Actions of Custodian Based on Proper Instructions and Special Instructions So long as and to the extent that the Custodian acts in accordance with (a) Proper Instructions or Special Instructions, as the case may be, and (b) the terms of this Agreement, the Custodian shall not be responsible for the title, validity or genuineness of any property, or evidence of title thereof, received by it or delivered by it pursuant to this Agreement.
Administration of Agreement All approvals referenced in this Agreement must be obtained from the parties' contract administrators or their designees. All notices must be given to the parties' contract administrators respectively. The OAG's contract administrator is Xxxxxxxxx X. Xxxxxx, Chief, Bureau of Advocacy and Grants Management. The Provider’s contract administrator will be provided at the time of execution. The parties will provide each other with written notification of any change in its designated representative for this Agreement. Such changes do not require a formal written amendment to this Agreement.
Administration and Servicing of Contracts 43 SECTION 3.01
EFFECTIVE DATE AND TERMINATION OF THE CUSTODIAN AS FOREIGN CUSTODY MANAGER The Board's delegation to the Custodian as Foreign Custody Manager of the Portfolios shall be effective as of the date hereof and shall remain in effect until terminated at any time, without penalty, by written notice from the terminating party to the non-terminating party. Termination will become effective thirty (30) days after receipt by the non-terminating party of such notice. The provisions of Section 3.2.2 hereof shall govern the delegation to and termination of the Custodian as Foreign Custody Manager of the Portfolios with respect to designated countries.
Amendments of Sale and Servicing Agreement and Trust Agreement The Issuer shall not agree to any amendment to Section 9.01 of the Sale and Servicing Agreement or Section 11.01 of the Trust Agreement to eliminate the requirements thereunder that the Indenture Trustee or the Noteholders consent to amendments thereto as provided therein.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Trustee’s Application for Instructions from the Company Any application by the Trustee for written instructions from the Company (other than with regard to any action proposed to be taken or omitted to be taken by the Trustee that affects the rights of the Holders of the Notes under this Indenture) may, at the option of the Trustee, set forth in writing any action proposed to be taken or omitted by the Trustee under this Indenture and the date on and/or after which such action shall be taken or such omission shall be effective. The Trustee shall not be liable to the Company for any action taken by, or omission of, the Trustee in accordance with a proposal included in such application on or after the date specified in such application (which date shall not be less than three Business Days after the date any officer that the Company has indicated to the Trustee should receive such application actually receives such application, unless any such officer shall have consented in writing to any earlier date), unless, prior to taking any such action (or the effective date in the case of any omission), the Trustee shall have received written instructions in accordance with this Indenture in response to such application specifying the action to be taken or omitted.
Administration of the Agreement The Agreement shall be administered by the Board of Directors of the Company or its delegate (the “Administrator”). Subject to the provisions of the Agreement, the Administrator shall have full and final authority in its discretion to take any action with respect to the Agreement including, without limitation, the authority to (i) determine all matters relating to the payments; (ii) establish, amend and rescind rules and regulations for the administration of the Agreement; and (iii) construe and interpret the Agreement, to interpret rules and regulations for administering the Agreement and to make all other determinations deemed necessary or advisable for administering the Agreement. Except to the extent otherwise required under Section 409A of the Internal Revenue Code of 1986, as amended (“Code”), the Administrator shall have the authority, in its sole discretion, to accelerate the date that any Consultation Payments or Separation Payments which were not otherwise vested or earned shall become vested or earned in whole or in part without any obligation to accelerate such date with respect to any other employee. The Administrator also may in its sole discretion determine that Executive’s rights or payments under the Agreement shall be subject to reduction, cancellation, forfeiture or recoupment due to conduct by Executive that is determined by the Administrator to be detrimental to the business or reputation of the Company, including, without limitation, upon termination of employment for cause; violation of policies of the Company; or breach of non-solicitation, noncompetition, confidentiality or other restrictive covenants that apply to the Executive. In addition to action by meeting in accordance with applicable laws, any action of the Administrator with respect to the Agreement may be taken by a written instrument signed by the Administrator (including, where the Board or a committee serves as the Administrator, by written consent signed by all of the members of the Board, or all of the members of a committee, and any such action so taken by written consent shall be as fully effective as if it had been taken by a majority of the members at a meeting duly held and called). No individual shall be liable while acting as Administrator for any action or determination made in good faith with respect to the Agreement, and any such individual shall be entitled to indemnification and reimbursement in the manner provided in the Company’s certificate of incorporation and bylaws and/or under applicable law.
Custodial Agreement 10 Custodian.....................................................................................10 Cut-off Date..................................................................................10
Responsibility for Contract Administration The Servicer will have the sole obligation to manage, administer, service and make collections on the Contracts and perform or cause to be performed all contractual and customary undertakings of the holder of the Contracts to the Obligor. The Owner Trustee, at the written request of a Servicing Officer, shall furnish the Servicer with any powers of attorney or other documents necessary or appropriate in the opinion of the Owner Trustee to enable the Servicer to carry out its servicing and administrative duties hereunder. The Servicer is hereby appointed the servicer hereunder until such time as any Service Transfer may be effected under Article VIII.
