Approved Builders and Architects Sample Clauses

Approved Builders and Architects. The design and construction of the single family residence to be constructed on the Property must be undertaken only by architects and builders who are duly licensed by the State and have been previously approved by Seller to design and build residences in the Community (hereinafter referred to as "Approved Architects" and "Approved Builders"). You may request Us to approve specific architects and builders, but We are not obligated to do so. You will not act as Your own builder unless You have been licensed by the State as a general contractor and have been approved in writing by ▇▇▇▇▇▇. You acknowledge and agree that neither We nor any affiliate has recommended or endorsed any architect, builder, contractor or subcontractor. You acknowledge that any architect or builder that is chosen by You will be chosen in Your sole discretion and that You will perform examinations of said architect's and builder's qualifications and financial ability as You deem appropriate. You further acknowledge that We are not responsible for Your choice of architects and builders, and that said architects and builders are not Our agents, partners or affiliates. You hereby release and forever waive any claims, actions, suits, damages (both direct and consequential) and judgments You may ever have against Us (and any entity affiliated with Us) based on or arising from an architect's or a builder's acts or omissions to act, or for any defects in the design or construction of improvements on the Property.
View SourceView Similar (2)

Related to Approved Builders and Architects

  • Architect Engineer shall provide assistance to Owner through the commissioning consultant/agent for the purpose of advising and counseling Owner’s personnel in the usage, operation and maintenance of the building mechanical, electrical, and plumbing systems.

  • SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services. § 3.1.1 The Architect shall manage the Architect’s services, research applicable design criteria, attend Project meetings, communicate with members of the Project team, and report progress to the Owner. § 3.1.2 The Architect shall coordinate its services with those services provided by the Owner and the Owner’s consultants. The Architect shall be entitled to rely on, and shall not be responsible for, the accuracy, completeness, and timeliness of, services and information furnished by the Owner and the Owner’s consultants. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error, omission, or inconsistency in such services or information. § 3.1.3 As soon as practicable after the date of this Agreement, the Architect shall submit for the Owner’s approval a schedule for the performance of the Architect’s services. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information. The schedule shall include allowances for periods of time required for the Owner’s review, for the performance of the Owner’s consultants, and for approval of submissions by authorities having jurisdiction over the Project. Once approved by the Owner, time limits established by the schedule shall not, except for reasonable cause, be exceeded by the Architect or Owner. With the Owner’s approval, the Architect shall adjust the schedule, if necessary, as the Project proceeds until the commencement of construction. § 3.1.4 The Architect shall not be responsible for an Owner’s directive or substitution, or for the Owner’s acceptance of non-conforming Work, made or given without the Architect’s written approval. § 3.1.5 The Architect shall contact governmental authorities required to approve the Construction Documents and entities providing utility services to the Project. The Architect shall respond to applicable design requirements imposed by those authorities and entities. § 3.1.6 The Architect shall assist the Owner in connection with the Owner’s responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project.

  • Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code ▇▇▇., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code ▇▇▇., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code ▇▇▇., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • CONTRACTOR’S INSURANCE REQUIREMENTS The insurance requirements of this Contract are set forth in Appendix J and, if applicable, Appendix J.

  • Contractor’s Insurance 27.1 The Contractor shall procure and maintain at all times it performs any portion of the Services the following insurance with minimum limits equal to the amount indicated below.