Completion of Construction Work Sample Clauses

Completion of Construction Work. Upon Substantial Completion of the Project, Tenant shall furnish the FCRHA with (a) a certification of the Architect (certified to the FCRHA) that it has examined the applicable plans and specifications (that shall include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been substantially completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all applicable Requirements, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Public Works and Environmental Services (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration) of the Project, within ninety (90) days of Substantial Completion, a complete set of “as built” plans, in either CADD format, to the extent available, or in field marked copies of the plans, and a survey showing the Project. The FCRHA shall have an unrestricted non-exclusive license to use such “as built” plans and survey for any purpose without paying any additional cost or compensation therefor, which license shall be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs
Completion of Construction Work. Upon Final Completion of the Project, Tenant shall furnish Landlord with (a) a certification of the Architect (certified to Landlord) that it has examined the applicable plans and specifications (that shall include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all Applicable Laws, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Planning and Development (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration for which “as built” plans will be issued) of the Project, within ninety (90) days after Substantial Completion, a complete set of “as built” plans and a survey showing the Project. Landlord shall have an unrestricted non-exclusive license to use such “as built” plans and survey in connection with any Restoration of the Project without paying any additional cost or compensation therefor, which license shall be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.‌
Sample 1Sample 2See All (4)
Completion of Construction Work. The following procedures shall govern all issues of incomplete construction work, which are not specifically addressed elsewhere in this Agreement:
Sample 1
Completion of Construction Work. In case of a plot / land, the construction shall be completed within 2 years and in case of a shed / stall / built-up space, the construction / preparation shall be completed within 1 year from the date of execution of the Deed of Assignment or delivery of possession, whichever is earlier. If there is any delay in completion of the construction or the preparatory work, on justifiable reasons beyond the control of the Assignee, the Assignor may allow such extension as deemed fit and proper.
Sample 1
Completion of Construction Work. Upon substantial completion of a Restoration or a Capital Improvement having a total cost in excess of $250,000, Tenant shall furnish Administrator with (a) a certification of the architect or a licensed professional engineer acceptable to Administrator (certified to Landlord and Administrator) that it has examined the applicable plans and specifications and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Restoration or the Capital Improvement, as the case may be, has been substantially completed in accordance with the plans and specifications applicable thereto and, as constructed, the Restoration or Capital Improvement, as the case may be, complies with the Building Code of New York City and all other Requirements, (b) a copy or copies of the temporary or permanent (whichever is applicable, if any) Certificate(s) of Occupancy for the relevant portion of the Premises, (c) copies of official certificates evidencing compliance with all Requirements, if any and (d) the most current set of available architectural plans. Tenant shall further furnish Administrator with a complete set of “as built” plans, as of the date a temporary or permanent (whichever is applicable) Certificate of Occupancy is issued, as soon as such are prepared, but in no event later than thirty (30) days after a temporary or permanent (as applicable) Certificate of Occupancy is issued. Administrator shall have a, non-exclusive, irrevocable license to use such “as built” plans and survey for the purpose of completing the Work on the Premises without paying any additional cost or compensation therefor, subject to copyright and similar rights under applicable law of the architect and other Persons who prepared such plans and surveys.
Sample 1

Related to Completion of Construction Work

  • Completion of Construction (a) For the purposes of this Agreement, the terms "

  • Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.

  • Initial Construction Attached hereto are plans showing proposed modifications to Premises. Within 20 days of execution of the Lease, Landlord will prepare construction drawings and specifications for such modifications containing such details as dimensions, partition plans, dimensioned electrical and telephone outlet plans, modified reflected ceiling plans, room finish schedule, including wall, carpet, floor tile, and VCT colors, and other necessary construction details and specifications for the completion of such work, all in a manner reasonably acceptable to Tenant. Space planning, construction drawings, and specifications shall be provided by Landlord to Tenant a no cost to Tenant. All construction of modifications to Tenant's Premises will be accomplished by Tenant's contractor, which contractor shall furnish to Landlord evidence of insurance as follows: General Liability and Property Damage - $2,000,000 Aggregate, $2,000,000 per Occurrence; Workmens Compensation, and an Owners and Contractors Protective Liability Policy in the amount of $1,000,000 naming the owner and The Gutixxxxx Xxxpany as insureds. In addition, in Tenant's construction contract, Tenant shall insure that the contract holds Landlord and The Gutixxxxx Xxxpany harmless, and that Landlord and The Gutixxxxx Xxxpany are additional named insureds on all of Tenant's insurance policies. It shall be Tenant's contractor's responsibility to obtain the building permit for said modifications to Premises. It shall be Tenant's responsibility to insure that all Tenant's general contractors subcontractors and materialmen are paid in full, and if a lien is placed upon the Building by any such contractor, subcontractor, materialmen, or other, to promptly remove such lien or provide a bond reasonably satisfactory to Landlord and Landlord's mortgagee to insure that such lien will be paid in full while contesting such lien. Landlord shall permit Tenant and Tenant's contractor access for construction of modifications to Tenant's premises promptly after execution hereof. All changes and additions shall be part of the Building, except such items as by writing at the time of approval the parties agree either shall be removed by Tenant on termination of this Lease, or shall be removed or left at Tenant's election.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Construction of Project 11.1.1 Developer agrees to cause the Project to be developed, constructed, and installed in accordance with the terms hereof and the Construction Provisions set forth in Exhibit D, including those things reasonably inferred from the Contract Documents as being within the scope of the Project and necessary to produce the stated result even though no mention is made in the Contract Documents.

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Definitions Construction (a) All initially capitalized terms used herein (including in the preamble and recitals hereof) without definition shall have the meanings ascribed thereto in the Credit Agreement (including Schedule 1.1 thereto). Any terms (whether capitalized or lower case) used in this Agreement that are defined in the Code shall be construed and defined as set forth in the Code unless otherwise defined herein or in the Credit Agreement; provided that to the extent that the Code is used to define any term used herein and if such term is defined differently in different Articles of the Code, the definition of such term contained in Article 9 of the Code shall govern. In addition to those terms defined elsewhere in this Agreement, as used in this Agreement, the following terms shall have the following meanings:

  • Legal Construction If one or more of the provisions contained in this Agreement shall for any reason be held invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability shall not affect any other provisions and this Agreement shall be construed as if it did not contain the invalid, illegal, or unenforceable provision.

  • Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).

Time is Money Join Law Insider Premium to draft better contracts faster.