Association’s Remedies if Owner Fails to Maintain Lot Sample Clauses

Association’s Remedies if Owner Fails to Maintain Lot. In the event that Developer or the Association determines that: (i) any Owner has failed or refused to discharge properly his obligations with regard to the maintenance, cleaning, repair, or replacement of items for which is his responsibility hereunder, or (ii) that the need for maintenance, cleaning, repair, or replacement which is the responsibility of the Association hereunder is caused through the willful or negligent act of an Owner, his family, tenants, guests, or invitees, and is not covered or paid for by insurance in whole or in part, then in either event, Developer or the Association, except in the event of an emergency situation, may give such Owner written notice of Developer’s or the Association’s intent to provide such necessary maintenance, cleaning, repair, or replacement, at the sole cost and expense of such Owner as the case may be, shall have ten (10) days within which to complete such maintenance, cleaning, repair or replacement in a good and workmanlike manner, or in the event that such maintenance, cleaning, repair or replacement is not capable of completion within said ten
Sample 1
AutoNDA by SimpleDocs

Related to Association’s Remedies if Owner Fails to Maintain Lot

  • Tenant’s Remedies/Limitation of Liability Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder. All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owner’s ownership.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • REMEDIES OF RESIDENTIAL FUNDING If an Event of Seller Default or an Event of Servicer Default shall occur, Residential Funding may, at its option, exercise one or more of those remedies set forth in the Guides.

  • No Waiver of Provisional Remedies, Self-Help and Foreclosure The arbitration requirement does not limit the right of any party to (i) foreclose against real or personal property collateral; (ii) exercise self-help remedies relating to collateral or proceeds of collateral such as setoff or repossession; or (iii) obtain provisional or ancillary remedies such as replevin, injunctive relief, attachment or the appointment of a receiver, before during or after the pendency of any arbitration proceeding. This exclusion does not constitute a waiver of the right or obligation of any party to submit any dispute to arbitration or reference hereunder, including those arising from the exercise of the actions detailed in sections (i), (ii) and (iii) of this paragraph.

  • Remedies for Contractor Breach Pertaining to contract-related issues, it is the responsibility of both CMHA and the contractor to communicate with each other in as clear and complete a manner as possible. If at any time during the term of this contract CMHA or the contractor is not satisfied with any issue, it is the responsibility of that party to deliver to the other party communication, in writing, fully detailing the issue and corrective action (please note that CMHA has the right to issue unilateral addendums to this contract, but the contractor does not have the same right). The other party shall, within 10 days, respond in writing to the other party (however, CMHA shall retain the right to, if conditions warrant, require the contractor to respond in a shorter period of time). Further, CMHA shall, at a minimum, employ the following steps in dealing with the contractor as to any performance issues: 20.16.1.1. If the contractor is in material breach of the contract, CMHA may promptly invoke the termination clause detailed within Section No. 3, form HUD-5370-C, General Conditions for Non-Construction Contracts, Section I—(With or without Maintenance Work), which is attached hereto, and terminate the contract for cause. Such termination must be delivered to the contractor in writing and shall fully detail all pertinent issues pertaining to the cause of and justification for the termination. 20.16.1.2. Prior to termination, CMHA may choose to warn 20.16.1.3. After termination, if the contractor does not agree with CMHA’s justification for the termination, the contractor shall have 10 days to dispute, in writing, such action; if he/she does not do so within the 10-day period, he/she shall have no recourse but to accept and agree with CMHA’s position on the issue. The written protest must detail all pertinent information pertaining to the dispute, including justification detailing CMHA’s alleged incorrect action(s). 20.16.1.4. The response to any protest received shall be conducted in accordance with Section No. 4.0 of this document. 20.16.1.5. It is CMHA’s policy to resolve all contractual issues informally and without litigation. Disputes will not be referred to HUD unless all administrative remedies have been exhausted. When appropriate, a mediator may be used to help resolve differences. 20.16.1.6. For contracts of $100,000 or less, the bidder/contractor may request to meet with the Procurement Officer. 20.16.1.7. All claims by a contractor relating to performance of a contract shall be submitted in writing to the Procurement Officer or designee for a written decision. The contractor may request a conference on the claim. The Procurement Officer’s decision shall inform the contractor of its appeal rights to the next higher level of authority in CMHA. Contractor claims shall be governed by the Changes clause in the form HUD-5370-C.

