Collateral Protection Expenses Preservation of Collateral (a) If an Event of Default shall have occurred and be continuing, the Agent may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral, make repairs thereto and pay any necessary filing fees. Each Grantor agrees to reimburse the Agent on demand for any and all expenditures so made. The Agent shall have no obligation to any Grantor to make any such expenditures, nor shall the making thereof relieve any Grantor of any default. (b) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each contract or agreement comprised in the Collateral to be observed or performed by such Grantor thereunder. The Agent shall not have any obligation or liability under any such contract or agreement by reason of or arising out of this Agreement or the receipt by the Agent of any payment relating to any of the Collateral, nor shall the Agent be obligated in any manner to perform any of the obligations of any Grantor under or pursuant to any such contract or agreement, to make inquiry as to the nature or sufficiency of any payment received by the Agent in respect of the Collateral or as to the sufficiency of any performance by any party under any such contract or agreement, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts which may have been assigned to the Agent or to which the Agent may be entitled at any time or times. The Agent’s sole duty with respect to the custody, safe keeping and physical preservation of the Collateral in its possession, under Sections 9-207 and 9-208 of the UCC or otherwise, shall be to deal with such Collateral in the same manner as the Agent deals with similar property for its own account. (c) Each Grantor shall, to the extent reasonably necessary to preserve and maintain the Intellectual Property Collateral and the interest of the Agent therein, diligently pursue legal or other action to enforce the Intellectual Property Collateral and any licenses thereof.
Establishment of Collateral Accounts Securities Intermediary acknowledges and agrees that: (i) it has established and is maintaining on its books and records the accounts identified on the attached Schedule 1 (each such account, together with any replacements thereof or substitutions therefor, the “Collateral Account” and such accounts, collectively, the “Collateral Accounts”) in the name of the Borrower; (ii) each Collateral Account is a “securities account” (within the meaning of Section 8-501(a) of the UCC) in respect of which Securities Intermediary is a “securities intermediary” (within the meaning of Section 8-102(a)(14) of the UCC and, with respect to any Book-Entry Security, within the meaning of Federal Book-Entry Regulations) and the Security Agent is the “entitlement holder” (within the meaning of Section 8-102(a)(7) of the UCC); provided, however, that if, notwithstanding the intention of the parties hereto, all or any portion of the Collateral Account is determined to be a “deposit account” (within the meaning of Section 9-102 of the UCC) rather than a “securities account,” then the Securities Intermediary represents, warrants, covenants and agrees that it is a “bank” (as defined in Section 9-102(a)(8) of the UCC) and will treat the Borrower as its customer (within the meaning of Section 9-104(a)(3) of the UCC) with respect to the Collateral Accounts (or portion thereof); (iii) all property delivered, or to be delivered, to Securities Intermediary pursuant to this Agreement is, and will be, promptly credited to the Collateral Accounts; (iv) it does not know of any claim to or interest in any Collateral Account or any assets or funds therein, except for claims and interests of the parties to this Agreement as set forth herein; and (v) it shall not change the name or account number of any Collateral Account without the prior written consent of the Security Agent. Except as provided in Section 2(b), Securities Intermediary agrees that it shall not take “entitlement orders” (as defined in Section 8-102(a)(8) of the UCC) or “instructions” (within the meaning of Section 9-104(a)(2) of the UCC) with respect to the Collateral Accounts or any assets or funds therein from any Person other than the Security Agent.
