Delivery Obligations (a) The Seller shall Deliver to the Purchaser, not later than the 5th Business Day following the Determination Date for each Lot (the “Delivery Deadline”), Finished Cobalt in an amount equal to the Payable Cobalt in respect of the Parcel from which such Lot was produced (the “Delivery Amount”); provided that where such Lot is comprised of Off-Spec Material, the Seller shall provide the Purchaser with prompt (and in any event prior to the initial Delivery Deadline) written notice (an “Off-Spec Material Notice”) of the existence of such Off-Spec Material and the Delivery Deadline for such Delivery Amount shall be as follows: (i) to the extent that the Seller is able to Deliver some or all of the Delivery Amount using Finished Cobalt held on the date of the Off- Spec Material Notice by any Vale Affiliate in inventory in a Warehouse located in [REDACTED: Commercially Sensitive], the Delivery Deadline in respect of such portion of the Delivery Amount shall be not later than the 5th Business Day following the Determination Date for the relevant Lot; (ii) thereafter, to the extent that the Seller is able to Deliver some or all of any remaining portion of the Delivery Amount using Finished Cobalt held on the date of the Off-Spec Material Notice by any Vale Affiliate in inventory in a Warehouse located in [REDACTED: Commercially Sensitive], the Delivery Deadline in respect of such portion of the Delivery Amount shall be not later than the 10th Business Day following the Determination Date for the relevant Lot; and (iii) thereafter, in respect of the balance of the Delivery Amount (the “Delivery Balance”), if any, the Delivery Deadline shall be not later than the 15th Business Day following the Determination Date for the relevant Lot, subject to Section 2.2(c). Notwithstanding the foregoing, to the extent that the Seller grants or has granted a permitted Stream Equivalent Transaction required to be settled in physical cobalt to any Person other than the Purchaser, the Seller shall use its available Finished Cobalt inventory (and any other Finished Cobalt that it is able to acquire) to satisfy its delivery obligations to the Purchaser and to such other Person(s) proportionately to their respective cobalt stream percentages or similar interests in cobalt. (b) The Seller shall ensure that the Vale Affiliates maintain, at all times, an inventory of at least [REDACTED: Commercially Sensitive] tonnes of Finished Cobalt ([REDACTED: Commercially Sensitive]) in one or more Warehouses located in [REDACTED: Commercially Sensitive], provided that where the Vale Affiliates have drawn on such inventory of Finished Cobalt to meet the Seller’s Delivery obligations to the Purchaser in accordance with Section 2.2(a)(i) and any other permitted Stream Equivalent Transactions granted by the Seller that are required to be settled in physical cobalt, the Vale Affiliates shall have up to 45 days after the date of the relevant Delivery to restore such inventory of Finished Cobalt to at least [REDACTED: Commercially Sensitive] tonnes. Notwithstanding the foregoing, the Vale Affiliates shall not be required to maintain any inventory of Finished Cobalt for so long as any increase to the Stream Percentage in accordance with Section 5.3 is in effect. (c) [REDACTED: Commercially Sensitive]. (d) No later than 15 Business Days following the end of each calendar quarter, the Seller shall conduct an updated Metal Balance Determination in respect of all Lots in respect of which Deliveries of Finished Cobalt were made (or required to be made) by the Seller to the Purchaser in accordance with Section 2.2(a) within such calendar quarter and shall determine the quantity of Minerals processed at Long Harbour over the period of processing attributed to such Lots (the “Quarterly Parcel”). The Seller shall calculate the Payable Cobalt in respect of such Quarterly Parcel as if it were a Parcel and to the extent that the aggregate Payable Cobalt in respect of the Quarterly Parcel is greater or less than the Finished Cobalt actually Delivered (or required to be Delivered) by the Seller to the Purchaser during such calendar quarter in respect of such Lots, the Seller shall (subject to Section 2.2(e)) reduce or increase, as the case may be, the amount of the next following Delivery of Finished Cobalt (the “Subject Delivery”) to account for such difference (a “Delivery Adjustment”); provided that: (i) where the amount of such Subject Delivery is required to be increased by an amount of Finished Cobalt (the “Top-Up Amount”) pursuant to a Delivery Adjustment, the Top-Up Amount shall be calculated in accordance with the following formula: Top-Up Amount = A x (B/C) where: “A” is the number of pounds of Finished Cobalt by which (a) the number of pounds of Payable Cobalt calculated in respect of the Quarterly Parcel exceeds (b) the Finished Cobalt actually Delivered (or required to be Delivered) to the Purchaser during the relevant calendar quarter;
Primary Obligations This Guaranty is a primary and original ------------------- obligation of Guarantor, is not merely the creation of a surety relationship, and is an absolute, unconditional, and continuing guaranty of payment and performance which shall remain in full force and effect without respect to future changes in conditions until full and final payment in cash (or other consideration acceptable to Foothill in its sole discretion and agreed to by Foothill) of the Guarantied Obligations and the termination of all commitments of Foothill to extend Credit to Debtor or Guarantor. Guarantor agrees that it is directly, jointly and severally with any other guarantor of the Guarantied Obligations, liable to Guarantied Party, that the obligations of Guarantor hereunder are independent of the obligations of Debtor or any other guarantor, and that a separate action may be brought against Guarantor, whether such action is brought against Debtor or any other guarantor or whether Debtor or any other guarantor is joined in such action. Guarantor agrees that its liability hereunder shall be immediate and shall not be contingent upon the exercise or enforcement by Guarantied Party of whatever remedies it may have against Debtor or any other guarantor, or the enforcement of any lien or realization upon any security Guarantied Party may at any time possess. Guarantor agrees that any release which may be given by Guarantied Party to Debtor or any other guarantor shall not release Guarantor. Guarantor consents and agrees that Guarantied Party shall be under no obligation to marshal any property or assets of Debtor or any other guarantor in favor of Guarantor, or against or in payment of any or all of the Guarantied Obligations.
