Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is April 25, 2016. The completion date for this contract is October 15, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
Default Not Exceeding 10% of Firm Units If any Underwriter or Underwriters shall default in its or their obligations to purchase the Firm Units and if the number of the Firm Units with respect to which such default relates does not exceed in the aggregate 10% of the number of Firm Units that all Underwriters have agreed to purchase hereunder, then such Firm Units to which the default relates shall be purchased by the non-defaulting Underwriters in proportion to their respective commitments hereunder.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Xxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Termination Damages If the Term of this Lease is terminated for default, unless and until Landlord elects lump sum liquidated damages described in the next paragraph, Tenant covenants, as an additional, cumulative obligation after any such termination, to pay punctually to Landlord all the sums and perform all of its obligations in the same manner as if the Term had not been terminated. In calculating such amounts Tenant will be credited with the net proceeds of any rent then actually received by Landlord from a reletting of the Premises after deducting all Rent that has not then been paid by Tenant, provided that Tenant shall never be entitled to receive any portion of the re-letting proceeds, even if the same exceed the Rent originally due hereunder.
Net Out of Settlement Amounts The Non-Defaulting Party shall calculate a Termination Payment by aggregating all Settlement Amounts due under this Agreement or any other agreement(s) between the Company and the BGS-RSCP Supplier for the provision of BGS Supply into a single amount: by netting out (a) all Settlement Amounts that are due or will become due to the Defaulting Party, plus at the option of the Non-Defaulting Party, any cash or other form of security then available to the Non- Defaulting Party and actually received, liquidated and retained by the Non-Defaulting Party, plus any or all other amounts due to the Defaulting Party under this Agreement or any other agreement(s) between the Company and the BGS-RSCP Supplier for the provision of BGS Supply against (b) all Settlement Amounts that are due or will become due to the Non-Defaulting Party, plus any or all other amounts due to the Non-Defaulting Party under this Agreement or any other agreement(s) between the Company and the BGS- RSCP Supplier for the provision of BGS Supply, so that all such amounts shall be netted out to a single liquidated amount; provided, however, that if the BGS-RSCP Supplier is the Defaulting Party and the Termination Payment is due to the BGS-RSCP Supplier, the Company shall be entitled to retain a commercially reasonable portion of the Termination Payment, which may be equal to the entire amount of the Termination Payment, as security for additional amounts that may be determined to be due and owing by the BGS-RSCP Supplier as Damages and further provided that any previously attached security interest of the Company in such retained amounts shall continue. The Termination Payment shall be due to or due from the Non-Defaulting Party as appropriate. If the Termination Payment has been retained by the Company as security for additional amounts that may be determined to be due and owing by the BGS-RSCP Supplier, and if, upon making a final determination of Damages, the Termination Payment, or any portion thereof, is to be made to the BGS-RSCP Supplier, the Company will pay simple interest on the Termination Payment amount being made to the BGS-RSCP Supplier. Simple interest will be calculated at the lower of the Interest Index or six (6) percent per annum.
Mandatory Redemption at Subscriber’s Election In the event the Company is prohibited from issuing Conversion Shares, or fails to timely deliver Shares on a Delivery Date, or upon the occurrence of any other Event of Default (as defined in this Note or in the Subscription Agreement) or for any reason other than pursuant to the limitations set forth in Section 2.3 hereof, then at the Subscriber's election, the Company must pay to the Subscriber ten (10) business days after request by the Subscriber, at the Subscriber's election, a sum of money in immediately available terms equal to the greater of (i) the product of the outstanding principal amount of the Note designated by the Subscriber multiplied by 120%, or (ii) the product of the number of Conversion Shares otherwise deliverable upon conversion of an amount of Note principal and/or interest designated by the Subscriber (with the date of giving of such designation being a “Deemed Conversion Date”) at the then Conversion Price that would be in effect on the Deemed Conversion Date multiplied by the average of the closing bid prices for the Common Stock for the five consecutive trading days preceding either: (1) the date the Company becomes obligated to pay the Mandatory Redemption Payment, or (2) the date on which the Mandatory Redemption Payment is made in full, whichever is greater, together with accrued but unpaid interest thereon and any liquidated damages then payable (“Mandatory Redemption Payment”). The Mandatory Redemption Payment must be received by the Subscriber on the same date as the Company Shares otherwise deliverable or within ten (10) business days after request, whichever is sooner (“Mandatory Redemption Payment Date”). Upon receipt of the Mandatory Redemption Payment, the corresponding Note principal and interest will be deemed paid and no longer outstanding. Liquidated damages calculated pursuant to Section 2.5(c) hereof, that have been paid or accrued for the twenty (20) day period prior to the actual receipt of the Mandatory Redemption Payment by the Subscriber shall be credited against the Mandatory Redemption Payment.
Alternative Tenders 12.1 Unless otherwise specified in the TDS, alternative Tenders shall not be considered.
