City Obligations 26.1 City shall provide full information in a timely manner regarding requirements for and limitations on projects and work tasks. With regard to subcontractor liens, City shall furnish to Engineer, within fifteen (15) days after receipt of a written request, information necessary and relevant for Engineer to evaluate, give notice of, or enforce lien. 26.2 City shall establish and update, if necessary, overall project budgets, including engineering and construction costs. 26.3 City shall furnish the services of consultants, including geotechnical engineers, when such services are requested by Engineer, reasonably required by the scope of a project, and agreed to by City. 26.4 City shall furnish all testing as required by law or the contract documents. 26.5 City shall furnish all legal accounting, auditing and insurance services as necessary for projects to meet the City’s needs and interests, after Engineer has performed requisite project management and oversight duties. 26.6 City shall provide prompt written notice to Engineer if City becomes aware of any fault or defect in a project, including any errors, omissions or inconsistencies in Engineer’s design or performance under the contract. 26.7 City shall pay Engineer in accordance with paragraph 3 and Exhibit E of this Contract, upon receipt of Engineer’s submission of monthly invoices, and satisfactory progress and performance made in accordance with the scope of work. Payments shall reflect work completed, or progress made on a project to date, on a pro rata basis. 26.8 City shall report the total amount of all payments to Engineer, including any expenses, in accordance with federal Internal Revenue Service and State of Oregon Department of Revenue regulations. 26.9 City shall guarantee access to, and make all provisions for Engineer to enter upon public and private property necessary for performance of the Scope of Work over which City exercises control. 26.10 Extra work or work on contingency tasks is not permitted unless authorized by the City in writing. Failure of Engineer to secure written authorization for extra work shall constitute a waiver of all rights to an adjustment in the Agreement price or Agreement time.
Settlement of Third Party Claims Notwithstanding any other provision of this Agreement, the Indemnifying Party shall not enter into settlement of any Third Party Claim without the prior written consent of the Indemnified Party, except as provided in this Section 8.05(b). If a firm offer is made to settle a Third Party Claim without leading to liability or the creation of a financial or other obligation on the part of the Indemnified Party and provides, in customary form, for the unconditional release of each Indemnified Party from all liabilities and obligations in connection with such Third Party Claim and the Indemnifying Party desires to accept and agree to such offer, the Indemnifying Party shall give written notice to that effect to the Indemnified Party. If the Indemnified Party fails to consent to such firm offer within ten days after its receipt of such notice, the Indemnified Party may continue to contest or defend such Third Party Claim and in such event, the maximum liability of the Indemnifying Party as to such Third Party Claim shall not exceed the amount of such settlement offer. If the Indemnified Party fails to consent to such firm offer and also fails to assume defense of such Third Party Claim, the Indemnifying Party may settle the Third Party Claim upon the terms set forth in such firm offer to settle such Third Party Claim. If the Indemnified Party has assumed the defense pursuant to Section 8.05(a), it shall not agree to any settlement without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed).
Defense and Settlement of Third Party Claims The Indemnifying Party shall have the right (without prejudice to the right of any Indemnified Party to participate at its or his own expense through counsel of its or his own choosing) to defend against any Third Party Claim at its or his expense and through counsel of its or his own choosing and to control such defense if the Indemnifying Party gives written notice of its or his intention to do so within 15 business days of its or his receipt of notice of the Third Party Claim. The Indemnified Party shall cooperate fully in all reasonable respects in the defense of such Third Party Claim and shall make available to the Indemnifying Party or its or his counsel all pertinent information under their control relating thereto. The Indemnified Party shall have the right to elect to settle any Third Party Claim; provided, however, the Indemnifying Party shall not have any indemnification obligation with respect to any monetary payment to any third party required by such settlement unless the Indemnifying Party shall have consented thereto. The Indemnifying Party shall have the right to elect to settle any Third Party Claim subject to the consent of the Indemnified Party; provided, however, that if the Indemnified Party fails to give such consent within 15 business days of being requested to do so, the Indemnified Party shall, at its expense, assume the defense of such Third Party Claim and regardless of the outcome of such matter, the Indemnifying Party's liability hereunder shall be limited to the amount of any such proposed settlement. The foregoing provisions notwithstanding, in no event (a) may either Indemnifying Party adjust, compromise or settle any Third Party Claim unless such adjustment, compromise or settlement unconditionally releases the Indemnified Party from all liability, (b) may the Company Indemnifying Party adjust, compromise or settle any Third Party Claim if such adjustment, compromise or settlement affects the absolute and sole right of Provant or the Surviving Corporation to own or use any of the Company's assets or (c) may the Company Indemnifying Party defend any Third Party Claim which, if adversely determined, would materially impair the financial condition, business or prospects of Provant or the Surviving Corporation.
Non-Third Party Claims Upon discovery of any claim for which Buyer has an indemnification obligation under the terms of Section 12.1 which does not involve a claim by a third party against the Indemnitee, the Indemnitee shall give prompt notice to Buyer of such claim and, in any case, shall give Buyer such notice within 30 days of such discovery. A failure by Indemnitee to timely give the foregoing notice to Buyer shall not excuse Buyer from any indemnification liability except to the extent that Buyer is materially and adversely prejudiced by such failure.