Recipient Obligations 2.1 The Recipient agrees to support the Project in accordance with this Agreement. 2.2 In supporting the Project, the Recipient must: (a) exercise reasonable diligence, care and skill; (b) administer the Funding in accordance with the Agreement to support the Fellow to complete the Project; (c) not replace the Fellow named in the Application with another person; (d) complete the Project Deliverables by the relevant Deliverable due dates. This includes the provision of the required Reports, Financial Acquittal Statements and valid tax invoices; (e) ensure that the Fellow completes the Project Milestones annually; (f) ensure it makes the Recipient Contribution to the Project as per the Application and summarised in Item 11 of Schedule 1; (g) ensure the Partners provide the Partner Contributions to the Project as per the Application and summarised in Item 12 of Schedule 1; (h) ensure that the Project expenditure is managed in accordance with the project expenditure table in the Application; (i) notify the Department within 20 Business Days of any matter that may affect the Fellow or Recipient’s eligibility for funding under the Guidelines, including but not limited to: (i) the Fellow ceasing employment with the Recipient; (ii) the Fellow moving residence to outside of Queensland; (iii) the Fellow travelling outside of Queensland for more than six weeks; (iv) the Fellow taking extended leave or being unable to undertake the Project for an extended period; (v) the Fellow changing the proportion of their time committed to the Project; (vi) the Recipient Contributions or Partner Contributions changing; (vii) the Project Partner organisations changing; and (viii) the Project expenditure changing. (j) ensure that (where relevant): (i) the Project complies with National Health and Medical Research Council Guidelines; (ii) the Project complies with the Code of Ethical Practice for Biotechnology in Queensland; (iii) the Project is cleared by all relevant ethical committees prescribed by the Recipient organisation’s research rules; and (iv) evidence of compliance with this clause is provided, if requested by the Department; (k) not assign, transfer or subcontract its obligations, without prior written consent of the Department; (l) notify the Department of any breach of these terms or any matter that may affect the performance of the Agreement; and (m) comply with all relevant laws.
Client Obligations 3.1 The Client warrants and represents that: 3.1.1 it shall co-operate with Centaur as required for the proper performance of the Services; 3.1.2 it shall provide, for Centaur, its agents, subcontractors, consultants and employees, in a timely manner and at no charge, access to the Client's premises during normal office hours (being Monday – Friday 8am – 6pm), office accommodation, data and other facilities as is reasonably required by Centaur or any of them for the proper performance of the Services; 3.1.3 all information it has provided to Centaur in relation to the Services as at the date of the Order Form is accurate, complete and is not misleading and it shall provide, in a timely manner, such further information and Client Material as Centaur may require for the proper performance of the Services, and ensure that such information and Client Material is accurate, complete and not misleading; 3.1.4 it shall be responsible (at its own cost) for preparing and maintaining the relevant premises for the supply of the Services; 3.1.5 it shall inform Centaur of all health and safety rules and regulations and any other reasonable security requirements that apply at any of the Client's premises; 3.1.6 it shall only use the Services for internal business purposes and, without prejudice to the foregoing, shall not use the Services, the Deliverables or any Centaur Materials to develop a product or service that competes with any of the products or services provided by Centaur; 3.1.7 the Client Materials shall not infringe any third party rights, including any third party Intellectual Property Rights; and 3.1.8 it shall obtain and maintain all necessary licences and consents and comply with all relevant legislation in relation to the Services, before the date on which the Services are to start. 3.2 If Centaur's performance of its obligations under this Agreement is prevented or delayed by any act or omission of the Client, its agents, subcontractors, consultants or employees, Centaur shall not be liable for any costs, charges or losses sustained or incurred by the Client that arise directly or indirectly from such prevention or delay.
