Schedule Delay definition

Schedule Delay means a projected or actual delay in completion of tasks, activities, or project completion that does not result in a change to the original Agreement scope of Services or Total Agreement Price.
View Source

Examples of Schedule Delay in a sentence

  • If, in the opinion of the Owner’s Representative, the Architect’s revised CPM Schedule will avoid any further delay, thereby reflecting the timely attainment of the next succeeding milestone date, and if the Architect proceeds in accordance with and achieves the revised date in such approved revised CPM Schedule, Delay Damages for the failure to meet such date or milestone will cease to accrue and shall not be charged to the Architect as to such delay.

  • If the Contractor is late in submitting the Time Schedule, Delay Damages shall accrue in accordance with the same principles as those stated in Article 37.

Related to Schedule Delay

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, material litigation by parties other than the Parties not caused by the Parties’ failure to perform, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable party using reasonable diligence to overcome which prevents such party from performing its specific duties or obligation hereunder in a timely manner.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.