Guaranty Obligations Unless otherwise specified, the amount of any Guaranty Obligation shall be the lesser of the principal amount of the obligations guaranteed and still outstanding and the maximum amount for which the guaranteeing Person may be liable pursuant to the terms of the instrument embodying such Guaranty Obligation.
Reaffirmation of Credit Party Obligations Each Credit Party hereby ratifies the Credit Agreement and acknowledges and reaffirms (a) that it is bound by all terms of the Credit Agreement applicable to it and (b) that it is responsible for the observance and full performance of its respective Credit Party Obligations.
Guaranty of the Obligations Subject to the provisions of Section 7.2, Guarantors jointly and severally hereby irrevocably and unconditionally guaranty to Administrative Agent for the ratable benefit of the Beneficiaries the due and punctual payment in full of all Obligations when the same shall become due, whether at stated maturity, by required prepayment, declaration, acceleration, demand or otherwise (including amounts that would become due but for the operation of the automatic stay under Section 362(a) of the Bankruptcy Code, 11 U.S.C. § 362(a)) (collectively, the “Guaranteed Obligations”).
Reinstatement of Guarantied Obligations If claim is ever made on the Administrative Agent or any other Guarantied Party for repayment or recovery of any amount or amounts received in payment or on account of any of the Guarantied Obligations, and the Administrative Agent or such other Guarantied Party repays all or part of said amount by reason of (a) any judgment, decree or order of any court or administrative body of competent jurisdiction, or (b) any settlement or compromise of any such claim effected by the Administrative Agent or such other Guarantied Party with any such claimant (including the Borrower or a trustee in bankruptcy for the Borrower), then and in such event each Guarantor agrees that any such judgment, decree, order, settlement or compromise shall be binding on it, notwithstanding any revocation hereof or the cancellation of the Credit Agreement, any of the other Loan Documents, or any other instrument evidencing any liability of the Borrower, and such Guarantor shall be and remain liable to the Administrative Agent or such other Guarantied Party for the amounts so repaid or recovered to the same extent as if such amount had never originally been paid to the Administrative Agent or such other Guarantied Party.
Surety Obligations No Borrower or Subsidiary is obligated as surety or indemnitor under any bond or other contract that assures payment or performance of any obligation of any Person, except as permitted hereunder.
Warranty Obligations
(a) Project Co represents, warrants and covenants that:
(i) the Works shall conform to the requirements of this Project Agreement, Good Industry Practice, Applicable Law and all professional engineering principles generally accepted as standards of the industry in the Province of Ontario;
(ii) the Works shall be free of defects, including design defects, errors and omissions; and
(iii) materials and equipment shall be of good quality and in compliance with this Project Agreement.
(b) During the Warranty Period and subject to Section 11.15(c), Project Co shall promptly, at its sole cost and expense, correct and Make Good all Construction Defects arising in respect of the Works. For greater certainty, Project Co is required to correct and Make Good Construction Defects related to any Product during the applicable Warranty Period despite Project Co having obtained on Contracting Authority’s behalf industry- standard or other equipment warranties in accordance with Section 11.15(f). For all work to correct Construction Defects, the applicable Warranty Period shall be extended for a further two years from the date of the last work completed in respect of such corrective Works. For clarity, any extension of a Warranty Period for the purposes of a correction shall only apply to the relevant Construction Defect and not the Works as a whole.
(c) In addition to the obligation to correct and Make Good Construction Defects during the Warranty Period, Project Co shall at its expense correct and Make Good any Construction Defects that could not reasonably have been ascertained by a competent person in accordance with Good Industry Practice during a visual inspection of the Works (“Construction Latent Defect”), provided Contracting Authority gives Project Co written Notice of the Construction Latent Defect within the time frame applicable to such Construction Latent Defect pursuant to the Limitations Act, 2002 (Ontario).
(d) The warranties described in this Section 11.15 shall cover labour and material, including, the costs of removal and replacement of covering materials. The warranties shall not limit extended warranties on any Product or item of equipment called for elsewhere in the Output Specifications or otherwise provided by any manufacturer of such Product or equipment.
(e) If Project Co fails to correct and Make Good any Construction Defects or Construction Latent Defects in accordance with Sections 11.15(b) and 11.15(c) and in the time period specified in Section 11.16(a) or Section 11.16(b), as applicable, without prejudice to any other right or remedy Contracting Authority may have, Contracting Authority may correct such Construction Defects or Construction Latent Defects at Project Co’s sole cost and expense.
