Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Transition of Registry upon Termination of Agreement Upon expiration of the Term pursuant to Section 4.1 or Section 4.2 or any termination of this Agreement pursuant to Section 4.3 or Section 4.4, Registry Operator shall provide ICANN or any successor registry operator that may be designated by ICANN for the TLD in accordance with this Section 4.5 with all data (including the data escrowed in accordance with Section 2.3) regarding operations of the registry for the TLD necessary to maintain operations and registry functions that may be reasonably requested by ICANN or such successor registry operator. After consultation with Registry Operator, ICANN shall determine whether or not to transition operation of the TLD to a successor registry operator in its sole discretion and in conformance with the Registry Transition Process; provided, however, that (i) ICANN will take into consideration any intellectual property rights of Registry Operator (as communicated to ICANN by Registry Operator) in determining whether to transition operation of the TLD to a successor registry operator and (ii) if Registry Operator demonstrates to ICANN’s reasonable satisfaction that (A) all domain name registrations in the TLD are registered to, and maintained by, Registry Operator or its Affiliates for their exclusive use, (B) Registry Operator does not sell, distribute or transfer control or use of any registrations in the TLD to any third party that is not an Affiliate of Registry Operator, and (C) transitioning operation of the TLD is not necessary to protect the public interest, then ICANN may not transition operation of the TLD to a successor registry operator upon the expiration or termination of this Agreement without the consent of Registry Operator (which shall not be unreasonably withheld, conditioned or delayed). For the avoidance of doubt, the foregoing sentence shall not prohibit ICANN from delegating the TLD pursuant to a future application process for the delegation of top-‐level domains, subject to any processes and objection procedures instituted by ICANN in connection with such application process intended to protect the rights of third parties. Registry Operator agrees that ICANN may make any changes it deems necessary to the IANA database for DNS and WHOIS records with respect to the TLD in the event of a transition of the TLD pursuant to this Section 4.5. In addition, ICANN or its designee shall retain and may enforce its rights under the Continued Operations Instrument for the maintenance and operation of the TLD, regardless of the reason for termination or expiration of this Agreement.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
No Construction as Employment Agreement Nothing contained in this Agreement shall be construed as giving Indemnitee any right to be retained in the employ of the Company or any of its subsidiaries.
Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.
Enforcement of Due-on-Sale Clauses; Assumption and Modification Agreements; Certain Assignments (a) When any Mortgaged Property is conveyed by the Mortgagor, the Master Servicer or Subservicer, to the extent it has knowledge of such conveyance, shall enforce any due-on-sale clause contained in any Mortgage Note or Mortgage, to the extent permitted under applicable law and governmental regulations, but only to the extent that such enforcement will not adversely affect or jeopardize coverage under any Required Insurance Policy. Notwithstanding the foregoing:
(i) the Master Servicer shall not be deemed to be in default under this Section 3.13(a) by reason of any transfer or assumption which the Master Servicer is restricted by law from preventing; and
(ii) if the Master Servicer determines that it is reasonably likely that any Mortgagor will bring, or if any Mortgagor does bring, legal action to declare invalid or otherwise avoid enforcement of a due-on-sale clause contained in any Mortgage Note or Mortgage, the Master Servicer shall not be required to enforce the due-on-sale clause or to contest such action.
