City's Right to Proceed In the event this contract is terminated pursuant to Paragraph 8, then the City may take over the work and prosecute the same to completion, by contract or otherwise, and Contractor and its sureties shall be liable to the City for any costs over the amount of this contract thereby occasioned by the City. In any such case, the City may take possession of, and utilize in completing the work, such materials, appliances and structures as may be on the work site and are necessary for completion of the work. The foregoing provisions are in addition to, and not in limitation of, the rights of the City under any other provisions of the contract, city ordinances, and state and federal laws.
Agency’s Right to Audit A. Performing Agency shall make available at reasonable times and upon reasonable notice, and for reasonable periods, work papers, reports, books, records, supporting documents kept current by Performing Agency pertaining to the Contract for purposes of inspecting, monitoring, auditing, or evaluating by System Agency and the State of Texas.
City’s Right to Reject The City reserves the right to reject a certificate of insurance if Contractor’s insurance company is widely regarded in the insurance industry as financially unstable. This would include but is not limited to insurance companies with no less than AVIII rating in the A.M. Best insurance rating guide.
Continuing Jurisdiction of the Court The Parties agree that, after entry of Judgment, the Court will retain jurisdiction over the Parties, Action, and the Settlement solely for purposes of (i) enforcing this Agreement and/or Judgment, (ii) addressing settlement administration matters, and (iii) addressing such post-Judgment matters as are permitted by law.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.1.5. There is no legal limitation on the Owner’s right to make changes such as may be, in the Owner’s sole discretion, useful or desirable to the Project.
Notification of Compromise or Potential Compromise The compromise or potential compromise of Confidential Information must be reported to the DSHS Contact designated on the contract within one (1) business day of discovery. Contractor must also take actions to mitigate the risk of loss and comply with any notification or other requirements imposed by law or DSHS.
HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.
Representative's Authority to Contract By signing this contract, the representative of the contractor thereby represents that such person is duly authorized by the contractor to execute this contract on behalf of the contractor and that the contractor agrees to be bound by the provisions thereof.
Company's Rights The existence of this Agreement will not affect in any way the right or power of the Company or its Shareholders to accomplish any corporate act, including, without limitation, the acts referred to in Section 11.16 of the Plan.
City’s Right to Withhold Payment In the event City becomes credibly informed that any representations of Consulting Engineer/Architect provided in its monthly billing, are wholly or partially inaccurate, City may withhold payment of sums then or in the future otherwise due to Consulting Engineer/Architect until the inaccuracy and the cause thereof, is corrected to City's reasonable satisfaction. In the event City questions some element of an invoice, that fact shall be made known to Consulting Engineer/Architect immediately. Consulting Engineer/Architect will help effect resolution and transmit a revised invoice, if necessary. Amounts not questioned by City shall be paid to Consulting Engineer/Architect in accordance with the contract payment procedures.
