Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.
Initial Forecasts/Trunking Requirements Because Verizon’s trunking requirements will, at least during an initial period, be dependent on the Customer segments and service segments within Customer segments to whom CSTC decides to market its services, Verizon will be largely dependent on CSTC to provide accurate trunk forecasts for both inbound (from Verizon) and outbound (to Verizon) traffic. Verizon will, as an initial matter, provide the same number of trunks to terminate Reciprocal Compensation Traffic to CSTC as CSTC provides to terminate Reciprocal Compensation Traffic to Verizon. At Verizon’s discretion, when CSTC expressly identifies particular situations that are expected to produce traffic that is substantially skewed in either the inbound or outbound direction, Verizon will provide the number of trunks CSTC suggests; provided, however, that in all cases Verizon’s provision of the forecasted number of trunks to CSTC is conditioned on the following: that such forecast is based on reasonable engineering criteria, there are no capacity constraints, and CSTC’s previous forecasts have proven to be reliable and accurate.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
GEOGRAPHIC AREA AND SECTOR SPECIFIC ALLOWANCES, CONDITIONS AND EXCEPTIONS The following allowances and conditions shall apply where relevant: Where the company does work which falls under the following headings, the company agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