(b) Subject to the Master Servicer's duty to enforce any due-on-sale clause to the extent set forth in Section 3.13(a), in any case in which a Mortgaged Property is to be conveyed to a Person by a Mortgagor, and such Person is to enter into an assumption or modification agreement or supplement to the Mortgage Note or Mortgage which requires the signature of the Trustee, or if an instrument of release signed by the Trustee is required releasing the Mortgagor from liability on the Mortgage Loan, the Master Servicer is authorized, subject to the requirements of the sentence next following, to execute and deliver, on behalf of the Trustee, the assumption agreement with the Person to whom the Mortgaged Property is to be conveyed and such modification agreement or supplement to the Mortgage Note or Mortgage or other instruments as are reasonable or necessary to carry out the terms of the Mortgage Note or Mortgage or otherwise to comply with any applicable laws regarding assumptions or the transfer of the Mortgaged Property to such Person; provided, however, none of such terms and requirements shall either (i) both (A) constitute a "significant modification" effecting an exchange or reissuance of such Mortgage Loan under the REMIC Provisions and (B) cause any portion of any REMIC formed under the Series Supplement to fail to qualify as a REMIC under the Code or (subject to Section 10.01(f)), result in the imposition of any tax on "prohibited transactions" or (ii) constitute "contributions" after the start-up date under the REMIC Provisions. The Master Servicer shall execute and deliver such documents only if it reasonably determines that (i) its execution and delivery thereof will not conflict with or violate any terms of this Agreement or cause the unpaid balance and interest on the Mortgage Loan to be uncollectible in whole or in part, (ii) any required consents of insurers under any Required Insurance Policies have been obtained and (iii) subsequent to the closing of the transaction involving the assumption or transfer (A) the Mortgage Loan will continue to be secured by a first mortgage lien pursuant to the terms of the Mortgage, (B) such transaction will not adversely affect the coverage under any Required Insurance Policies, (C) the Mortgage Loan will fully amortize over the remaining term thereof, (D) no material term of the Mortgage Loan (including the interest rate on the Mortgage Loan) will be altered nor will the term of the Mortgage Loan be changed and (E) if the seller/transferor of the Mortgaged Property is to be released from liability on the Mortgage Loan, such release will not (based on the Master Servicer's or Subservicer's good faith determination) adversely affect the collectability of the Mortgage Loan. Upon receipt of appropriate instructions from the Master Servicer in accordance with the foregoing, the Trustee shall execute any necessary instruments for such assumption or substitution of liability as directed in writing by the Master Servicer. Upon the closing of the transactions contemplated by such documents, the Master Servicer shall cause the originals or true and correct copies of the assumption agreement, the release (if any), or the modification or supplement to the Mortgage Note or Mortgage to be delivered to the Trustee or the Custodian and deposited with the Mortgage File for such Mortgage Loan. Any fee collected by the Master Servicer or such related Subservicer for entering into an assumption or substitution of liability agreement will be retained by the Master Servicer or such Subservicer as additional servicing compensation.
(c) The Master Servicer or the related Subservicer, as the case may be, shall be entitled to approve a request from a Mortgagor for a partial release of the related Mortgaged Property, the granting of an easement thereon in favor of another Person, any alteration or demolition of the related Mortgaged Property (or, with respect to a Cooperative Loan, the related Cooperative Apartment) without any right of reimbursement or other similar matters if it has determined, exercising its good faith business judgment in the same manner as it would if it were the owner of the related Mortgage Loan, that the security for, and the timely and full collectability of, such Mortgage Loan would not be adversely affected thereby and that any portion of any REMIC formed under the Series Supplement would not fail to continue to qualify as a REMIC under the Code as a result thereof and (subject to Section 10.01(f)) that no tax on "prohibited transactions" or "contributions" after the startup day would be imposed on any such REMIC as a result thereof. Any fee collected by the Master Servicer or the related Subservicer for processing such a request will be retained by the Master Servicer or such Subservicer as additional servicing compensation.
(d) Subject to any other applicable terms and conditions of this Agreement, the Trustee and Master Servicer shall be entitled to approve an assignment in lieu of satisfaction with respect to any Mortgage Loan, provided the obligee with respect to such Mortgage Loan following such proposed assignment provides the Trustee and Master Servicer with a "Lender Certification for Assignment of Mortgage Loan" in the form attached hereto as Exhibit M, in form and substance satisfactory to the Trustee and Master Servicer, providing the following: (i) that the substance of the assignment is, and is intended to be, a refinancing of such Mortgage; (ii) that the Mortgage Loan following the proposed assignment will have a rate of interest at least 0.25 percent below or above the rate of interest on such Mortgage Loan prior to such proposed assignment; and (iii) that such assignment is at the request of the borrower under the related Mortgage Loan. Upon approval of an assignment in lieu of satisfaction with respect to any Mortgage Loan, the Master Servicer shall receive cash in an amount equal to the unpaid principal balance of and accrued interest on such Mortgage Loan and the Master Servicer shall treat such amount as a Principal Prepayment in Full with respect to such Mortgage Loan for all purposes hereof.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State.