Administration of the Mortgage Loans (a) Each of the Master Servicer and the Special Servicer shall service and administer the Mortgage Loans that it is obligated to service and administer pursuant to this Agreement on behalf of the Trustee, and in the best interests and for the benefit of the Certificateholders, in accordance with any and all applicable laws and the terms of this Agreement, the Insurance Policies and the respective Mortgage Loans and, to the extent consistent with the foregoing, in accordance with the Servicing Standard. Without limiting the foregoing, and subject to Section 3.21, (i) the Master Servicer shall service and administer all Mortgage Loans as to which no Servicing Transfer Event has occurred and all Corrected Mortgage Loans, and (ii) the Special Servicer shall service and administer (x) each Mortgage Loan (other than a Corrected Mortgage Loan) as to which a Servicing Transfer Event has occurred, and (y) each REO Property; provided, however, that the Master Servicer shall continue to collect information and prepare all reports to the Trustee required hereunder with respect to any Specially Serviced Mortgage Loans and REO Properties (and the related REO Loans), and further to render such incidental services with respect to any Specially Serviced Mortgage Loans and REO Properties as are specifically provided for herein. (b) Subject to Section 3.01(a), the Master Servicer and the Special Servicer each shall have full power and authority, acting alone, to do or cause to be done any and all things in connection with such servicing and administration which it may deem necessary or desirable. Without limiting the generality of the foregoing, each of the Master Servicer and the Special Servicer, in its own name, with respect to each of the Mortgage Loans it is obligated to service hereunder, is hereby authorized and empowered by the Trustee to execute and deliver, on behalf of the Certificateholders and the Trustee or any of them: (i) any and all financing statements, continuation statements and other documents or instruments necessary to maintain the lien created by any Mortgage or other security document in the related Mortgage File on the related Mortgaged Property and related collateral; (ii) in accordance with the Servicing Standard and subject to Sections 3.08 and 3.20, any and all modifications, waivers, amendments or consents to or with respect to any documents contained in the related Mortgage File; and (iii) any and all instruments of satisfaction or cancellation, or of partial or full release or discharge, and all other comparable instruments. Subject to Section 3.10, the Trustee shall, at the written request of a Servicing Officer of the Master Servicer or the Special Servicer, furnish, or cause to be so furnished, to the Master Servicer and the Special Servicer, as the case may be, any limited powers of attorney and other documents necessary or appropriate to enable them to carry out their servicing and administrative duties hereunder; provided, however, that the Trustee shall not be held liable for any misuse of any such power of attorney by the Master Servicer or the Special Servicer. (c) The relationship of each of the Master Servicer and Special Servicer to the Trustee under this Agreement is intended by the parties to be that of an independent contractor and not that of a joint venturer, partner or agent. (d) In the event that any two or more Mortgage Loans are cross-collateralized with each other, the Master Servicer or Special Servicer, as applicable, in accordance with the terms of this Agreement, shall service and administer such Mortgage Loans as a single Mortgage Loan as and when it deems necessary and appropriate, consistent with the Servicing Standard. If any Cross-Collateralized Mortgage Loan becomes a Specially Serviced Mortgage Loan, then each other Mortgage Loan that is cross-collateralized with it shall also become a Specially Serviced Mortgage Loan. Similarly, no Cross-Collateralized Mortgage Loan shall subsequently become a Corrected Mortgage Loan, unless and until all Servicing Transfer Events in respect of each other Mortgage Loan that is cross-collateralized with it, are remediated or otherwise addressed as contemplated in the definition of "Specially Serviced Mortgage Loan".
Maintenance of Collateral Accounts Maintain any Collateral Account except pursuant to the terms of Section 6.6(b) hereof.
Servicer to Maintain Perfection and Priority The Servicer covenants that, in order to evidence the interests of CNHCR and Issuing Entity under this Agreement, Servicer shall take such action, or execute and deliver such instruments as may be necessary or advisable (including, without limitation, such actions as are requested by Issuing Entity) to maintain and perfect, as a first priority interest, Issuing Entity’s security interest in the Receivables. Servicer shall, from time to time and within the time limits established by law, prepare and present to Issuing Entity for Issuing Entity to authorize the Servicer to file all financing statements, amendments, continuations, financing statements in lieu of a continuation statement, terminations, partial terminations, releases or partial releases, or any other filings necessary or advisable to continue, maintain and perfect the Issuing Entity’s security interest in the Receivables as a first-priority interest (each a “Filing”). Issuing Entity shall promptly authorize in writing Servicer to, and Servicer shall, effect such Filing under the Uniform Commercial Code without the signature of CNHCR or Issuing Entity where allowed by applicable law.
PRESERVATION, MANAGEMENT AND MAINTENANCE OF MORTGAGED PROPERTY (a) Borrower shall not commit waste or permit impairment or deterioration of the Mortgaged Property. (b) Borrower shall not abandon the Mortgaged Property. (c) Borrower shall restore or repair promptly, in a good and workmanlike manner, any damaged part of the Mortgaged Property to the equivalent of its original condition, or such other condition as Lender may approve in writing, whether or not insurance proceeds or condemnation awards are available to cover any costs of such restoration or repair; however, Borrower shall not be obligated to perform such restoration or repair if (i) no Event of Default has occurred and is continuing, and (ii) Lender has elected to apply any available insurance proceeds and/or condemnation awards to the payment of Indebtedness pursuant to Section 19(h)(ii), (iii), (iv) or (v), or pursuant to Section 20. (d) Borrower shall keep the Mortgaged Property in good repair, including the replacement of Personalty and Fixtures with items of equal or better function and quality. (e) Borrower shall provide for professional management of the Mortgaged Property by a residential rental property manager satisfactory to Lender at all times under a contract approved by Lender in writing, which contract must be terminable upon not more than 30 days notice without the necessity of establishing cause and without payment of a penalty or termination fee by Borrower or its successors. (f) Borrower shall give Notice to Lender of and, unless otherwise directed in writing by Lender, shall appear in and defend any action or proceeding purporting to affect the Mortgaged Property, Lender's security or Lender's rights under this Instrument. Borrower shall not (and shall not permit any tenant or other person to) remove, demolish or alter the Mortgaged Property or any part of the Mortgaged Property, including any removal, demolition or alteration occurring in connection with a rehabilitation of all or part of the Mortgaged Property, except (i) in connection with the replacement of tangible Personalty, (ii) if Borrower is a cooperative housing corporation or association, to the extent permitted with respect to individual dwelling units under the form of proprietary lease or occupancy agreement and (iii) repairs and replacements in connection with making an individual unit ready for a new occupant. (g) Unless otherwise waived by Lender in writing, Borrower must have or must establish and must adhere to the MMP. If the Borrower is required to have an MMP, the Borrower must keep all MMP documentation at the Mortgaged Property or at the management agent's office and available for the Lender or the Loan Servicer to review during any annual assessment or other inspection of the Mortgaged Property that is required by Lender. (h) If Borrower is a housing cooperative corporation or association, until the Indebtedness is paid in full Borrower shall not reduce the maintenance fees, charges or assessments payable by shareholders or residents under proprietary leases or occupancy agreements below a level which is sufficient to pay all expenses of the Borrower, including, without limitation, all operating and other expenses for the Mortgaged Property and all payments due pursuant to the terms of the Note and any Loan Documents.