Warranty Obligations (a) Project Co represents, warrants and covenants that: (i) the Works shall conform to the requirements of this Project Agreement, Good Industry Practice, Applicable Law and all professional engineering principles generally accepted as standards of the industry in the Province of Ontario; (ii) the Works shall be free of defects, including design defects, errors and omissions; and (iii) materials and equipment shall be of good quality and in compliance with this Project Agreement. (b) During the Warranty Period and subject to Section 11.15(c), Project Co shall promptly, at its sole cost and expense, correct and Make Good all Construction Defects arising in respect of the Works. For greater certainty, Project Co is required to correct and Make Good Construction Defects related to any Product during the applicable Warranty Period despite Project Co having obtained on Contracting Authority’s behalf industry- standard or other equipment warranties in accordance with Section 11.15(f). For all work to correct Construction Defects, the applicable Warranty Period shall be extended for a further two years from the date of the last work completed in respect of such corrective Works. For clarity, any extension of a Warranty Period for the purposes of a correction shall only apply to the relevant Construction Defect and not the Works as a whole. (c) In addition to the obligation to correct and Make Good Construction Defects during the Warranty Period, Project Co shall at its expense correct and Make Good any Construction Defects that could not reasonably have been ascertained by a competent person in accordance with Good Industry Practice during a visual inspection of the Works (“Construction Latent Defect”), provided Contracting Authority gives Project Co written Notice of the Construction Latent Defect within the time frame applicable to such Construction Latent Defect pursuant to the Limitations Act, 2002 (Ontario). (d) The warranties described in this Section 11.15 shall cover labour and material, including, the costs of removal and replacement of covering materials. The warranties shall not limit extended warranties on any Product or item of equipment called for elsewhere in the Output Specifications or otherwise provided by any manufacturer of such Product or equipment. (e) If Project Co fails to correct and Make Good any Construction Defects or Construction Latent Defects in accordance with Sections 11.15(b) and 11.15(c) and in the time period specified in Section 11.16(a) or Section 11.16(b), as applicable, without prejudice to any other right or remedy Contracting Authority may have, Contracting Authority may correct such Construction Defects or Construction Latent Defects at Project Co’s sole cost and expense. (f) Project Co shall obtain warranties from the manufacturers of each of the Products for the duration(s) and in accordance with the applicable requirements specified in the Output Specifications in the name of and to the benefit of both Project Co and Contracting Authority. Where, in respect of a Product warranty, the Output Specifications do not specify a specific duration and/or other requirements, Project Co shall obtain industry-standard warranties from the applicable manufacturers in the name of and to the benefit of Project Co and Contracting Authority which shall extend no less than two years from the Substantial Completion Date. Each Product warranty shall be issued by the applicable manufacturer and delivered to Project Co no later than 30 days prior to the Substantial Completion Date. Project Co shall ensure that each Product warranty, including any Product warranty extended under this Section 11.15(f), is fully assigned to Contracting Authority, at no cost or expense to Contracting Authority, at the end of the Warranty Period, as such Warranty Period may be extended in accordance with Section 11.15(b).
Guaranty of the Obligations Subject to the provisions of Section 7.2, Guarantors jointly and severally hereby irrevocably and unconditionally guaranty to Administrative Agent for the ratable benefit of the Beneficiaries the due and punctual payment in full of all Obligations when the same shall become due, whether at stated maturity, by required prepayment, declaration, acceleration, demand or otherwise (including amounts that would become due but for the operation of the automatic stay under Section 362(a) of the Bankruptcy Code, 11 U.S.C. § 362(a)) (collectively, the “Guaranteed Obligations”).
Primary Obligation This Agreement is a primary and original obligation of each Borrower and shall remain in effect notwithstanding future changes in conditions, including any change of law or any invalidity or irregularity in the creation or acquisition of any Obligations or in the execution or delivery of any agreement between Bank and any Borrower. Each Borrower shall be liable for existing and future Obligations as fully as if all of all Credit Extensions were advanced to such Borrower. Bank may rely on any certificate or representation made by any Borrower as made on behalf of, and binding on, all Borrowers, including without limitation Disbursement Request Forms, Borrowing Base Certificates and Compliance Certificates.
Statutory Obligations Nothing in this Agreement shall be construed to modify, eliminate or detract from the statutory responsibilities and obligations of the Employer except that the exercise of its rights in the furtherance of such statutory obligations shall not be in conflict with the provisions of this Agreement.
Litigation and Contingent Obligations There is no litigation, arbitration, governmental investigation, proceeding or inquiry pending or, to the knowledge of any of their officers, threatened against or affecting the Borrower or any of its Subsidiaries which could reasonably be expected to have a Material Adverse Effect or which seeks to prevent, enjoin or delay the making of any Loans. Other than any liability incident to any litigation, arbitration or proceeding which could not reasonably be expected to have a Material Adverse Effect, the Borrower has no material contingent obligations not provided for or disclosed in the financial statements referred to in Section 5.4.
Delivery of Instruments and Chattel Paper If any amount payable under or in connection with any of the Collateral shall be or become evidenced by any Instrument or Chattel Paper, such Instrument or Chattel Paper shall be immediately delivered to the Administrative Agent, duly indorsed in a manner satisfactory to the Administrative Agent, to be held as Collateral pursuant to this Agreement.
