Agreement for diversion of water Sample Clauses

Related to Agreement for diversion of water

Certification Regarding Entire TIPS Agreement for Part 1 and Part 2 Contracts 5 This is a two part solicitation. Part 1 is solicited for TIPS sales that are not considered a "public work" construction project. Part 1 permits the sale of goods and non-construction/non-"public work" services such as maintenance and minor repairs. Part 2 Job Order Contract (JOC) is solicited for projects considered by your TIPS Member Customers to be a "public work" construction project. The determination of whether or not a TIPS sale amounts to a "public work" construction project requiring a Part 2 JOC contract is made by the TIPS Member Customer at the time of each TIPS sale. Thus, Vendors are encouraged to respond to both Parts 1 and 2 in case your TIPS Member Customers require that a sale be made under one Part or the other. However, responding to both Parts is not required. If Vendor responds and is awarded to both Parts, Vendor will have one contract for Part 1 and a separate contract for Part 2.
Requirement for Project Planning No physical work will begin on the construction site until the receipt of a Proceed Order issued by the Owner. The Contract assumes that a Proceed Order will be issued in not more than sixty days from the Effective Date of the Contract. Failure of the Contractor to provide the necessary documentation for the issuance of a Proceed Order shall not entitle the Contractor to any extension of time. If a Proceed Order is not issued within sixty days from the award of the Contract and non-issuance is due to nonperformance by the Contractor, the Contractor may be in default.
Clinical Management for Behavioral Health Services (CMBHS) System The CMBHS is the official record of documentation by System Agency. Grantee shall:
Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $696,243.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
Your Billing Rights: Keep This Document For Future Use This notice tells you about your rights and our responsibilities under the Fair Credit Billing Act.
Volunteer Agreement I understand that my services are donated to Mayo Clinic Health System without promise, expectation, or receipt of compensation or future employment. I also understand that volunteering should not be viewed as a means of obtaining permanent employment at Mayo Clinic Health System. I agree to comply with all policies and guidelines of Mayo Clinic Health System and its volunteer program. I attest that I have reviewed, understand, and have been provided the opportunity to ask questions about the material in this document.
Files Management and Record Retention relating to Grantee and Administration of this Agreement a. The Grantee shall maintain books, records, and documents in accordance with generally accepted accounting procedures and practices which sufficiently and properly reflect all expenditures of funds provided by Florida Housing under this Agreement.
System for Award Management (XXX) Requirement Alongside a signed copy of this Agreement, Grantee will provide Florida Housing with a XXX.xxx proof of registration and Commercial and Government Entity (CAGE) number. Grantee will continue to maintain an active XXX registration with current information at all times during which it has an active award under this Agreement.
Project Monitoring by the State The State may conduct on-site or off-site monitoring reviews of the Project during the term of this Grant Agreement and for up to ninety (90) days after it expires or is otherwise terminated. The Grantee shall extend its full cooperation and give full access to the Project site and to relevant documentation to the State or its authorized designees for the purpose of determining, among other things:
Selection of Consulting Services 7. Except as ADB may otherwise agree, and except as set forth in the paragraph below, the Borrower shall apply quality- and cost-based selection for selecting and engaging Consulting Services. Schedule 4