Stop Work Orders definition

Stop Work Orders. Notwithstanding any other provisions of this Subcontract, a stop work order which relates to the Subcontractor’s Work, may, by issuance of written notice to Subcontractor, suspend all or any portion of the Work. Upon receipt of such written notice from Contractor, Subcontractor shall immediately cease all work as directed by Contractor. Subcontractor shall promptly resume all Work upon receipt of notice from Contractor that the stop work order has been lifted. Subcontractor shall make every effort to minimize all costs associated with stopping or resuming work. Subcontractor may not claim payment for any work performed during the stop work period.
View Source

Examples of Stop Work Orders in a sentence

  • Stop Work Orders may be issued for reasons such as a project exceeding budget, standard of performance, out of scope work, delay in project schedule, misrepresentations and the like.

  • The Court’s notice obligations under the foregoing sentence shall not apply to any Stop Work Orders issued by the Court under this Agreement or any Statement of Work.

  • The City may issue Stop Work Orders for violations arising under this Agreement or the regulations applied herein.

  • Issue Stop Work Orders, as directed by the City, in those cases where GEC Permittees have not complied with the erosion and sediment control regulations and/or with the conditions attached to the GEC Permit.

  • Any such order shall be specifically identified as a "Stop Work Order" issued pursuant to this Section 5.13 (MTA-Issued Stop Work Orders).

  • C.11 Suspension Period for Stop Work Orders GC 11.2.1 Refer to Information Sheet in Master Roster Agreement.

  • Monitors have the sole authority to issue Stop Work Orders during monitored activities.

  • Stop Work Orders may be issued for any reason, including but not limited to, the Project exceeding budget, performance issues, out of scope work, delays in the Project schedule, and misrepresentations.

  • The Contractor shall comply with the terms of this Master Contract and Work Orders, Change Orders, Work Order Amendments, and Stop Work Orders from the State.

  • During a dispute, Partner and any subcontractors must observe any Stop Work Orders put into effect until the dispute is resolved.