Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Development Agreement As soon as reasonably practicable following the ISO’s selection of a transmission Generator Deactivation Solution, the ISO shall tender to the Developer that proposed the selected transmission Generator Deactivation Solution a draft Development Agreement, with draft appendices completed by the ISO to the extent practicable, for review and completion by the Developer. The draft Development Agreement shall be in the form of the ISO’s Commission-approved Development Agreement for its reliability planning process, which is in Appendix C in Section 31.7 of Attachment Y of the ISO OATT, as amended by the ISO to reflect the Generator Deactivation Process. The ISO and the Developer shall finalize the Development Agreement and appendices as soon as reasonably practicable after the ISO’s tendering of the draft Development Agreement. For purposes of finalizing the Development Agreement, the ISO and Developer shall develop the description and dates for the milestones necessary to develop and construct the selected project by the required in-service date identified in the Generator Deactivation Assessment, including the milestones for obtaining all necessary authorizations. Any milestone that requires action by a Connecting Transmission Owner or Affected System Operator identified pursuant to Attachment P of the ISO OATT to complete must be included as an Advisory Milestone, as that term is defined in the Development Agreement. If the ISO or the Developer determines that negotiations are at an impasse, the ISO may file the Development Agreement in unexecuted form with the Commission on its own, or following the Developer’s request in writing that the agreement be filed unexecuted. If the Development Agreement is executed by both parties, the ISO shall file the agreement with the Commission for its acceptance within ten (10) Business Days after the execution of the Development Agreement by both parties. If the Developer requests that the Development Agreement be filed unexecuted, the ISO shall file the agreement at the Commission within ten (10) Business Days of receipt of the request from the Developer. The ISO will draft, to the extent practicable, the portions of the Development Agreement and appendices that are in dispute and will provide an explanation to the Commission of any matters as to which the parties disagree. The Developer will provide in a separate filing any comments that it has on the unexecuted agreement, including any alternative positions it may have with respect to the disputed provisions. Upon the ISO’s and the Developer’s execution of the Development Agreement or the ISO’s filing of an unexecuted Development Agreement with the Commission, the ISO and the Developer shall perform their respective obligations in accordance with the terms of the Development Agreement that are not in dispute, subject to modification by the Commission. The Connecting Transmission Owner(s) and Affected System Operator(s) that are identified in Attachment P of the ISO OATT in connection with the selected transmission Generator Deactivation Solution shall act in good faith in timely performing their obligations that are required for the Developer to satisfy its obligations under the Development Agreement.
Property Management Agreement The Property Management Agreement is in full force and effect and, to Borrower's Knowledge, there are no defaults thereunder by any party thereto and no event has occurred that, with the passage of time and/or the giving of notice would constitute a default thereunder.
Project Agreement 1.1 If applicable, the Department will recommend approval of the project by the Federal Highway Administration. 1.2 The Sponsor agrees to comply with Title VI of the Civil Rights Act of 1964, 78 Stat. § 252, 42 U.S.C. § 2000d et seq., and all requirements imposed by or pursuant to Title 49, Code of Federal Regulations, Part 21 - “Nondiscrimination in federally assisted programs of the Department of Transportation - effectuation of Title VI of the Civil Rights Act 1964". 1.3 The DEPARTMENT and SPONSOR mutually recognize that each party is a governmental entity subject to the provisions of the Governmental Tort Claims Act (51 O.S. § 151 et seq.). The DEPARTMENT and SPONSOR hereby mutually agree that each is and may be held severally liable for any and all claims, demands, and suits in law or equity, of any nature whatsoever, paying for damages or otherwise, arising from any negligent act or omission of any of their respective employees, agents or contractors which may occur during the prosecution or performance of this Agreement to the extent provided in the Governmental Tort Claims Act. Each party agrees to severally bear all costs of investigation and defense of claims arising under the Governmental Tort Claims Act and any judgments which may be rendered in such cause to the limits provided by law. Nothing in this section shall be interpreted or construed to waive any legal defense which may be available to a party or any exemption, limitation or exception which may be provided by the Governmental Tort Claims Act. 1.4 The Sponsor understands that should it fail to fulfill its responsibilities under this Agreement, such a failure will disqualify the Sponsor from future Federal-aid funding participation on any proposed project. Federal-aid funds are to be withheld until such a time as an engineering staff, satisfactory to the Department has been properly established and functioning, the deficiencies in regulations have been corrected or the improvements to be constructed under this Agreement are brought to a satisfactory condition of maintenance.
Project Agreements Provided that where the company commences work on a project where a site agreement exists to which the company is contractually obligated or where a site agreement exists between the union and the client or their agent that provides for higher rates of pay and conditions, the conditions contained in any such site agreement will take precedence over this Agreement for the duration of the project.
Project 3.01. The Recipient declares its commitment to the objectives of the Project. To this end, the Recipient shall carry out the Project in accordance with the provisions of Article IV of the General Conditions.
Project Management Plan 3.2.1 Developer is responsible for all quality assurance and quality control activities necessary to manage the Work, including the Utility Adjustment Work. Developer shall undertake all aspects of quality assurance and quality control for the Project and Work in accordance with the approved Project Management Plan, Good Industry Practice and applicable Law. 3.2.2 Developer shall develop the Project Management Plan and its component parts, plans and other documentation in accordance with the requirements set forth in Section 1.5.2.5
Improvement Plan A detailed, written plan collaboratively developed between the teacher and evaluator, utilized when a teacher receives an Evaluation Rating of ineffective. The approved form for the Improvement Plan is attached to this agreement as Appendix .
MANAGEMENT AGREEMENT AND FRANCHISE AGREEMENT (a) At or prior to the Closing, Seller shall terminate the Existing Management Agreement and the Existing Franchise Agreement, and Seller shall be solely responsible for all claims and liabilities arising thereunder on, prior to or following the Closing Date, except termination or similar fees, which shall be paid by Buyer. Seller shall be responsible for paying all costs related to the termination of the Existing Management Agreement and Buyer shall be responsible for paying all reasonable and actual costs of the Franchisor related to the assignment or termination, as applicable, of the Existing Franchise Agreement. (b) At Closing, Buyer shall enter into the New Management Agreement in the form attached as Exhibit E and the New Franchise Agreement, effective as of the Closing Date, containing terms and conditions acceptable to Buyer (including, without limitation, such terms and conditions as may be required to accommodate Buyer’s and/or Buyer’s Affiliates’ REIT structure). (c) Seller shall use best efforts to promptly provide all information required by the Franchisor in connection with the New Franchise Agreement. Prior to the expiration of the Review Period, Buyer and Franchisor shall agree on the form and substance of the New Franchise Agreement. Except as otherwise provided in this Contract, the New Franchise Agreement shall contain such terms and conditions as are acceptable to Buyer in its sole and absolute discretion.
Project Coordination The Engineer shall coordinate all subconsultant activity to include quality and consistency of deliverables and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.