Preservation of Collateral Following the occurrence of a Default or Event of Default, in addition to the rights and remedies set forth in Section 11.1 hereof, Agent: (a) may at any time take such steps as Agent deems necessary to protect Agent’s interest in and to preserve the Collateral, including the hiring of such security guards or the placing of other security protection measures as Agent may deem appropriate; (b) may employ and maintain at any of any Borrower’s premises a custodian who shall have full authority to do all acts necessary to protect Agent’s interests in the Collateral; (c) may lease warehouse facilities to which Agent may move all or part of the Collateral; (d) may use any Borrower’s owned or leased lifts, hoists, trucks and other facilities or equipment for handling or removing the Collateral; and (e) shall have, and is hereby granted, a right of ingress and egress to the places where the Collateral is located, and may proceed over and through any of Borrowers’ owned or leased property. Each Borrower shall cooperate fully with all of Agent’s efforts to preserve the Collateral and will take such actions to preserve the Collateral as Agent may direct. All of Agent’s expenses of preserving the Collateral, including any expenses relating to the bonding of a custodian, shall be charged to Borrowers’ Account as a Revolving Advance maintained as a Domestic Rate Loan and added to the Obligations.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Establishment of Collateral Account The Securities Intermediary hereby confirms that: (a) the Securities Intermediary has established the Collateral Account; (b) the Collateral Account is a securities account; (c) subject to the terms of this Agreement, the Securities Intermediary shall identify in its records the Collateral Agent as the entitlement holder entitled to exercise the rights that comprise any financial asset credited to the Collateral Account; (d) all property delivered to the Securities Intermediary pursuant to this Agreement, including any Applicable Ownership Interests in the Treasury Portfolio (as specified in clause (i) of the definition thereof) or Treasury Securities and the Permitted Investments, will be credited promptly to the Collateral Account; and (e) all securities or other property underlying any financial assets credited to the Collateral Account shall be (i) registered in the name of the Purchase Contract Agent and indorsed to the Securities Intermediary or in blank, (ii) registered in the name of the Securities Intermediary or (iii) credited to another securities account maintained in the name of the Securities Intermediary. In no case will any financial asset credited to the Collateral Account be registered in the name of the Purchase Contract Agent (in its capacity as such) or any Holder or specially indorsed to the Purchase Contract Agent (in its capacity as such) or any Holder, unless such financial asset has been further indorsed to the Securities Intermediary or in blank.
ADMINISTRATION OF THE CONTRACT 2.2.1 The Architect will provide administration of the Contract as hereinafter described. 2.2.2 The Architect will be the State's representative during construction and until final payment is due. The Architect will advise and consult with the State. The State's instructions to the Contractor shall be forwarded through the Architect. The Architect will have authority to act on behalf of the State only to the extent provided in the Contract Documents, unless otherwise modified by written instrument in accordance with Subparagraph 2.2.10. 2.2.3 The Architect will visit the site at intervals appropriate to the stage of construction to familiarize himself or herself generally with the progress and quality of the Work and to determine in general if the Work is proceeding in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of his or her on-site observations as an architect, he or she will keep the State informed of the progress of the Work, and will endeavor to guard the State against defects and deficiencies in the Work of the Contractor. 2.2.4 The Architect will not be responsible for and will not have control or charge of construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and he or she will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. The Architect will not be responsible for or have control or charge over the acts or omissions of the Contractor, 2.2.5 The Architect shall at all times have access to the Work wherever it is in preparation and progress. The Contractor shall provide facilities for such access so the Architect may perform his or her functions under the Contract Documents.