Approval Process for Project Selection
Approval Process for Project Selection Sample Clauses
Related to Approval Process for Project Selection
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Bona Fide Request/New Business Request Process for Further Unbundling 6.1 BellSouth shall, upon request of <<customer_name>>, provide to <<customer_name>> access to its network elements at any technically feasible point for the provision of <<customer_name>>'s telecommunications service where such access is necessary and failure to provide access would impair the ability of <<customer_name>> to provide services that it seeks to offer. Any request by <<customer_name>> for access to a network element, interconnection option, or for the provisioning of any service or product that is not already available shall be treated as a Bona Fide Request/New Business Request (BFR/NBR), and shall be submitted to BellSouth pursuant to the BFR/NBR process.
Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $696,243.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
Requirement for Project Planning No physical work will begin on the construction site until the receipt of a Proceed Order issued by the Owner. The Contract assumes that a Proceed Order will be issued in not more than sixty days from the Effective Date of the Contract. Failure of the Contractor to provide the necessary documentation for the issuance of a Proceed Order shall not entitle the Contractor to any extension of time. If a Proceed Order is not issued within sixty days from the award of the Contract and non-issuance is due to nonperformance by the Contractor, the Contractor may be in default.
000 APPLICATION FOR PROJECT AGREEMENT 1.100 Any Company desiring to enter into a Project Agreement for Maintenance by Contract, must appear before the General Presidents' Committee (hereinafter the "Committee") for purposes of review and orientation and present to the Committee written evidence of the Owner's intent to engage that Company in the performance of maintenance service for a minimum period of one full year, subject to the usual termination clauses in such contracts.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
LIS Forecasting 7.2.2.8.1 Both CLEC and Qwest shall work in good faith to define a mutually agreed upon forecast of LIS trunking.
Schedule for Completing Agreement Closeout Activities Provide All Draft and Final Written Products on a CD-ROM or USB memory stick, organized by the tasks in the Agreement. Products: • Final Meeting Agreement Summary (if applicable) • Schedule for Completing Agreement Closeout Activities • All Draft and Final Written Products
Review and Selection Process The Project Narratives of SAMHSA applications are peer-reviewed according to the evaluation criteria listed above. Decisions to fund a grant are based on the strengths and weaknesses of the application as identified by peer reviewers. The results of the peer review are advisory in nature. The program office and approving official make the final determination for funding based on the following: • Individual awards over $250,000 are approved by the Center for Mental Health Services National Advisory Council; • Availability of funds; • Equitable distribution of awards in terms of geography (including urban, rural, and remote settings) and balance among populations of focus and program size; • Submission of any required documentation that must be submitted prior to making an award; and • SAMHSA is required to review and consider any information about your organization that is in the Federal Award Performance and Integrity Information System (FAPIIS). In accordance with 45 CFR 75.212, SAMHSA reserves the right not to make an award to an entity if that entity does not meet the minimum qualification standards as described in section 75.205(a)(2). If SAMHSA chooses not to award a fundable application in accordance with 45 CFR 75.205(a)(2), SAMHSA must report that determination to the designated integrity and performance system accessible through the System for Award Management (XXX) [currently, FAPIIS]. You may review and comment on any information about your organization that a federal awarding agency previously entered. XXXXXX will consider your comments, in addition to other information in FAPIIS in making a judgment about your organization’s integrity, business ethics, and record of performance under federal awards when completing the review of risk posed as described in 45 CFR 75.205 HHS Awarding Agency Review of Risk by Applicants.
Access Toll Connecting Trunk Group Architecture 9.2.1 If CBB chooses to subtend a Verizon access Tandem, CBB’s NPA/NXX must be assigned by CBB to subtend the same Verizon access Tandem that a Verizon NPA/NXX serving the same Rate Center Area subtends as identified in the LERG.
