Liquidated damages, attorney's fees, waiver of vendor's liability, and waiver of statutes of limitations clauses should also be deleted or qualified with "to the extent permitted by the Constitution and laws of State of Texas." Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. Do you agree to these terms? 64 Remedies The parties shall be entitled to exercise any right or Yes, I Agree remedy available to it either at law or in equity, subject to the choice of law, venue and service of process clauses limitations agreed herein. Nothing in this agreement shall commit the TIPS to an arbitration resolution of any disagreement under any circumstances. Any Claim arising out of or related to the Contract, except for those specifically waived under the terms of the Contract, may, after denial of the Board of Directors, be subject to mediation at the request of either party. Any issues not resolved hereunder MAY be referred to non-binding mediation to be conducted by a mutually agreed upon mediator as a prerequisite to the filing of any lawsuit over such issue(s). The parties shall share the mediator’s fee and any associated filing fee equally. Mediation shall be held in Camp or Xxxxx County, Texas. Agreements reached in mediation shall be reduced to writing, and will be subject to the approval by the District's Board of Directors, signed by the Parties if approved by the Board of Directors, and, if signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Do you agree to these terms? 65 Remedies Explanation of No Answer 66 Choice of Law The agreement between the Vendor and TIPS/ESC Yes Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. THIS DOES NOT APPLY to a vendor's agreement entered into with a TIPS Member, as the Member may be located outside Texas. Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. Do you agree to these terms?
Liquidated damages, attorney's fees, waiver of vendor's liability, and waiver of statutes of limitations clauses should also be deleted or qualified with "to the extent permitted by the Constitution and laws of State of Texas." Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. Do you agree to these terms? Yes
Liquidated. DAMAGES -- CONSTRUCTION (SEP 2000) Para (a), Amount of liquidated damages. '"To be cited in each individual task order"' Applies to Firm-Fixed-Price CLIN(s), Labor-Hour CLIN(s), Cost-Plus-Incentive-Fee (Performance) CLIN(s), Cost-Plus-Award-Fee CLIN(s), Cost CLIN(s), Fixed-Price Incentive (Firm Target) CLIN(s)only. 52.211-13 TIME EXTENSIONS (SEP 2000) 52.211-17 DELIVERY OF EXCESS QUANTITIES (SEP 1989) Applies to Firm-Fixed-Price CLIN(s), Fixed-Price Incentive (Firm Target) CLIN(s), Fixed- Price Award Fee CLIN(s) only. 52.242-15 STOP-WORK ORDER (AUG 1989) Applies to Firm-Fixed-Price CLIN(s), Labor-Hour CLIN(s), Fixed-Price Incentive (Firm Target) CLIN(s), Fixed-Price Award Fee CLIN(s) only.
Liquidated. DAMAGES IN THE AMOUNT OF THE DEPOSIT (AS IT MAY BE INCREASED FROM TIME TO TIME) ARE AND WOULD BE REASONABLE AS A MEASURE OF SUCH DAMAGES, (III) IN THE EVENT OF SUCH BREACH, SELLER SHALL BE ENTITLED TO RETAIN THE DEPOSIT AS SUCH LIQUIDATED DAMAGES, AND (IV) IN CONSIDERATION OF THE PAYMENT OF SUCH LIQUIDATED DAMAGES, SELLER SHALL BE DEEMED TO HAVE WAIVED ALL OTHER CLAIMS FOR DAMAGES OR RELIEF AT LAW OR IN EQUITY ON ACCOUNT OF THE FAILURE OF THE CLOSING TO OCCUR, EXCEPT FOR: (A) CLAIMS FOR THE RETURN OR OTHER DELIVERY OF DOCUMENTS IN CONNECTION WITH THIS AGREEMENT; (B) ACTIONS TO EXPUNGE A LIS PENDENS OR OTHER CLOUDS ON TITLE CAUSED BY BUYER; (C) CLAIMS ON ACCOUNT OF BUYER'S INDEMNITY OBLIGATIONS UNDER THIS AGREEMENT, AND (D) ATTORNEYS' FEES AND COSTS INCURRED BY SELLER INCIDENT TO CLAUSES (A) THROUGH (C). NOTWITHSTANDING THE FOREGOING, IN THE EVENT BUYER OBJECTS TO, FAILS TO COOPERATE WITH OR OTHERWISE OPPOSES SELLER'S WITHDRAWAL OF THE DEPOSIT OUT OF THE ESCROW, SELLER SHALL HAVE ALL OF THE REMEDIES OTHERWISE AVAILABLE TO SELLER AT LAW OR IN EQUITY. SELLER'S INITIALS BUYER'S INITIALS __________ __________
