Excusable Delay definition

Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

Excusable Delay means:

Excusable Delay means any delay of the completion of the Project beyond the expiration of the Contract Time caused by conditions beyond the control and without the fault or negligence of the Contractor such as strikes, embargoes, fire, unavoidable casualties, unusual delays in transportation, national emergency, and stormy and inclement weather conditions in which the work cannot continue. The financial inability of the Contractor or any subcontractor and default of any subcontractor, without limitation, shall not be deemed conditions beyond the Contractor's control. An Excusable Delay may entitle the Contractor to an adjustment in the Contract Time.

Examples of Excusable Delay in a sentence

• In the event the Design- Builder fails to provide the Safety Plan, the Design-Builder will not be permitted to commence the Construction Phase until the Safety Plan is submitted and in no event shall any resulting delay constitute an Excusable Delay.

• Notwithstanding the foregoing, no Excusable Delay will be deemed to exist unless the Developer notifies the City in writing of such Excusable Delay within 30 days after the commencement of the event causing such Excusable Delay (or within 30 days after the date that the Developer should reasonably have determined that such event will cause such Excusable Delay).

• The parties agree that as of the date of this Agreement, no known condition or event exists that would justify an Excusable Delay.

• An Excusable Delay shall not include any condition or circumstance caused or extended by the Developer or a Related Party or attributable to the action or inaction of the Developer or a Related Party.

• In the event the Design- Builder fails to provide the Safety Plan, the Design- Builder will not be permitted to commence the Construction Phase until the Safety Plan is submitted and in no event shall any resulting delay constitute an Excusable Delay.

More Definitions of Excusable Delay

Excusable Delay has the meaning set out in Clause 10.1.

Excusable Delay means unforeseeable delay beyond the Contractor or BSA’s control and not resulting from Contractor’s fault or negligence. Excusable Delay includes labor disputes, fire, Unusual Weather, unavoidable casualties and unusual delays in transportation.

Excusable Delay shall have the meaning attributed to it in Article 13.1;

Excusable Delay means any Delay to the path of activities that is critical to Substantial Completion of the Work within the Contract Time caused by conditions beyond the control or foreseeability, and without the fault or negligence of Contractor or its Subcontractors, such as, but not limited to: war, embargoes, fire, unavoidable casualties, unusual delays in transportation, national emergency, and stormy and inclement weather conditions that are unusual and unseasonable and in which the Work cannot continue. Without limitation to the foregoing, the financial inability of Contractor or any Subcontractor, shall not be deemed conditions beyond Contractor's control or foreseeability. Contractor may claim an Excusable Delay only if all Work on a critically scheduled activity is stopped for more than six (6) hours of a normal eight (8) hour work day, or if three to six hours are lost in one work day, then it may be claimed for one-half day.

Excusable Delay means delay due to strikes, acts of God, inability to obtain labor or materials, orders of any governmental authority having jurisdiction, removal of Hazardous Materials discovered at any time after the commencement of the Term, enemy action, civil commotion, fire, unusual inclement weather, unavoidable casualty or similar causes beyond the reasonable control of Tenant.

Excusable Delay means a delay solely due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Mezzanine Borrower or Mortgage Borrower, but Mezzanine Borrower’s or Mortgage Borrower’s lack of funds in and of itself shall not be deemed a cause beyond the control of Mezzanine Borrower or Mortgage Borrower, as applicable.

Excusable Delay means a delay, not to exceed a total of sixty (60) days, caused by unusually adverse weather conditions which have not been taken into account in the construction schedule, fire, earthquake or other acts of God, strikes, lockouts, acts of public enemy, riots or insurrections or any other unforeseen circumstances or events beyond the control of Borrower (except financial circumstances or events or matters which may be resolved by the payment of money), and as to which Borrower notifies Administrative Agent in writing within ten (10) days after such occurrence; provided, however, no Excusable Delay shall extend the Completion Date or suspend or xxxxx any obligation of Borrower or any Guarantor or any other person to pay any money.