Product Labeling The labeling of all Licensed Products sold or offered for sale under this Agreement shall expressly state that the Licensed Product is manufactured under a license from the Medicines Patent Pool.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Labeling Upon request, Lessee will xxxx the Equipment indicating Lessor's interest with labels provided by Lessor. Lessee will keep all Equipment free from any other marking or labeling which might be interpreted as a claim of ownership.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI. (b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Labelling The distributor, on behalf of the selected vendor agrees that all supplies of articles should invariably contain the following information on its label and the carton. One information should not be overlapped by any other information needed to be furnished. The label should contain : a. Name of the item as approved b. CMS Cat. No. c. Manufacturing date/Import date for the imported items. d. Expiry Date. (where applicable) e. Name & address of Registered Office of Manufacturers and place of manufacture. f. Manufacturing License Number. (where applicable for Manufactures) g. Batch Number (where applicable) h. Month and Year of supply. i. The label & Carton must invariably marked “W B. GOVT SUPPLY : NOT FOR SALE”. j. All Surgical items quoted/supplied by the tenderer must conform to IS /BIS /CE/USFDA. Pacemker must conform to CE & US FDA norms. In case of Drugs items quoted /supplied by tenderer MUST CONFORM TO IP, BP, or USP norms and N.F.I. –III specification as noted against the item(s) in catalogue as applicable. k. The MRP and Trade Name will not be allowed to be printed in any pack. This will lead to cancellation of candidature straightaway. However, for excisable products, insertion of writing of Govt MRP is allowed as per provision laid down in the order of the Central Excise dept. However, for imported item(s), MRP and Trade name may be allowed in addition to Generic name.
Product Quality (a) Tesoro warrants that all Products delivered under this Agreement or any Purchaser Order shall meet the latest applicable pipeline specifications or otherwise mutually agreed upon specifications for that Product upon receipt at the applicable Terminal and contain no deleterious substances or concentrations of any contaminants that may make it or its components commercially unacceptable in general industry application. Tesoro shall not deliver to any of the Terminals any Products which: (i) would in any way be injurious to any of the Terminals; (ii) would render any of the Terminals unfit for the proper storage of similar Products; (iii) would contaminate or otherwise downgrade the quality of the Products stored in commingled storage; (iv) may not be lawfully stored at the Terminals; or (v) otherwise do not meet applicable Product specifications for such Product that are customary in the location of the Terminal. If, however, there are Products that do not have such applicable specifications, the specifications shall be mutually agreed upon by the Parties. Should Tesoro’s commingled Products not meet or exceed the minimum quality standards set forth in this Agreement or any applicable Terminal Service Order, Tesoro shall be liable for all loss, damage and cost incurred thereby, including damage to Products of third parties commingled with Tesoro’s unfit Products. (b) TLO shall have the right to store compatible Products received for Tesoro’s account with Products belonging to TLO or third parties in TLO’s commingled storage tanks. TLO shall handle Tesoro’s fungible Products in accordance with TLO’s prevailing practices and procedures for handling such Products. The quality of all Products tendered into commingled storage for Tesoro’s account shall be verified either by Tesoro’s refinery analysis or supplier’s certification, such that Products so tendered shall meet TLO’s Product specifications. All costs for such analysis shall be borne solely by Tesoro. TLO shall have the right to sample any Product tendered to the Terminals hereunder. The cost of such sampling shall be borne solely by TLO. All Products returned to Tesoro shall meet or exceed Product specifications in effect on the date the Products are delivered to Tesoro. Notwithstanding any other provision herein, any and all Products that leave the Terminals shall meet all relevant ASTM, EPA, federal and state specifications, and shall not leave the Terminals in the form of a sub-octane grade Product. (c) TLO shall exercise reasonable care to ensure that all Products delivered by third parties into commingled storage with Tesoro’s Products meet applicable Product specifications for such Product that are customary in the location of the Terminal. In the event that Tesoro’s Products are commingled with third-party Products that do not meet or exceed the minimum quality standards set forth in this Agreement or any Terminal Service Order, TLO shall be liable for all loss, damage and cost incurred thereby.
PRODUCT MANUFACTURER'S SUPPLIERS Only those dealers/distributors listed by the manufacturer will be considered authorized to act on behalf of the Product Manufacturer.
Product Data Illustrations, standard schedules, performance charts, instructions, brochures, diagrams, and other information furnished by Developer to illustrate a material, product, or system for some portion of the Work.
RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
