Joint Funded Project with the Ohio Department of Transportation In the event that the Recipient does not have contracting authority over project engineering, construction, or right-of- way, the Recipient and the OPWC hereby assign certain responsibilities to the Ohio Department of Transportation, an authorized representative of the State of Ohio. Notwithstanding Sections IV, VI.A., VI.B., VI.C., and VII of the Project Agreement, Recipient hereby acknowledges that upon notification by the Ohio Department of Transportation, all payments for eligible project costs will be disbursed by the Grantor directly to the Ohio Department of Transportation. A Memorandum of Funds issued by the Ohio Department of Transportation shall be used to certify the estimated project costs. Upon receipt of a Memorandum of Funds from the Ohio Department of Transportation, the OPWC shall transfer funds directly to the Ohio Department of Transportation via an Intra-State Transfer Voucher. The amount or amounts transferred shall be determined by applying the Participation Percentages defined in Appendix D to those eligible project costs within the Memorandum of Funds. In the event that the Project Scope is for right-of-way only, notwithstanding Appendix D, the OPWC shall pay for 100% of the right-of-way costs not to exceed the total financial assistance provided in Appendix C. APPENDIX D LOCAL SUBDIVISION CONTRIBUTION, PROJECT FINANCING AND EXPENSES SCHEME AND DISBURSEMENT RATIO
PROCEDURE TO SELECT, APPOINT AND MANAGE SUB-CONTRACTORS 4.1 The Supplier shall comply with requirements under Clause 25 (Transfer and Sub-Contracting).
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
Data Protection Impact Assessment and Prior Consultation Processor shall provide reasonable assistance to the Company with any data protection impact assessments, and prior consultations with Supervising Authorities or other competent data privacy authorities, which Company reasonably considers to be required by article 35 or 36 of the GDPR or equivalent provisions of any other Data Protection Law, in each case solely in relation to Processing of Company Personal Data by, and taking into account the nature of the Processing and information available to, the Contracted Processors.
Installation and Use Rights You may install and use any number of copies of the software on your devices.
Appointment of Key Sub-Contractors The Supplier shall ensure that all Sub-Contracts contain a provision: requiring the Supplier to pay any undisputed sums which are due from it to the Sub-Contractor within a specified period not exceeding thirty (30) days from the receipt of a valid invoice; requiring that any invoices submitted by a Sub-Contractor shall be considered and verified by the Supplier in a timely fashion and that undue delay in doing so shall not be sufficient justification for failing to regard an invoice as valid and undisputed; requiring the Sub-Contractor to include in any Sub-Contract which it in turn awards suitable provisions to impose, as between the parties to that Sub-Contract, requirements to the same effect as those required by sub-clauses 5.17.1 and 5.17.2 directly above; and conferring a right to the Customer to publish the Supplier’s compliance with its obligation to pay undisputed invoices within the specified payment period. The Supplier shall pay any undisputed sums which are due from it to a Sub-Contractor within thirty (30) days from the receipt of a valid invoice. Any invoices submitted by a Sub-Contractor to the Supplier shall be considered and verified by the Supplier in a timely fashion. Undue delay in doing so shall not be sufficient justification for the Supplier failing to regard an invoice as valid and undisputed. Notwithstanding any provision of Clauses 9.2 (Confidentiality) and 13 (Publicity, Media and Official Enquiries) if the Supplier notifies the Customer that the Supplier has failed to pay an undisputed Sub-Contractor’s invoice within thirty (30) days of receipt, or the Customer otherwise discovers the same, the Customer shall be entitled to publish the details of the late or non-payment (including on Government websites and in the press).
