Requesting Price Increase/Required Documentation Contractor must submit a written notification at least thirty (30) calendar days prior to the requested effective date of the change, setting the amount of the increase, along with an itemized list of any increased prices, showing the Contractor’s current price, revised price, the actual dollar difference and the percentage of the price increase by line item. Price change requests must include H-GAC Forms D Offered Item Pricing and E Options Pricing, or the documentation used to submit pricing in the original Response and be supported with substantive documentation (e.g. manufacturer's price increase notices, copies of invoices from suppliers, etc.) clearly showing that Contractor's actual costs have increased per the applicable line item bid. The Producer Price Index (PPI) may be used as partial justification, subject to approval by H-GAC, but no price increase based solely on an increase in the PPI will be allowed. This documentation should be submitted in Excel format to facilitate analysis and updating of the website. The letter and documentation must be sent to the Bids and Specifications manager, Xxxxxxx Xxxxxx, at Xxxxxxx.Xxxxxx@x-xxx.xxx Review/Approval of Requests If H-GAC approves the price increase, Contractor will be notified in writing; no price increase will be effective until Contractor receives this notice. If H-GAC does not approve Contractor’s price increase, Contractor may terminate its performance upon sixty (60) days advance written notice to H-GAC, however Contractor must fulfill any outstanding Purchase Orders. Termination of performance is Contractor’s only remedy if H-GAC does not approve the price increase. H-GAC reserves the right to accept or reject any price change request.
Why did I get this Notice This is a court-authorized notice of a proposed settlement in a class action lawsuit, XxXxxxx, et al. v. Veriff, Inc., No. 2021L001202, pending in the Circuit Court of DuPage County, Illinois before the Xxx. Xxxxx Xxxxxxx. The Settlement would resolve a lawsuit brought on behalf of persons who allege that Veriff, Inc., collected individuals’ biometrics in Illinois through its identity-verification technology without first providing the individuals with legally-required written disclosures and obtaining written consent. If you received notice of this Settlement, you have been identified as someone who, at some time between November 12, 2016 and [Preliminary Approval], had biometrics collected, captured, purchased, received through trade, possessed, retained or otherwise obtained while in Illinois by Veriff or its technology for the purposes of identity verification, and whose identity was verified. The Court has granted preliminary approval of the Settlement and has conditionally certified the Settlement Class for purposes of settlement only. This notice explains the nature of the class action lawsuit, the terms of the Settlement, and the legal rights and obligations of the Settlement Class Members. Please read the instructions and explanations below so that you can better understand your legal rights. WHAT IS THIS LAWSUIT ABOUT? The Illinois Biometric Information Privacy Act (“BIPA”), 740 ILCS 14/1, et seq., prohibits private companies from capturing, obtaining, storing, transmitting, and/or using the biometric identifiers and/or information, such as scans of face geometry, of another individual for any purpose without first providing them with certain written disclosures and obtaining written consent. This lawsuit alleges that Defendant violated BIPA by collecting or capturing the scans of face geometry of individuals through identity verification technology in Illinois without first providing the requisite disclosures or obtaining the consent required by BIPA. Defendant contests these claims, denies that it collected or possessed facial biometrics or any other information subject to BIPA, and denies that it violated BIPA. WHY IS THIS A CLASS ACTION? A class action is a lawsuit in which an individual called a “Class Representative” brings a single lawsuit on behalf of other people who have similar claims. All of these people together are a “Class” or “Class Members.” Once a Class is certified, a class action Settlement finally approved by the Court resolves the issues for all Settlement Class Members, except for those who exclude themselves from the Settlement Class. WHY IS THERE A SETTLEMENT? To resolve this matter without the expense, delay, and uncertainties of litigation, the Parties have reached a Settlement, which resolves all claims against Defendant and its affiliated entities. The Settlement requires Defendant to pay money to the Settlement Class, as well as pay settlement administration expenses, attorneys’ fees and costs to Class Counsel, and Incentive Awards to each of the Class Representatives, if approved by the Court. The Settlement is not an admission of wrongdoing by Defendant and does not imply that there has been, or would be, any finding that Defendant violated the law. The Court has already preliminarily approved the Settlement. Nevertheless, because the settlement of a class action determines the rights of all members of the class, the Court overseeing this lawsuit must give final approval to the Settlement before it can be effective. The Court has conditionally certified the Settlement Class for settlement purposes only, so that members of the Settlement Class can be given this notice and the opportunity to exclude themselves from the Settlement Class, to voice their support or opposition to final approval of the Settlement, and to submit a Claim Form to receive the relief offered by the Settlement. If the Court does not give final approval to the Settlement, or if it is terminated by the Parties, the Settlement will be void, and the lawsuit will proceed as if there had been no settlement and no certification of the Settlement Class.
Notification of the Amount of Fair Share Fee Notice of the amount of the annual fair share fee, which shall not be more than 100% of the unified dues of the employee organization, shall be transmitted by the employee organization to the Board Treasurer on or about September 15 of each year during the term of this Agreement for the purpose of determining amounts to be payroll-deducted, and the Board agrees to promptly transmit all amounts deducted to the employee organization.
Amount of Rs ( ) (not exceeding 95% of the total consideration) to be paid to the Promoter on completion of the lifts, water pumps, electrical fittings, electro, mechanical and environment requirements, entrance lobby/s, plinth protection, paving of areas appertain and all other requirements as may be prescribed in the Agreement of sale of the building or wing in which the said Apartment is located.
Notice to Proceed (NTP Following the JOA and purchase order issuance, the County will issue a Notice to Proceed (NTP) that will provide the construction start date, the Work duration period, and the Substantial Completion date. The Contractor agrees to begin and complete construction within the dates specified on the NTP. The County must approve all extensions of time in writing. The County may also issue an Emergency Notice to Proceed (NTP). In the event the County requires the Contractor to respond to an immediate request for work, a Job Order will be created and an Emergency NTP will be issued. The Contractor will be required to perform the Scope of Work included with the Emergency NTP as directed by the County’s Project Manager or designee. The Detailed Scope of Work, Quotation, Subcontractor Listing, Shop Drawings and required Non Pre-priced backup documentation will be submitted upon completion of the emergency work in accordance with the Ordering Procedures detailed in Section III above.
Delay Claim Must Be In Writing Any claim to extend the Contract Time and Material Completion and Occupancy Date must be in writing, must set forth in detail the basis for the claim and the number of days of delay claimed, must be correlated with the approved Overall Project Schedule, must be executed by the Contractor and delivered to the Design Professional and the Owner, and must be reviewed and an appropriate time assessed by the Design Professional.
Physical Demand Sitting; close vision; use of hands to finger, handle, or feel objects, tools or controls.
Reimbursable Expenses; Maximum Total Payment; Invoicing District will make no payment until this Contract is fully executed by the authorized representatives of both parties.
MAXIMUM OBLIGATION The total Maximum Obligation of County to the Subrecipient for the cost of services provided in accordance with this Contract is $ 350,000, with individual Maximum Obligation budgets for each Fiscal Year as further detailed in the Budget Schedule, identified and incorporated herein by this reference as Attachment “C”.
Calculation of Liquidation Amount Upon the occurrence of a Liquidation Date:
