All Work Under the Direction of Inspector. Pursuant to Title 24 requirements, the Contractor shall not carry on Work except with the knowledge of the Inspector. (See Title 24 generally)
All Work Under the Direction of Inspector Sample Clauses
Related to All Work Under the Direction of Inspector
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Verification of Coverage Prior to beginning any work under this Agreement, Consultant shall furnish City with certificates of insurance and with original endorsements effecting coverage required herein. The certificates and endorsements for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf. The City reserves the right to require complete, certified copies of all required insurance policies at any time.
Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.
Response/Compliance with Audit or Inspection Findings A. Grantee must act to ensure its and its Subcontractors’ compliance with all corrections necessary to address any finding of noncompliance with any law, regulation, audit requirement, or generally accepted accounting principle, or any other deficiency identified in any audit, review, inspection or investigation of the Grant Agreement and the services and Deliverables provided. Any such correction will be at Grantee’s or its Subcontractor's sole expense. Whether Xxxxxxx's action corrects the noncompliance shall be solely the decision of the System Agency. B. As part of the services, Grantee must provide to HHS upon request a copy of those portions of Grantee's and its Subcontractors' internal audit reports relating to the services and Deliverables provided to the State under the Grant Agreement. C. Grantee shall include the requirement to provide to System Agency (and any of its duly authorized federal, state, or local authorities) internal audit reports related to this Grant Agreement in any Subcontract it awards. Upon request by System Agency, Grantee shall enforce this requirement against its Subcontractor. Further, Grantee shall include in any Subcontract it awards a requirement that all Subcontractor Subcontracts must also include these provisions.
Inspection; Compliance with Law Lessor, Lessor's agents, employees, contractors and designated representatives, and the holders of any mortgages, deeds of trust or ground leases on the Premises ("Lenders") shall have the right to enter the Premises at any time in the case of an emergency, and otherwise at reasonable times, for the purpose of inspecting the condition of the Premises and for verifying compliance by Lessee with this Lease and all Applicable Requirements (as defined in Paragraph 6.3), and Lessor shall be entitled to employ experts and/or consultants in connection therewith to advise Lessor with respect to Lessee's activities, including but not limited to Lessee's installation, operation, use, monitoring, maintenance, or removal of any Hazardous Substance on or from the Premises. The costs and expenses of any such inspections shall be paid by the party requesting same, unless a Default or Breach of this Lease by Lessee or a violation of Applicable Requirements or a contamination, caused or materially contributed to by Lessee, is found to exist or to be imminent, or unless the inspection is requested or ordered by a governmental authority as the result of any such existing or imminent violation or contamination. In such case, Lessee shall upon request reimburse Lessor or Lessor's Lender, as the case may be, for the costs and expenses of such inspections.
Access to and Maintenance of Auction Records The Auction Agent shall afford to the Company, its agents, independent public accountants and counsel, access at reasonable times during normal business hours to review and make extracts or copies (at the Company's sole cost and expense) of all books, records, documents and other information concerning the conduct and results of Auctions, provided that any such agent, accountant or counsel shall furnish the Auction Agent with a letter from the Company requesting that the Auction Agent afford such person access. The Auction Agent shall maintain records relating to any Auction for a period of two years after such Auction (unless requested by the Company to maintain such records for such longer period not in excess of four years, then for such longer period), and such records, in reasonable detail, shall accurately and fairly reflect the actions taken by the Auction Agent hereunder. The Company agrees to keep confidential any information regarding the customers of any Broker-Dealer received from the Auction Agent in connection with this Agreement or any Auction, and shall not disclose such information or permit the disclosure of such information without the prior written consent of the applicable Broker- Dealer to anyone except such agent, accountant or counsel engaged to audit or review the results of Auctions as permitted by this Section 2.7, provided that the Company reserves the right to disclose any such information if it is advised by its counsel that its failure to do so would (i) be unlawful or (ii) expose it to liability, unless the Broker-Dealer shall have offered indemnification satisfactory to the Company. Any such agent, accountant or counsel, before having access to such information, shall agree to keep such information confidential and not to disclose such information or permit disclosure of such information without the prior written consent of the applicable Broker-Dealer, provided that such agent, accountant or counsel may reserve the right to disclose any such information if it is advised by its counsel that its failure to do so would (i) be unlawful or (ii) expose it to liability, unless the Broker-Dealer shall have offered indemnification satisfactory to such agent, accountant or counsel.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Acceptance of Appointment; Standard of Performance Adviser accepts the appointment as discretionary portfolio manager and agrees to use its best professional judgment to make timely investment decisions for the Fund in accordance with the provisions of this Agreement.
SOURCE OF INSTRUCTIONS The Contractor shall neither seek nor accept instructions from any authority external to UNDP in connection with the performance of its services under this Contract. The Contractor shall refrain from any action that may adversely affect UNDP or the United Nations and shall fulfill its commitments with the fullest regard to the interests of UNDP.
Acceptance and Performance of Duties under Serviced Appointments With respect to each Serviced Appointment of Xxxxx Bank, the Bank Assets Purchaser hereby accepts its engagement as Servicer and agrees to perform and discharge all Serviced Duties consistent with the terms hereof. With respect to each Serviced Appointment of Xxxxx Trust Company, the Delaware Trust Assets Purchaser (or the Bank Assets Purchaser, if required by Section 3.3) hereby accepts its engagement as Servicer and agrees to perform and discharge all Serviced Duties consistent with the terms hereof. On the terms and subject to the conditions set forth herein, including Article 8, effective as of the Closing, the Purchasers agree to discharge and perform when due the Assumed Servicing Liabilities.