Liquidated. DAMAGES (LD)
Liquidated. DAMAGES FOR FAILURE TO MAINTAIN AND/OR PROVIDE SPARE PARTS: If the Contractor fails to provide any of the parts covered in this Contract or any Mini-bid Project Definitions issued hereunder within 24 hours of establishment of need for such parts, the Authorized User will deduct the ‘Daily Rate’ (see Daily Rate Formula above) from future invoice(s) for every day until the parts are received, to compensate the Authorized User for the loss of use of the Lift Equipment and the inconvenience created thereby. For this purpose, parts shall be considered those parts needed for “normal wear and tear” or “small” parts. The Authorized User’s Representative shall make the final determination, and will notify the Contractor of any failure to provide parts and will deduct the appropriate withholding amount from future monthly invoice(s).
Liquidated. DAMAGES FOR FAILURE TO COMPLETE MAINTENANCE DEFICIENCIES AS CITED BY THE STATE QUALIFIED ELEVATOR INSPECTOR: If the Contractor fails to timely correct maintenance deficiencies as identified by the State’s Qualified Elevator Inspector/Inspection Report, by the sooner of the time periods set forth in the State’s Qualified Elevator Inspector/Inspection Report or 30 days from Contractor’s receipt from the Authorized User Representative of the Qualified Elevator Inspector’s inspection report, the Authorized User Representative will notify the Contractor and deduct two
Liquidated. DAMAGES FOR EXCESS UNSCHEDULED LIFT EQUIPMENT DOWN-TIME: Lift Equipment cannot experience unscheduled down-time of more than six Facility working days per contract year per piece of Lift Equipment unless the Contractor’s failure to place the Lift Equipment back into service arises out of causes beyond the Contractor’s control and without the fault or negligence of the Contractor (i.e. acts of God, the public enemy, fires, floods, freight embargoes, regulated utilities delays, etc.). If Lift Equipment is down longer than the acceptable amount of time specified above, the Excess Lift Equipment Downtime Liquidated Damages Formula below will determine the Contractor’s liability therefore, not as a penalty, but as liquidated damages. The Contractor’s liability for such liquidated damages shall be the product of three factors: (i) the yearly contract costs; times
Liquidated. DAMAGES FOR FAILURE TO TIMELY SUBMITTHE MAINTENANCE CONTROL PLAN (MCP) FOR APPROVAL: If the Contractor fails to timely submit the MCP to the Authorized User Representative for approval, the Authorized User Representative will notify the Contractor and deduct one (1) time the Daily Rate (see above Daily Rate Formula) per Elevator, Escalators or other Lift Equipment from future monthly invoices for each and every day late until such time that the MCP is submitted to the Authorized User Representative for approval. The MCP is the support documentation used by the Authorized User Representative to certify that the maintenance service had been performed. In addition to the assessment of liquidated damages, the non-submittal the MCP will also result in a suspension of payments for the preventive maintenance monthly fee.
Liquidated. Damages If the Consultant fails to complete any Tasks of the Services by the date(s) outlined in Annex II, and provided such delays are not occasioned by delays on the part of the Centre in fulfilling contingent obligations as outlined in Clause 3 of this Contract, the Centre may without prejudice to all its other remedies under the Contract, deduct from the Contract Price, as liquidated damages, a sum equivalent to two percent (2%) of the Contract price for each week or part thereof of delay until actual delivery or performance, up to a maximum deduction of ten percent (10%) of the contract price. Once the maximum is reached, the Centre may terminate the Contract pursuant to Clause 17 of this Contract.
