric Association.
Mentally incapacitated means that a person is rendered temporarily incapable of appraising or controlling his or her conduct whether this condition is produced by illness, defect, the influence of a substance or from some other cause. S.C. Code Ann. § 16-3-651(f).
Smoking means inhaling, exhaling, burning, or carrying any lighted or heated cigar, cigarette, pipe, hookah, or any other lighted or heated tobacco or plant product intended for inhalation, including marijuana, whether natural or synthetic, in any manner or in any form. “Smoking” also includes the use of an electronic smoking device which creates an aerosol or vapor, in any manner or in any form, or the use of any oral smoking device for the purpose of circumventing the prohibition of smoking in this Article.
Contractor Commercially Sensitive Information means the information listed in the Contractor Commercial Sensitive Information Annex to the Contract being information notified by the Contractor to the Authority which is acknowledged by the Authority as being commercially sensitive information.
Functionally Dependent Facility means a facility which cannot be used for its intended purpose unless it is located in close proximity to water, limited to a docking or port facility necessary for the loading and unloading of cargo or passengers, shipbuilding, or ship repair. The term does not include long-term storage, manufacture, sales, or service facilities.
Potentially hazardous food means any food or ingredient, natural or synthetic, in a form capable of supporting the growth of infectious or toxigenic microorganisms, including Clostridium botulinum. This term includes raw or heat treated foods of animal origin, raw seed sprouts, and treated foods of plant origin. The term does not include foods which have a pH level of 4.6 or below or a water activity (Aw) value of 0.85 or less.
Medically incapacitated means a person who is incapacitated as a result of prescribed sedatives, anesthesia, or other medication.
Mentally disabled means that a person suffers from a mental disease or defect which renders him or her incapable of appraising the nature of his or her conduct.