Please see the current Washtenaw Community College catalog for up-to-date program requirements Secondary / Post-Secondary Program Alignment Welding HIGH SCHOOL COURSE SEQUENCE 9th Grade 10th Grade 11th Grade 12th Grade English 9 Algebra I World History/Geography Biology World Language Phys Ed/Health English 10 Geometry U.S. History/Geography Physics or Chemistry World Language Visual/Performing/Applied Arts English 11 Algebra II Civics/Economics Welding English 12 Math Credit Science Credit Welding WASHTENAW COMMUNITY COLLEGE Welding Associate in Applied Science Semester 1 Math Elective(s)* 3 WAF 105 Introduction to Welding Processes 2 WAF 111 Oxy-fuel Welding 4 WAF 112 Shielded Metal Arc Welding 4 Semester Total 13 Semester 2 Speech Elective(s) 3 WAF 106 Blueprint Reading for Welders 3 WAF 123 Advanced Oxy-fuel Welding 4 WAF 124 Advanced Shielded Metal Arc Welding 4 Semester Total 14 Semester 3 Arts/Human. Elective(s) 3 Computer Lit. Elective(s) 3 WAF 215 Advanced Gas Tungsten Arc Welding 4 WAF 288 Gas Metal Arc Welding 4 Semester Total 14 Semester 4 WAF 200 Layout Theory Welding 3 WAF 210 Welding Metallurgy 3 Soc. Sci. Elective(s) 3 WAF 226 Specialized Welding Procedures 4 Semester Total 13 Semester 5 Nat. Sci. Elective(s) 4 WAF 227 Basic Fabrication 3 WAF 229 Shape Cutting Operations 3 Writing Elective(s) 3 Semester Total 13 Program Totals 67
The Settling Entity’s Release of Xxxxxxx The Settling Entity, on behalf of itself, its past and current agents, representatives, attorneys, successors, and assignees, hereby waives any and all claims against Xxxxxxx and his attorneys and other representatives, for any and all actions taken or statements made (or those that could have been taken or made) by Xxxxxxx and his attorneys and other representatives, whether in the course of investigating claims or otherwise seeking to enforce Proposition 65 in connection with the notice or Products.
County of Orange Child Support Enforcement In order to comply with the child support enforcement requirements of the County of Orange, within ten (10) days of notification of selection of award of CONTRACT but prior to official award of CONTRACT, the selected CONTRACTOR agrees to furnish to the CONTRACT MANAGER, the Purchasing Agent, or the agency/department deputy purchasing agent:
Texas Education Code Chapter 22 Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide service s to obtain criminal history record information regarding covered employees. Contractors must certify to the district t hat they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a sch ool district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing dutie s related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the o ffense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined abo ve. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure tha t the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain t hese precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history. (2) If Contractor receives information that a covered employee subsequently has a reported criminal history, Contra ctor will immediately remove the covered employee from contract duties and notify the District in writing within 3 busi ness days. (3) Upon request, Contractor will provide the District with the name and any other requested information of covered employees so that the District may obtain criminal history record information on the covered employees. (4) If the District objects to the assignment of a covered employee on the basis of the covered employee's criminal h istory record information, Contractor agrees to discontinue using that covered employee to provide services at the District. Noncompliance or misrepresentation regarding this certification may be grounds for contract termination. None Texas Business and Commerce Code § 272 Requirements as of 9-1-2017 SB 807 prohibits construction contracts to have provisions requiring the contract to be subject to the laws of anothe r state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract wit h such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The t erm also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLI CABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WH EN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. 7 5 Texas Government Code 2270 Verification Form Texas Government Code 2270 Verification Form Texas 2017 House Xxxx 89 has been signed into law by the governor and as of September 1, 2017 will be codified as Texas Government Code § 2270 and 808 et seq. The relevant section addressed by this form reads as follows: Texas Government Code Sec. 2270.002. PROVISION REQUIRED IN CONTRACT. A governmental entity may not ent er into a contract with a company for goods or services unless the contract contains a written verification from the c ompany that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract.engaged by ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx,XX,00000 verify by this writing that the above-named company affirms that it (1) does not boycott Israel; and (2) will not boycot t Israel during the term of this contract, or any contract with the above-named Texas governmental entity in the futur e. I further affirm that if our company’s position on this issue is reversed and this affirmation is no longer valid, that t he above-named Texas governmental entity will be notified in writing within one (1) business day and we understand that our company’s failure to affirm and comply with the requirements of Texas Government Code 2270 et seq. shall be grounds for immediate contract termination without penalty to the above-named Texas governmental entity. AND our company is not listed on and we do not do business with companies that are on the the Texas Comptroller of Pu blic Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://x xxxxxxxxxx.xxxxx.xxx/xxxxxxxxxx/xxxx/xxxxxxx-xxxxxxxxx.xxx I swear and affirm that the above is true and correct. YES
