Administration of Medication CONTRACTOR shall comply with the requirements of California Education Code section 49423 when CONTRACTOR serves a student that is required to take prescription and/or over-the-counter medication during the school day. CONTRACTOR may designate personnel to assist the student with the administration of such medication after the student’s parent(s) provides to CONTRACTOR: (a) a written statement from a physician detailing the type, administration method, amount, and time schedules by which such medication shall be taken; and (b) a written statement from the student’s parent(s) granting CONTRACTOR permission to administer medication(s) as specified in the physician’s statement. CONTRACTOR shall maintain, and provide to LEA upon request, copies of such written statements. CONTRACTOR shall maintain a written log for each student to whom medication is administered. Such written log shall specify the student’s name; the type of medication; the date, time, and amount of each administration; and the name of CONTRACTOR’s employee who administered the medication. CONTRACTOR maintains full responsibility for assuring appropriate staff training in the administration of such medication consistent with physician’s written orders. Any change in medication type, administration method, amount or schedule must be authorized by both a licensed physician and parent.
ADMINISTRATION OF THE CONTRACT 2.2.1 The Architect will provide administration of the Contract as hereinafter described.
2.2.2 The Architect will be the State's representative during construction and until final payment is due. The Architect will advise and consult with the State. The State's instructions to the Contractor shall be forwarded through the Architect. The Architect will have authority to act on behalf of the State only to the extent provided in the Contract Documents, unless otherwise modified by written instrument in accordance with Subparagraph 2.2.10.
2.2.3 The Architect will visit the site at intervals appropriate to the stage of construction to familiarize himself or herself generally with the progress and quality of the Work and to determine in general if the Work is proceeding in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of his or her on-site observations as an architect, he or she will keep the State informed of the progress of the Work, and will endeavor to guard the State against defects and deficiencies in the Work of the Contractor.
2.2.4 The Architect will not be responsible for and will not have control or charge of construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and he or she will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. The Architect will not be responsible for or have control or charge over the acts or omissions of the Contractor,
2.2.5 The Architect shall at all times have access to the Work wherever it is in preparation and progress. The Contractor shall provide facilities for such access so the Architect may perform his or her functions under the Contract Documents.
Administration Services When a medical prescription drug is administered by infusion, the administration of the prescription drug may be covered separately from the prescription drug. See Infusion Therapy - Administration Services in the Summary of Medical Benefits for benefit limits and the amount you pay. Prescription drugs that are self-administered are not covered as a medical benefit but may be covered as a pharmacy benefit. Please see Pharmacy Prescription Drugs and Diabetic Equipment or Supplies – Pharmacy Benefits section above for additional information. For some medical prescription drugs, after the first administration, coverage may be limited to certain locations (for example, a designated outpatient or ambulatory service facility, physician’s office, or your home), provided the location is appropriate based on your medical status. For a list of medical prescription drugs that are subject to this Site of Care Program, visit our website. Preauthorization may be required to determine medical necessity as well as appropriate site of care. If we deny your request for preauthorization, or you disagree with our determination for the appropriate site of care, you can submit a medical appeal. See Appeals in Section 5 for information on how to file a medical appeal.
Administration of the Bank a. The Committee maintains records of employees participating, receives requests, verifies validity, approves, and communicates actions to members and to the District.
b. Decisions will be final and made in writing to the applicant within ten (10) working days of the application to the Committee.
c. All requests and actions by the Committee will be confidential.
d. The District will keep records and notify the Committee monthly of new members and days remaining in the Bank.
e. If the Catastrophic Leave Program is discontinued, the Committee will continue to administer Catastrophic Leave days until the days in the Bank are exhausted.
f. In order to protect someone from being charged an extra day when not necessary, the Committee shall set the maximum number of days in the bank after the first year of experience. If the number of days accumulated exceeds the maximum number of days, no contributions will be assessed except for new members wishing to join the bank.
Administration of the Plan Subject to the final authority of the Board, the administration of the plan shall be vested in the Human Resources Department. The Human Resources Department shall keep a record of the credits and deductions for each employee and shall provide a statement in hours to each employee annually of the state of their credit under the plan.
Administration of Agreement All approvals referenced in this Agreement must be obtained from the parties' contract administrators or their designees. All notices must be given to the parties' contract administrators respectively. The OAG's contract administrator is Xxxxxxxxx X. Xxxxxx, Chief, Bureau of Advocacy and Grants Management. The Provider’s contract administrator will be provided at the time of execution. The parties will provide each other with written notification of any change in its designated representative for this Agreement. Such changes do not require a formal written amendment to this Agreement.
Administration of Plan The Plan is administered by the Committee appointed by the Company’s Board of Directors. The Committee has the authority to construe and interpret the Plan, to make rules of general application relating to the Plan, to amend outstanding awards pursuant to the Plan, and to require of any person receiving an award, at the time of such receipt or lapse of restrictions, the execution of any paper or the making of any representation or the giving of any commitment that the Committee shall, in its discretion, deem necessary or advisable by reason of the securities laws of the United States or any State, or the execution of any paper or the payment of any sum of money in respect of taxes or the undertaking to pay or have paid any such sum that the Committee shall in its discretion, deem necessary by reason of the Internal Revenue Code or any rule or regulation thereunder, or by reason of the tax laws of any State.
