Upgrade Completion Form definition

Upgrade Completion Form means the form completed and submitted by the Participant to Alberta Municipalities, once an Upgrade has reached Substantial Performance, which lists the Upgrades installed and confirms the Eligible Costs.
Sample 1Sample 2Sample 3
Upgrade Completion Form means the form completed and submitted by the Property Owner to the AMSC, along with Project invoices, once the Project has reached Substantial Performance, which lists the final Upgrades installed and the costs associated with the Services completed.
Sample 1Sample 2
Upgrade Completion Form means the form completed and submitted by the Participant to the AMSC, once an Upgrade has reached Substantial Performance, which lists the final Upgrade installed and confirms the Project Costs;
Sample 1Sample 2

Examples of Upgrade Completion Form in a sentence

  • Once the associated Upgrade has a minimum Capital Cost of $3,000 and has reached Substantial Performance, the Participant may submit an Upgrade Completion Form and Supporting Documentation for payment of Professional Services costs and/or Incidental Costs to the Participant, if the Participant paid such costs, or to the Qualified Contractor, if not previously paid by the Participant.

  • If the AMSC determines that an Upgrade Completion Form and/or Supporting Documentation is deficient or incomplete, the AMSC will notify the Participant and the Qualified Contractor and provide them with an opportunity to rectify the deficiency.

  • Once an Upgrade has been installed, the Participant must submit an Upgrade Completion Form to Alberta Municipalities within 3 calendar 5 business days of the Upgrade reaching Substantial Performance.

  • The Qualified Contractor will receive payment for the costs submitted in the Upgrade Completion Form.

  • The property owner will submit an Upgrade Completion Form to the AMSC confirming the clean energy improvement was installed and the final costs of the improvement.


More Definitions of Upgrade Completion Form

Upgrade Completion Form means the form completed and submitted by the Property Owner to the Program Administrator, once a Clean Energy Improvement has reached Substantial Performance, which lists the Clean Energy Improvements installed and confirms the Eligible Costs.
Sample 1
Upgrade Completion Form means the form completed and submitted by the Participant to the Program Administrator, once a Clean Energy Improvement has reached Substantial Performance, which confirms: (i) the final costs, including Capital Costs, Professional Service costs, and the Incidental Costs for each Clean Energy Improvement completed, (ii) the Municipality Financing requested; and (iii) any direction setting out Property owner reimbursement, if applicable.
Sample 1

Related to Upgrade Completion Form

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.

  • Construction Completion Certificate means a certificate of the I-Bank to the effect that the construction of the Project is complete.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Commissioning test means tests applied to a distributed generation facility by the applicant after construction is completed to verify that the facility does not create adverse system impacts and performs to the submitted specifications. At a minimum, the scope of the commissioning tests performed shall include the commissioning test specified in Institute of Electrical and Electronics Engineers, Inc. (IEEE) Standard 1547 Section 5.4 "Commissioning tests".

  • Commissioning Tests means all of the procedures and tests which, in accordance with the Reasonable and Prudent Standard, and in compliance with industry guidelines, practices and standards, are:

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Notice of Completion means a document issued by the Department or Delegated Agency at the end of project construction when all items and conditions of the approved Sediment and Stormwater Management Plan have been satisfied, post construction verification documents demonstrate that the stormwater management systems have been constructed in accordance with the approved Sediment and Stormwater Management Plan, and final stabilization of disturbed areas on the site has been achieved.

  • Application Review Start Date means the later date of either the date on which the District issues its written notice that the Applicant has submitted a completed Application or the date on which the Comptroller issues its written notice that the Applicant has submitted a completed Application and as further identified in Section 2.3.A of this Agreement.

  • Tests on Completion means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Acceptance Tests means those tests performed during the Performance Period which are intended to determine compliance of Equipment and Software with the specifications and all other Attachments incorporated herein by reference and to determine the reliability of the Equipment.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Acceptance Testing mean the tests, reviews and other activities that are performed by or on behalf of Agency to determine whether the Deliverables meet the Acceptance Criteria or otherwise satisfy the Agency, as determined by the Agency in its sole discretion.