TENANT'S REMEDIES definition

TENANT'S REMEDIES. With respect to any provision of this Lease which provides, in effect, that Landlord shall not unreasonably withhold or unreasonably delay any consent or any approval, Tenant in no event, shall be entitled to make, nor shall Tenant make, any claim, and Tenant hereby waives any claim, for money damages; nor shall Tenant claim any money damages by way of setoff, counterclaim or defense, based upon any claim or assertion by Tenant that Landlord has unreasonably withheld or unreasonably delayed any consent or approval; but Tenant's sole remedy shall be an action or proceeding to enforce any such provision, or for specific performance, injunction or declaratory judgment.
Sample 1
TENANT'S REMEDIES. In the event of a breach of this lease by Landlord, and Landlord's failure to cure such breach within thirty (30) days of Tenant's written notice of breach to Landlord, or if claimed breach cannot be cured within thirty (30) days, or if curative steps are not undertaken at the same time and diligently pursued, Tenant will have the right of pursuing any other remedies which Tenant may have at law or equity or under any state statute or regulation. Should Tenant elect to cure Landlord's breach, Tenant may offset the costs of cure incurred by Tenant against future sums due Landlord under this lease and/or submit an invoice to Landlord specifying the amount due Tenant, which amount Landlord will pay within ten (10) days of receipt of Tenant's invoice. The election by Tenant of any remedy afforded Tenant will not be deemed a waiver of any other remedies available to Tenant, Tenant's remedies being cumulative.
Sample 1

Examples of TENANT'S REMEDIES in a sentence

  • IN THE EVENT LANDLORD IS IN BREACH OR DEFAULT WITH RESPECT TO LANDLORD'S OBLIGATIONS OR OTHERWISE UNDER THIS LEASE, TENANT SHALL LOOK SOLELY TO THE EQUITY OF LANDLORD IN THE BUILDING FOR THE SATISFACTION OF TENANT'S REMEDIES.

  • TENANT'S REMEDIES REGARDING REVOCATION OF CERTIFICATE OF OCCUPANCY.

  • TENANT'S REMEDIES SHALL BE LIMITED TO DAMAGES AND INJUNCTIVE RELIEF.

  • TENANT SHALL LOOK SOLELY TO LANDLORD'S INTEREST IN THE PROPERTY FOR THE RECOVERY OF ANY JUDGMENT OR AWARD AGAINST LANDLORD, AND NO OTHER PROPERTY OR ASSETS OF LANDLORD SHALL BE SUBJECT TO LEVY, EXECUTION, OR OTHER PROCEDURES FOR SATISFACTION OF TENANT'S REMEDIES.

  • TENANT HEREBY AGREES THAT TENANT'S REMEDIES FOR DEFAULT HEREUNDER OR IN ANY WAY ARISING IN CONNECTION WITH THIS LEASE INCLUDING ANY BREACH OF ANY PROMISE OR INDUCEMENT OR WARRANTY, EXPRESSED OR IMPLIED, SHALL BE LIMITED TO SUIT FOR DIRECT AND PROXIMATE DAMAGES PROVIDED THAT TENANT HAS GIVEN THE NOTICES AS HEREINAFTER REQUIRED.

  • IN THE EVENT LANDLORD IS IN BREACH OR DEFAULT WITH RESPECT TO LANDLORD'S OBLIGATIONS OR OTHERWISE UNDER THIS LEASE, TENANT SHALL LOOK SOLELY TO THE EQUITY OF LANDLORD IN THE LAND AND BUILDING FOR THE SATISFACTION OF TENANT'S REMEDIES.

  • For the importance of resource webs as a key constraint in foreign-policy restructuring, see Thomas J.

  • In order to comprehend the socioeconomic factors which effect persons throughout The Bahamas, the Government of the Commonwealth of The Bahamas implemented the first-ever Bahamian Living Conditions Survey (BLCS).

  • INTRODUCTIONISSN 1582-3024The use of precast concrete structures in seismic areas have been frequently limited, by the lack of confidence about their performance in seismic regions as well as by the absence of seismic design provisions or specific codes for analysis and design of critical zones in the structure, i.e. the connecting joints.

  • Its ability to interface with the world outside the model allows a system to automatically gather additional information that may assist people in performing and improving their collaborative activities.We should emphasize that while some parts of this system have been designed and some parts have been constructed, there is not yet a single coherent framework in which all these notions are realized.

Related to TENANT'S REMEDIES

  • Landlord Default shall have the meaning given such term in Article 14.

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Landlord Waiver means a letter in form and substance reasonably acceptable to the Administrative Agent and executed by a landlord in respect of Inventory of a Loan Party located at any leased premises of a Loan Party pursuant to which such landlord, among other things, waives or subordinates on terms and conditions reasonably acceptable to the Administrative Agent any Lien such landlord may have in respect of such Inventory.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent (50%) of the then Replacement Cost of the building.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Structural damage means a covered building, regardless of the date of its construction, has experienced the following.

  • Major Damage means damage that in the estimation of the surveyor exceeds USD

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Master Lease means any master lease now or hereafter entered into, in which the Healthcare Facility is aggregated with other HUD-insured healthcare facilities and leased to a Master Tenant and any amendments or joinders thereto.

  • Tenant means a person entitled under a rental agreement to occupy a dwelling unit to the exclusion of others.

  • Tenants means the tenants under the Leases.

  • Major Tenants has the meaning ascribed to such term in Section 7.2.

  • Premises Partial Damage means damage or destruction to the Premises, other than Lessee-Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than fifty percent (50%) of the then Replacement Cost (as defined in Paragraph 9.1(d)) of the Premises (excluding Lessee-Owned Alterations and Utility Installations and Trade Fixtures) immediately prior to such damage or destruction.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.

  • Landlord Personal Property Collateral Access Agreement means a Landlord Waiver and Consent Agreement substantially in the form of Exhibit L, with such amendments, modifications or supplements thereto as may be approved by the Administrative Agent.

  • Tenant’s Property means Removable Installations and, other than Installations, any personal property or equipment of Tenant that may be removed without material damage to the Premises, and (z) “Installations” means all property of any kind paid for by Landlord, all Alterations, all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment, property and improvements built into the Premises so as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch.

  • Landlord Parties means Landlord and Property Manager and their respective officers, directors, partners, shareholders, members and employees.

  • Landlord Liens means liens on or against the Leased Property or any payment of Rent (a) which result from any act of, or any claim against, Landlord or any owner (other than Tenant) of a direct or indirect interest in the Leased Property, or which result from any violation by Landlord of any terms of this Agreement or the Purchase Agreement, or (b) which result from liens in favor of any taxing authority by reason of any tax owed by Landlord or any fee owner of a direct or indirect interest in the Leased Property; provided, however, that "Landlord Lien" shall not include any lien resulting from any tax for which Tenant is obligated to pay or indemnify Landlord against until such time as Tenant shall have already paid to or on behalf of Landlord the tax or the required indemnity with respect to the same.

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Tenant Parties means Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.

  • this Lease means the relevant portion of Articles 1 through 29 of this Office Lease to which this Tenant Work Letter is attached as EXHIBIT B and of which this Tenant Work Letter forms a part, and all references in this Tenant Work Letter to sections of "this Tenant Work Letter" shall mean the relevant portion of Sections 1 through 7 of this Tenant Work Letter.