Remedies on Default Whenever an Event of Default shall have happened and be subsisting, either or both of the following remedial steps may be taken:
H DEFAULT, DISRUPTION AND TERMINATION H1 Termination on insolvency and change of control H1.1 The Client may terminate the Contract with immediate effect by notice in writing where the Contractor is a company and in respect of the Contractor:
No Breach or Default In no event will either party be liable or responsible to the other party, or be deemed to have defaulted under or breached this Agreement, for any failure or delay in fulfilling or performing any term of this Agreement (except for any payment obligation) when and to the extent such failure or delay is caused by any circumstances beyond such party’s reasonable control (a “Force Majeure Event”), including acts of God, flood, fire, earthquake or explosion, pandemic, war, terrorism, invasion, riot or other civil unrest, embargoes or blockades in effect on or after the date of this Agreement, national or regional emergency, strikes, labor stoppages or slowdowns or other industrial disturbances, passage of Law or any action taken by a governmental or public authority, including imposing an embargo, export or import restriction, quota or other restriction or prohibition or any complete or partial government shutdown, or national or regional shortage of adequate power or telecommunications or transportation. Either party may terminate this Agreement if a Force Majeure Event continues substantially uninterrupted for a period of 30 days or more.
Termination on Default The Authority may terminate this Framework Agreement by serving written notice on the Supplier with effect from the date specified in such notice where the Supplier commits a Material Default and if:
Termination Upon Default Either Party may terminate this Agreement in whole or in part in the event of a default by the other Party; provided however, that the non-defaulting Party notifies the defaulting party in writing of the alleged default and that the defaulting Party does not cure the alleged default within sixty (60) calendar days of receipt of written notice thereof. Default is defined to include:
Absence of Violations, Defaults and Conflicts Neither the Company nor any of its subsidiaries is (A) in violation of its charter, by-laws or similar organizational document, (B) in default in the performance or observance of any obligation, agreement, covenant or condition contained in any contract, indenture, mortgage, deed of trust, loan or credit agreement, note, lease or other agreement or instrument to which the Company or any of its subsidiaries is a party or by which it or any of them may be bound or to which any of the properties or assets of the Company or any subsidiary is subject (collectively, “Agreements and Instruments”), except for such defaults that would not reasonably be expected to, singly or in the aggregate, result in a Material Adverse Effect, or (C) in violation of any law, statute, rule, regulation, judgment, order, writ or decree of any arbitrator, court, governmental body, regulatory body, administrative agency or other authority, body or agency having jurisdiction over the Company or any of its subsidiaries or any of their respective properties, assets or operations (each, a “Governmental Entity”), except for such violations that would not reasonably be expected to, singly or in the aggregate, result in a Material Adverse Effect. The execution, delivery and performance of this Agreement and the consummation of the transactions contemplated herein and in the Registration Statement, the General Disclosure Package and the Prospectus (including the issuance and sale of the Securities and the use of the proceeds from the sale of the Securities as described therein under the caption “Use of Proceeds”) and compliance by the Company with its obligations hereunder have been duly authorized by all necessary corporate action and do not and will not, whether with or without the giving of notice or passage of time or both, conflict with or constitute a breach of, or default or Repayment Event (as defined below) under, or result in the creation or imposition of any lien, charge or encumbrance upon any properties or assets of the Company or any subsidiary pursuant to, the Agreements and Instruments (except for such conflicts, breaches, defaults or Repayment Events or liens, charges or encumbrances that would not reasonably be expected to, singly or in the aggregate, result in a Material Adverse Effect), nor will such action result in any violation of (x) the provisions of the charter, by-laws or similar organizational document of the Company or any of its subsidiaries or (y) any law, statute, rule, regulation, judgment, order, writ or decree of any Governmental Entity, except with respect to clause (y), such violations as would not reasonably be expected to, singly or in the aggregate, result in a Material Adverse Effect. As used herein, a “Repayment Event” means any event or condition which gives the holder of any note, debenture or other evidence of indebtedness (or any person acting on such holder’s behalf) the right to require the repurchase, redemption or repayment of all or a portion of such indebtedness by the Company or any of its subsidiaries.
Succession upon Default Each of the following events shall constitute an Event of Default by Xxxxxx Xxx hereunder:
Termination; Default If Contractor is in default of any of its obligations under this Contract and has not commenced cure within ten days after receipt of a written notice of default from County and cured such default within the time specified in the notice, the County shall immediately be entitled to either commence resolution in accordance with this paragraph or to terminate this Contract by giving written notice to take effect immediately. Default shall include failure to carry out any of the requirements of this Contract, including, but not limited to not providing enough properly skilled workers or proper materials, persistently disregarding laws and or ordinances, not proceeding with the work as agreed to herein, or otherwise substantially violating any provision of this Contract. Upon termination of the Contract with Contractor, the County may begin negotiations with a third-party Contractor to provide goods and/or services as specified in this Contract. The right of either party to terminate this Contract hereunder shall not be affected in any way by its waiver of or failure to take action with respect to any previous default.
Suspension or Termination Upon Default Either Party may suspend or terminate this Agreement, in whole or in part, in the event of a Default by the other Party so long as the non-Defaulting Party notifies the Defaulting Party in writing of the Default and the Defaulting Party does not cure the Default within thirty (30) Days of receipt of the written notice, provided however, that any requirements for written notice and opportunity to cure with respect to the failure to make timely payment of undisputed charges shall be governed separately under Section 51. Following CenturyLink’s notice to CLEC of its Default, CenturyLink shall not be required to process new Service Orders until the Default is timely cured.
Enforcement and Rights and Remedies on Default 5.1 The Developer agrees that any officer appointed by the Municipality to enforce this Agreement shall be granted access onto the Lands during all reasonable hours without obtaining consent of the Developer. The Developer further agrees that, upon receiving written notification from an officer of the Municipality to inspect the interior of any building located on the Lands, the Developer agrees to allow for such an inspection during any reasonable hour within two (2) business days of receiving such a request.