Administration of the Agreement The Agreement shall be administered by the Board of Directors of the Company or its delegate (the “Administrator”). Subject to the provisions of the Agreement, the Administrator shall have full and final authority in its discretion to take any action with respect to the Agreement including, without limitation, the authority to (i) determine all matters relating to the payments; (ii) establish, amend and rescind rules and regulations for the administration of the Agreement; and (iii) construe and interpret the Agreement, to interpret rules and regulations for administering the Agreement and to make all other determinations deemed necessary or advisable for administering the Agreement. Except to the extent otherwise required under Section 409A of the Internal Revenue Code of 1986, as amended (“Code”), the Administrator shall have the authority, in its sole discretion, to accelerate the date that any Consultation Payments or Separation Payments which were not otherwise vested or earned shall become vested or earned in whole or in part without any obligation to accelerate such date with respect to any other employee. The Administrator also may in its sole discretion determine that Executive’s rights or payments under the Agreement shall be subject to reduction, cancellation, forfeiture or recoupment due to conduct by Executive that is determined by the Administrator to be detrimental to the business or reputation of the Company, including, without limitation, upon termination of employment for cause; violation of policies of the Company; or breach of non-solicitation, noncompetition, confidentiality or other restrictive covenants that apply to the Executive. In addition to action by meeting in accordance with applicable laws, any action of the Administrator with respect to the Agreement may be taken by a written instrument signed by the Administrator (including, where the Board or a committee serves as the Administrator, by written consent signed by all of the members of the Board, or all of the members of a committee, and any such action so taken by written consent shall be as fully effective as if it had been taken by a majority of the members at a meeting duly held and called). No individual shall be liable while acting as Administrator for any action or determination made in good faith with respect to the Agreement, and any such individual shall be entitled to indemnification and reimbursement in the manner provided in the Company’s certificate of incorporation and bylaws and/or under applicable law.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Administration of the Trust (a) The Trustee shall administer the Trust Property for the benefit of the Unitholders. In engaging in such activities, the Trustee shall follow or cause to be followed collection procedures in accordance with the terms of the Trust Agreement, the Underlying Securities, the Swap Agreement, the indemnification offered by the Depositor pursuant to Section 10.05(b) and the Guarantee. The duties of the Trustee shall be performed in accordance with applicable local, State and Federal law.
(b) Subject to Article X, the Trustee is hereby authorized to perform, and from time to time hereafter, shall perform only those acts which are described in the Trust Agreement as obligations of the Trustee. Notwithstanding the generality of the foregoing, the Trustee is hereby specifically authorized to do the following on behalf of the Trust: to issue the Certificates evidencing Units; to execute and deliver and perform its obligations and exercise its rights under the Swap Agreement; to establish and maintain the Unit Account hereunder; to accept delivery of the Underlying Securities and the Swap Agreement; to pledge the assets of the Trust (including the Underlying Securities) to secure the obligations of the Trust including obligations under the Swap Agreement; to sell the Underlying Securities through the Selling Agent in accordance with Section 9.05; to make Permitted Investments pursuant to Section 3.06; to liquidate the Trust pursuant to Article IX and to make distributions pursuant to Article IV.
(c) Notwithstanding anything to the contrary herein, the Trust shall not engage in any business or activities other than receiving the Underlying Securities and any Credit Support or other Trust Property and entering into the Swap Agreement as provided herein, holding the Underlying Securities, the Swap Agreement and any Credit Support (or other Trust Property), issuing Certificates evidencing Units, making Permitted Investments in accordance with Section 3.06 and performing its obligations hereunder and under the Swap Agreement; provided, however, that during its existence the Trust shall not engage in any business or activity which will cause it to be or become an open-end investment company, unit investment trust or face-amount certificate company that is or is required to be registered under Section 8 of the Investment Company Act, or to be or become a closed-end investment company required to be registered, but not registered, under the Investment Company Act.
(d) The Trustee shall not sell, assign, pledge or otherwise transfer the Underlying Securities, the Swap Agreement, any Credit Support or other Trust Property, or any interest of the Trust therein, to any Person or Persons, except to a successor trustee as provided in Section 10.07, through the Selling Agent in accordance with Section 9.05, in accordance with Section 10.02(a)(x), as required under any Swap Agreement or as otherwise expressly permitted hereunder. This section shall not be construed to prohibit transfers of the Units.
(e) The Trustee shall have the legal power to exercise all of the rights, powers and privileges of holders of the Underlying Securities in which the Units evidence an interest; provided, however, that the exercise of such powers shall be subject to the provisions of this Section 3.02, Article X and the other provisions hereof. However, neither the Trustee (except as specifically provided herein or in the TIA) nor the Depositor shall be under any obligation whatsoever to appear in, prosecute or defend any action, suit or other proceeding in respect of Underlying Securities or Units.
(f) Except for actions expressly authorized by the Trust Agreement, the Trustee shall not take actions reasonably likely to (nor fail to take actions, if such failure would be reasonably likely to) (i) impair the interests of the Trust in any Underlying Security, any Credit Support, the Swap Agreement or the Guarantee (or any other Trust Property); (ii) impair the value of any Underlying Security, any Credit Support, the Swap Agreement or the Guarantee (or any other Trust Property); or (iii) alter the classification of a Trust for U.S. federal income tax purposes.
(g) Except as expressly provided in the Trust Agreement, the Trustee shall have no power to vary the corpus of the Trust Property including by (i) accepting any substitute obligation or asset for a Underlying Security or any Credit Support, (ii) entering into any amendment or modification of the Swap Agreement or the Underlying Securities, (iii) accepting any substitute guarantee for the Guarantee, (iv) adding any other investment, obligation or security to the Trust Property, (v) withdrawing from the Trust Property any Underlying Securities or Credit Support, (vi) terminating the Swap Agreement except in accordance with its terms or (vii) rejecting or otherwise failing to accept the continuing benefits of the Guarantee.