Contracts (Rights of Third Parties) Xxx 0000 No term of this Agreement is enforceable under the Contracts (Rights of Third Parties) Xxx 0000 by a person who is not a party to this Agreement.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
CORPORATE INTEGRITY OBLIGATIONS Indivior shall establish and maintain a Compliance Program that includes the following elements:
Conduct of Third Party Claims If the matter or circumstance that may give rise to a Claim other than a Tax Claim is a result of or in connection with a claim by a third party (a “Third Party Claim”) then: 11.4.1 the Purchaser shall, to the extent reasonably practicable and subject to Applicable Law, consult with the Seller in relation to the conduct of the Third Party Claim and shall take reasonable account of the views of the Seller before taking any action in relation to the Third Party Claim; 11.4.2 no admissions in relation to the Third Party Claim shall be made by or on behalf of the Purchaser or any member of the Purchaser’s Group and the Third Party Claim shall not be compromised, disposed of or settled without the written consent of the Seller, such consent not to be unreasonably withheld or delayed; 11.4.3 subject to the Seller indemnifying the Purchaser or member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred thereby, the Purchaser shall, or the Purchaser shall procure that the members of the Purchaser’s Group shall, take such action as the Seller may reasonably request to avoid, dispute, deny, defend, resist, appeal, compromise or contest the Third Party Claim; 11.4.4 the Seller shall, subject in each case to being paid all reasonable out-of-pocket costs and expenses: (i) make available to the Purchaser and the relevant Group Company such persons and all such information as the Purchaser may reasonably request for assessing, contesting, disputing, defending, compromising or appealing the Third Party Claim; and (ii) shall give the Purchaser and the relevant Group Company reasonable access to its premises and to its books and records for such purpose during normal business hours on any Business Day following reasonable notice being given to the Seller; 11.4.5 subject to 11.4.3, the Seller shall be entitled at its own expense and in its absolute discretion, by notice in writing to the Purchaser, to assume conduct of any Third Party Claim and to have the conduct of any related proceedings, negotiations or appeals; 11.4.6 if the Seller sends a notice to the Purchaser pursuant to Clause 11.4.5 and until such time as any final compromise, agreement, expert determination or non-appealable decision of a court or tribunal of competent jurisdiction is made in respect of that Third Party Claim or that Third Party Claim is otherwise finally disposed of: (i) the Purchaser shall, and the Purchaser shall procure that any member of the Purchaser’s Group shall: (a) give, subject to being paid all reasonable costs and expenses, all such information and assistance including access to premises and personnel, and the right to examine and copy or photograph any assets, accounts, documents and records (excluding, in each case, information or documents which are protected by legal professional privilege but including, in each case, information or documents that are subject to common interest privilege), as the Seller may reasonably request, including instructing such professional or legal advisers as the Seller may nominate to act on behalf of the Purchaser or other member of the Purchaser’s Group concerned but in accordance with the Seller’s instructions, provided that the appointment of such adviser or advisers shall have been approved in writing by the Purchaser (such approval not to be unreasonably withheld, conditioned or delayed); and (b) not make any admission of liability, agreement or compromise in relation to that Third Party Claim without the prior written approval of the Seller (such approval not to be unreasonably withheld, conditioned or delayed); (ii) the Seller shall: (a) consult with the Purchaser and take reasonable account of the views of the Purchaser before taking any action in relation to the Third Party Claim; (b) without prejudice to its ability to defend the Third Party Claim, conduct the Third Party Claim with a view to minimising any material harm to the goodwill and reputation of the Wider Group or the Purchaser’s Group; (c) keep the Purchaser informed of all relevant matters relating to the Third Party Claim and shall promptly forward or procure to be forwarded to the Purchaser copies of all correspondence and other written communications with such other information, including non-written records (except information or documents which are protected by legal professional privilege), relating to the Third Party Claim; (d) not make any admission of liability, settlement or compromise of the Third Party Claim without the written consent of the Purchaser, such consent not to be unreasonably withheld, conditioned or delayed. If the Purchaser or member of the Purchaser’s Group fails to consent to a settlement or compromise, the maximum liability of the Seller shall (without prejudice to Clause 10) not exceed the full amount of the proposed settlement or compromise and the Purchaser or member of the Purchaser’s Group shall be liable for any damages awarded in excess of the proposed settlement or compromise and costs incurred from (and including) the date the Seller notified the Purchaser of the settlement or compromise; and (e) indemnify, save as set out in Clause 11.4.6(ii)(d), the Purchaser or other member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred as a result of the Seller assuming conduct of the Third Party Claim. 11.4.7 The covenants in this Clause 11.4 may be enforced: (i) by any Group Company against the Seller; and (ii) by any member of the Seller’s Group against the Purchaser or a Group Company, under the Contracts (Rights of Third Parties) Xxx 0000. 11.4.8 The provisions of this Clause 11.4 may be varied or terminated by agreement between the Seller and the Purchaser (and the Purchaser may also release or compromise in whole or in part any liability in respect of rights or claims contemplated by this Clause 11.4) without the consent of any Group Company.
Consents of Third Parties No vote, approval or consent of any holder of capital stock of the Company or any other third parties is required or necessary to be obtained by the Company in connection with the authorization, execution, deliver and performance of this Agreement and the other Transaction Documents or in connection with the authorization, issue and sale of the Securities and, upon issuance, the Warrant Shares, except as previously obtained, each of which is in full force and effect.
Indemnification in Third Party Proceedings Subject to Section 10 below, the Company shall indemnify Indemnitee to the fullest extent permitted by the Code, as the same may be amended from time to time (but, only to the extent that such amendment permits Indemnitee to broader indemnification rights than the Code permitted prior to adoption of such amendment), if Indemnitee is a party to or threatened to be made a party to or otherwise involved in any proceeding, for any and all expenses, actually and reasonably incurred by Indemnitee in connection with the investigation, defense, settlement or appeal of such proceeding.
