Planned Completion Date definition

Planned Completion Date means, subject to any variation to such date pursuant to the Project Agreement, 12 January 2002;
Sample 1Sample 2Sample 3
Planned Completion Date means November 24, 2009, as the same may be extended in accordance with the provisions of Article 25 (Delay Events);
Sample 1
Planned Completion Date means the date as agreed in the Contract Agreement; “Actual Completion Date” means the date as determined in accordance with Completion Date. Construction Duration: the period necessary for the Contractor to complete the Project specified in the Contract Agreement, including any amendments thereto made in accordance with the Contract. Defects Liability Period: the period during which the Contractor should assume defects repair liability in accordance with the Contract and the Employer retains the quality guarantee deposit. It shall be calculated as of the Actual Completion Date. Warranty Period: the period during which the Contractor should assume warranty liability of the Project in accordance with the Contract. It shall be calculated as of the date when the Project is completed and accepted to be qualified. Base Date: the date 28 days before the closing date for submission of the Bid in the contracting project through bidding, or the date 28 days before the date when the Contract is signed in the direct contracting project. Day: unless otherwise specified, “Day” means the calendar day. Where the time in the Contract is calculated by day, the period shall be calculated starting from the next day instead of the date when the period starts and the ending time of the last day of the period shall be 24:00 of that day. Contract Price and Cost Signed Contract Price: the total amount confirmed in the Contract Agreement by the Contractor and Employer, including safe and civilized construction fees, Provisional Estimate and Provisional Sum. Contract Price: the amount paid by the Employer to the Contractor for completion of all works within the contracting scope as per the Contract, including price changes in accordance with the Contract during the performance of the Contract. Cost: necessary expenditures incurred or to be incurred for the performance of the Contract, including administrative fees and other unamortized expense, but excluding the profits. Provisional Estimate: the amount provided by the Employer in the Bill of Quantities or Budget Statement for paying the expenses of materials and Engineering Equipment and for professional engineering and services which are inevitable but temporarily cannot be confirmed. Provisional Sum: a sum included in the Contract Price and a provisional sum in the Bill of Quantities or Budget Statement by the Employer for procurement of materials, Engineering Equipment or services which are undetermined or unforeseeable when th...
Sample 1

Examples of Planned Completion Date in a sentence

  • Planned Start Date: March 1, 2007 Planned Completion Date: December 31, 2009The project will operate for 3 years.

  • Planned Start Date: Planned Completion Date: Year Building was Constructed: Estimated Total Cost of Project before tax: Project Information:Include costs of entire project based on the lowest contractor quotation.

  • Transfer applicants must forward official transcripts from all previously attended colleges or postsecondary institutions.

  • In 2017, the Bank launched a new equity investmentservice-- "Zhanyi Zhitou" to directly make small-value equity investments in those companies that need equity financing, and support the growth of innovative enterprises through the model of "creditor's rights + equity".

  • Planned Completion Date for CAPThe planned completion date for the CAP is ongoing.

  • SEBI/IMD/CIR No. 4/168230/09 dated June 30, 2009 has notified that w.e.f. August 01, 2009 there will be no entry load charged to the schemes of the Mutual Fund and the upfront commission to distributors will be paid by the investor directly to the distributor, based on his assessment of various factors includingthe service rendered by the distributor.

  • Syliphone, SLP 13, 33.3 rpm disc, ca 1970; Appels au peuple, Syliphone, SLP 26,33.3 rpm disc, ca 1971.

  • Planned Completion Date for the Corrective Action Plan:Complete and review financial transactions during the year: On-going.Complete additional pre-audit work on specific transactions accounts for 2017: April 2018.Review staff workload in future years to see if the department has the funds and capacity to create the financial statements in house.

  • Without limiting Project Co’s obligations under Section 2.4, Project Co shall at, its own cost and expense, (i) apply for, obtain, maintain and, as applicable, renew all Development Approvals and Consents; and (ii) comply with all Development Approvals and Consents in accordance with their terms, which, in each case, may be required for the development of the Site and the Project Facilities to achieve Completion on or before the Planned Completion Date.

  • Planned Start Date: Planned Completion Date: Estimated Total Cost of Project before tax: Project Information: Include costs of entire project based on the lowest contractor quotation.


More Definitions of Planned Completion Date

Planned Completion Date means the date the "project" would be put into operation or use in the normal course of construction if "loss" from any of the Covered Causes of Loss had not occurred.
Sample 1

Related to Planned Completion Date

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Commissioning Date means that date when construction of the contemplated Project is complete, and the Maintenance Term commences;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Commissioning Period has the meaning set forth in Attachment T.

  • Billing Commencement Date means the earlier of:

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;