  • COVENANTS OF REGISTRY OPERATOR Registry Operator covenants and agrees with ICANN as follows:

  • Landlord’s Remedies Upon occurrence of any default by Tenant under this Lease and (i) if the event of default described in Section 8.1(a) is not cured within five (5) days after written notice from Landlord of such default; provided, however, Landlord shall only be obligated to provide such written notice to Tenant once in each Lease Year and thereafter, Tenant shall be in default if it shall fail to pay any Rent or other monetary charge due from Tenant hereunder as and when due and payable; (ii) if the events described in Sections 8.1(b), (d), (f) and (g) are not cured within thirty (30) days after written notice from Landlord of such default; provided, however, that if the nature of Tenant’s default under Section 8.1(b) is such that more than thirty (30) days are reasonably required for its cure, then Tenant shall be afforded such additional period of time not to exceed an additional thirty (30) days within which to cure such default as shall be reasonable under the circumstance, if and so long as Tenant commenced to cure within the first thirty (30) day period and diligently prosecuted the cure thereof to completion within such additional thirty (30) day period; or (iii) with no additional notice and cure period for events of defaults described in Sections 8.1(c), (e), and (h), the Landlord shall have the option to do and perform any one or more of the following in addition to, and not in limitation of, any other remedy or right permitted it by law or in equity or by this Lease: (a) Continue this Lease in full force and effect, and this Lease shall continue in full force and effect as long as Landlord does not terminate this Lease, and Landlord shall have the right to collect Rent, Additional Rent and other charges when due. (b) Terminate this Lease, and Landlord may in accordance within applicable laws forthwith repossess the Premises and be entitled to recover as damages a sum of money equal to the total of (i) the cost of recovering the Premises, (ii) the cost of removing and storing Tenant’s or any other occupant’s property, (iii) the unpaid Rent and any other sums accrued hereunder at the date of termination, (iv) a sum equal to the amount, if any, by which the present value of the total Rent and other benefits which would have accrued to Landlord under this Lease for the remainder of the Term, if the terms of this Lease had been fully complied with by Tenant, discounted at eight percent (8%) per annum exceeds the total fair market value of the Premises for the balance of the Term, also discounted back to present value at eight percent (8%) per annum (it being the agreement of the parties hereto that Landlord shall receive the benefit of its bargain), (v) the cost of reletting the Premises including, without limitation, the cost of restoring the Premises to the condition necessary to rent the Premises at the prevailing market rental rate, normal wear and tear excepted, (vi) any increase in insurance premiums caused by the vacancy of the Premises, (vii) amount of any unamortized improvements to the Premises paid for by Landlord, (viii) the amount of any unamortized brokerage commissions or other costs paid, (ix) the cost of decorations, repairs, changes, alterations and additions to the Premises, (x) the cost of any brokerage fees or commissions payable by Landlord in connection with any reletting or attempted reletting, (xi) any other sum of money or damages owed by Tenant to Landlord. In the event Landlord shall elect to terminate this Lease, Landlord shall at once have all the rights of reentry upon the Premises available under North Carolina law, without becoming liable for damages, or guilty of trespass. (c) Terminate Tenant’s right of occupancy of the Premises and reenter and repossess the Premises by entry, forcible entry or detainer suit or otherwise, without demand or notice of any kind to Tenant and without terminating this Lease, without acceptance of surrender of possession of the Premises, and without becoming liable for damages or guilty of trespass, in which event Landlord shall use reasonable efforts to relet the Premises or any part thereof for the account of Tenant, but only to the extent provided in Section 8.3 hereinbelow (provided that in no event shall Landlord be under any obligation to relet the Premises before Landlord relets or leases any other portion of the Project or any other property under the ownership or control of Landlord) for a period equal to or lesser or greater than the remainder of the Term of the Lease on whatever terms and conditions as Landlord, at Landlord’s sole discretion, deems advisable. Tenant shall be liable for and shall pay to Landlord all Rent payable by Tenant under this Lease (plus interest at the past due rate provided in Section 3.1(c) of this Lease if in arrears) plus an amount equal to (i) the cost of recovering possession of the Premises, (ii) the reasonable cost of removing and storing any of Tenant’s or any other occupant’s property left on the Premises or the Project after reentry, (iii) the cost of repairs, changes, alterations and additions to the Premises and the Project, (iv) the cost of any attempted reletting or reletting and the collection of the rent accruing from such reletting,

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Construction or Rehabilitation of Mortgaged Property No Mortgage Loan was made in connection with the construction or rehabilitation of a Mortgaged Property or facilitating the trade-in or exchange of a Mortgaged Property;

  • GRANTOR'S RIGHT TO POSSESSION AND TO COLLECT ACCOUNTS Until default and except as otherwise provided below with respect to accounts, Grantor may have possession of the tangible personal property and beneficial use of all the Collateral and may use it in any lawful manner not inconsistent with this Agreement or the Related Documents, provided that Grantor's right to possession and beneficial use shall not apply to any Collateral where possession of the Collateral by Lender is required by law to perfect Lender's security interest in such Collateral. Until otherwise notified by Lender, Grantor may collect any of the Collateral consisting of accounts. At any time and even though no Event of Default exists, Lender may exercise its rights to collect the accounts and to notify account debtors to make payments directly to Lender for application to the Indebtedness. If Lender at any time has possession of any Collateral, whether before or after an Event of Default, Lender shall be deemed to have exercised reasonable care in the custody and preservation of the Collateral if Lender takes such action for that purpose as Grantor shall request or as Lender, in Lender's sole discretion, shall deem appropriate under the circumstances, but failure to honor any request by Grantor shall not of itself be deemed to be a failure to exercise reasonable care. Lender shall not be required to take any steps necessary to preserve any rights in the Collateral against prior parties, nor to protect, preserve or maintain any security interest given to secure the Indebtedness.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!