4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor.
4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor.
4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto.
4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project.
4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Change of Control; Assignment and Subcontracting Except as set forth in this Section 7.5, neither party may assign any of its rights and obligations under this Agreement without the prior written approval of the other party, which approval will not be unreasonably withheld. For purposes of this Section 7.5, a direct or indirect change of control of Registry Operator or any subcontracting arrangement that relates to any Critical Function (as identified in Section 6 of Specification 10) for the TLD (a “Material Subcontracting Arrangement”) shall be deemed an assignment.
(a) Registry Operator must provide no less than thirty (30) calendar days advance notice to ICANN of any assignment or Material Subcontracting Arrangement, and any agreement to assign or subcontract any portion of the operations of the TLD (whether or not a Material Subcontracting Arrangement) must mandate compliance with all covenants, obligations and agreements by Registry Operator hereunder, and Registry Operator shall continue to be bound by such covenants, obligations and agreements. Registry Operator must also provide no less than thirty (30) calendar days advance notice to ICANN prior to the consummation of any transaction anticipated to result in a direct or indirect change of control of Registry Operator.
(b) Within thirty (30) calendar days of either such notification pursuant to Section 7.5(a), ICANN may request additional information from Registry Operator establishing (i) compliance with this Agreement and (ii) that the party acquiring such control or entering into such assignment or Material Subcontracting Arrangement (in any case, the “Contracting Party”) and the ultimate parent entity of the Contracting Party meets the ICANN-‐adopted specification or policy on registry operator criteria then in effect (including with respect to financial resources and operational and technical capabilities), in which case Registry Operator must supply the requested information within fifteen (15) calendar days.
(c) Registry Operator agrees that ICANN’s consent to any assignment, change of control or Material Subcontracting Arrangement will also be subject to background checks on any proposed Contracting Party (and such Contracting Party’s Affiliates).
(d) If ICANN fails to expressly provide or withhold its consent to any assignment, direct or indirect change of control of Registry Operator or any Material Subcontracting Arrangement within thirty (30) calendar days of ICANN’s receipt of notice of such transaction (or, if ICANN has requested additional information from Registry Operator as set forth above, thirty (30) calendar days of the receipt of all requested written information regarding such transaction) from Registry Operator, ICANN shall be deemed to have consented to such transaction.
(e) In connection with any such assignment, change of control or Material Subcontracting Arrangement, Registry Operator shall comply with the Registry Transition Process.
(f) Notwithstanding the foregoing, (i) any consummated change of control shall not be voidable by ICANN; provided, however, that, if ICANN reasonably determines to withhold its consent to such transaction, ICANN may terminate this Agreement pursuant to Section 4.3(g), (ii) ICANN may assign this Agreement without the consent of Registry Operator upon approval of the ICANN Board of Directors in conjunction with a reorganization, reconstitution or re-‐incorporation of ICANN upon such assignee’s express assumption of the terms and conditions of this Agreement, (iii) Registry Operator may assign this Agreement without the consent of ICANN directly to a wholly-‐owned subsidiary of Registry Operator, or, if Registry Operator is a wholly-‐owned subsidiary, to its direct parent or to another wholly-‐owned subsidiary of its direct parent, upon such subsidiary’s or parent’s, as applicable, express assumption of the terms and conditions of this Agreement, and (iv) ICANN shall be deemed to have consented to any assignment, Material Subcontracting Arrangement or change of control transaction in which the Contracting Party is an existing operator of a generic top-‐level domain pursuant to a registry agreement between such Contracting Party and ICANN (provided that such Contracting Party is then in compliance with the terms and conditions of such registry agreement in all material respects), unless ICANN provides to Registry Operator a written objection to such transaction within ten (10) calendar days of ICANN’s receipt of notice of such transaction pursuant to this Section 7.5. Notwithstanding Section 7.5(a), in the event an assignment is made pursuant to clauses (ii) or (iii) of this Section 7.5(f), the assigning party will provide the other party with prompt notice following any such assignment.
Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.
