Certificate of Substantial Completion The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the City when construction is sufficiently complete, in accordance with the Contract Documents, so the City of Roanoke, Virginia (City or Owner) can occupy or utilize the Work or designated portion thereof for the use for which it is intended, as expressed in the Contract Documents. ITB NO.: PROJECT: CONTRACTOR: PROJECT OR DESIGNATED PORTION SHALL INCLUDE: The Work or portion thereof designated above performed under this Contract has been reviewed and found to be substantially complete. The Date of Substantial Completion of the Project or portion thereof designated above is hereby established as . The City will assume possession thereof at a.m./p.m. on that date. A list of items ("punch list"), prepared by the A/E and/or Director, Department of Public Works, to be completed or corrected by the Contractor, is attached hereto. The failure to include any items on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. The Contractor will complete any portion of the Work that is not substantially complete and will complete or correct the work on the punch list in accordance with the Contract Documents. The establishment of a date of substantial completion and/or the acceptance of the Work or designated portion thereof does not relieve the Contractor of any responsibility for any faulty materials or workmanship or operate to relieve the Contractor or its Surety from any obligation under the Contract with the City or the Performance Bond or Labor and Material Payment Bond. This Certificate is subject to the terms and conditions of the Contract Documents, including but not limited to Section 20.8 of the General Conditions. Contractor By Date City of Roanoke, Virginia City By Date CITY OF ROANOKE, VIRGINIA AFFIDAVIT OF PAYMENT OF CLAIMS By: This day personally appeared before me, , and, being by me first duly sworn states that all subcontractors and suppliers of labor and materials have been paid all sums due them for work performed or materials furnished in the performance of the Contract between the City of Roanoke, Virginia, and ,Contractor, dated , 20 , for or arrangements have been made by the Contractor satisfactory to such subcontractors and suppliers with respect to the payment of such sums as may be due from the Contractor to the subcontractors and suppliers. COMMONWEALTH OF VIRGINIA CITY/COUNTY OF I, , a Notary Public in and for the Commonwealth of Virginia, do hereby certify that , whose name is signed to the foregoing, has subscribed, sworn to and acknowledged the same before me this day of , 20 . Seal: Notary Public Registration #: My Commission Expires:
FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such
9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees.
9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims.
9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from:
(a) unsettled liens,
(b) faulty or defective Work appearing after Substantial Completion,
(c) failure of the Work to comply with the requirements of the Contract Documents, or
(d) terms of any special warranties required by the Contract Documents.
9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.
Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.
Certificate of Completion The Interconnection Customer shall provide the EDC with a completed copy of the Interconnection Agreement Certificate of Completion, including evidence of the electrical inspection performed by the local authority having jurisdiction. The evidence of completion of the electrical inspection may be provided on inspection forms used by local inspecting authorities. The Interconnection request shall not be finally approved until the EDC’s representative signs the Interconnection Agreement Certificate of Completion.
Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.
Completion of Review for Certain Subject Receivables Following the delivery of the list of the Subject Receivables and before the delivery of the Review Report by the Asset Representations Reviewer, the Servicer may notify the Asset Representations Reviewer if a Subject Receivable is paid in full by or on behalf of the Obligor or purchased from the Issuer by the Sponsor or the Servicer in accordance with the Transaction Documents. On receipt of notice, the Asset Representations Reviewer will immediately terminate all Tests of such Receivables and the Asset Review of such Receivables will be considered complete (a “Test Complete”). In this case, the Review Report will indicate a Test Complete for the Receivables and the related reason.
Withdrawal from Agreement A. Any Fund may elect to withdraw from this Agreement effective at the end of any monthly period by giving at least 90 days’ prior written notice to each of the parties to this Agreement. Upon the written demand of all other Funds which are parties to this Agreement a Fund shall withdraw, and in the event of its failure to do so shall be deemed to have withdrawn, from this Agreement; such demand shall specify the date of withdrawal which shall be at the end of any monthly period at least 90 days from the time of service of such demand.
B. In the event of the withdrawal of any Fund from this Agreement, all its rights and obligations, except for lease commitments, under this Agreement (except such rights or obligations as have accrued prior to the date of withdrawal) shall terminate as of the date of the withdrawal. The withdrawing Fund shall surrender its Shares to Service Company, and (1) shall be entitled to receive from Service Company an amount equal to the excess of the fair value of (i) its Shares of other securities Service Company as of the date of its withdrawal less (ii) its proportionate interest in any liabilities of Service Company, including when appropriate any commitments of Service Company and unexpired leases at the date of withdrawal; (2) shall be obligated to pay Service Company an amount equal to the excess of (ii) over (i). Such amount to be received from or paid to Service Company shall be determined by the favorable vote of the holders of a majority of the Shares whose determination shall be conclusive upon the Funds. Any amount found payable by the Service Company to the withdrawing Fund shall be recoverable by Service Company from the Funds remaining under this Agreement in accordance with the provisions of Section 1.2, 1.3 and 1.4 hereof.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Collection of Taxes, Assessments and Similar Items; Escrow Accounts (a) To the extent required by the related Mortgage Note and not violative of current law, the Master Servicer shall establish and maintain one or more accounts (each, an "Escrow Account") and deposit and retain therein all collections from the Mortgagors (or advances by the Master Servicer) for the payment of taxes, assessments, hazard insurance premiums or comparable items for the account of the Mortgagors. Nothing herein shall require the Master Servicer to compel a Mortgagor to establish an Escrow Account in violation of applicable law.
(b) Withdrawals of amounts so collected from the Escrow Accounts may be made only to effect timely payment of taxes, assessments, hazard insurance premiums, condominium or PUD association dues, or comparable items, to reimburse the Master Servicer out of related collections for any payments made pursuant to Sections 3.01 hereof (with respect to taxes and assessments and insurance premiums) and 3.09 hereof (with respect to hazard insurance), to refund to any Mortgagors any sums determined to be overages, to pay interest, if required by law or the terms of the related Mortgage or Mortgage Note, to Mortgagors on balances in the Escrow Account or to clear and terminate the Escrow Account at the termination of this Agreement in accordance with Section 9.01 hereof. The Escrow Accounts shall not be a part of the Trust Fund.
(c) The Master Servicer shall advance any payments referred to in Section 3.06(a) that are not timely paid by the Mortgagors on the date when the tax, premium or other cost for which such payment is intended is due, but the Master Servicer shall be required so to advance only to the extent that such advances, in the good faith judgment of the Master Servicer, will be recoverable by the Master Servicer out of Insurance Proceeds, Liquidation Proceeds or otherwise.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain.
(b) Employees shall not be required to start a concrete pour in Inclement Weather.
(c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear.
(d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay.
(e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