(f) Project Co shall obtain warranties from the manufacturers of each of the Products for the duration(s) and in accordance with the applicable requirements specified in the Output Specifications in the name of and to the benefit of both Project Co and Contracting Authority. Where, in respect of a Product warranty, the Output Specifications do not specify a specific duration and/or other requirements, Project Co shall obtain industry-standard warranties from the applicable manufacturers in the name of and to the benefit of Project Co and Contracting Authority which shall extend no less than two years from the Substantial Completion Date. Each Product warranty shall be issued by the applicable manufacturer and delivered to Project Co no later than 30 days prior to the Substantial Completion Date. Project Co shall ensure that each Product warranty, including any Product warranty extended under this Section 11.15(f), is fully assigned to Contracting Authority, at no cost or expense to Contracting Authority, at the end of the Warranty Period, as such Warranty Period may be extended in accordance with Section 11.15(b).
Credit Agreement; Guarantee and Collateral Agreement The Administrative Agent shall have received (i) this Agreement, executed and delivered by the Administrative Agent, Holdings, the Borrower and each Person listed on Schedule 1.1A and (ii) the Guarantee and Collateral Agreement, executed and delivered by Holdings, the Borrower and each Subsidiary Guarantor.
Agents under Collateral Documents and Guaranty Each Secured Party hereby further authorizes Administrative Agent or Collateral Agent, as applicable, on behalf of and for the benefit of Secured Parties, to be the agent for and representative of Secured Parties with respect to the Guaranty, the Collateral and the Collateral Documents; provided that neither Administrative Agent nor Collateral Agent shall owe any fiduciary duty, duty of loyalty, duty of care, duty of disclosure or any other obligation whatsoever to any holder of Obligations with respect to any Hedge Agreement. Subject to Section 10.5, without further written consent or authorization from any Secured Party, Administrative Agent or Collateral Agent, as applicable may execute any documents or instruments necessary to (i) in connection with a sale or disposition of assets permitted by this Agreement, release any Lien encumbering any item of Collateral that is the subject of such sale or other disposition of assets or to which Requisite Lenders (or such other Lenders as may be required to give such consent under Section 10.5) have otherwise consented or (ii) release any Guarantor from the Guaranty pursuant to Section 7.12 or with respect to which Requisite Lenders (or such other Lenders as may be required to give such consent under Section 10.5) have otherwise consented. Collateral Agent further declares that it holds all Australian Collateral acquired by the Collateral Agent after the date hereof on trust for the benefit of the Secured Parties from time to time (it being understood that the provisions of this Section 9 apply to Collateral Agent in its capacity as trustee of such trust).
Issuing Bank’s Duties Regarding Letters of Credit; Unconditional Nature of Reimbursement Obligations In examining documents presented in connection with drawings under Letters of Credit and making payments under such Letters of Credit against such documents, the Issuing Bank shall only be required to use the same standard of care as it uses in connection with examining documents presented in connection with drawings under letters of credit in which it has not sold participations and making payments under such letters of credit. The Borrower assumes all risks of the acts and omissions of, or misuse of the Letters of Credit by, the respective beneficiaries of such Letters of Credit. In furtherance and not in limitation of the foregoing, none of the Issuing Bank, Administrative Agent or any of the Lenders shall be responsible for, and the Borrower’s obligations in respect of Letters of Credit shall not be affected in any manner by, (i) the form, validity, sufficiency, accuracy, genuineness or legal effects of any document submitted by any party in connection with the application for and issuance of or any drawing honored under any Letter of Credit even if such document should in fact prove to be in any or all respects invalid, insufficient, inaccurate, fraudulent or forged; (ii) the validity or sufficiency of any instrument transferring or assigning or purporting to transfer or assign any Letter of Credit, or the rights or benefits thereunder or proceeds thereof, in whole or in part, which may prove to be invalid or ineffective for any reason; (iii) failure of the beneficiary of any Letter of Credit to comply fully with conditions required in order to draw upon such Letter of Credit; (iv) errors, omissions, interruptions or delays in transmission or delivery of any messages, by mail, cable, facsimile, electronic mail, telecopy or otherwise, whether or not they be in cipher; (v) errors in interpretation of technical terms; (vi) any loss or delay in the transmission or otherwise of any document required in order to make a drawing under any Letter of Credit, or of the proceeds thereof; (vii) the misapplication by the beneficiary of any Letter of Credit, or of the proceeds of any drawing under any Letter of Credit; or (viii) any consequences arising from causes beyond the control of the Issuing Bank, Administrative Agent or the Lenders. None of the above shall affect, impair or prevent the vesting of any of the Issuing Bank’s or Administrative Agent’s rights or powers hereunder. Any action taken or omitted to be taken by the Issuing Bank under or in connection with any Letter of Credit, if taken or omitted in the absence of gross negligence or willful misconduct (as determined by a court of competent jurisdiction in a final, non-appealable judgment), shall not create against the Issuing Bank any liability to the Borrower, the Administrative Agent or any Lender. In this connection, the obligation of the Borrower to reimburse the Issuing Bank for any drawing made under any Letter of Credit, and to repay any Revolving Loan made pursuant to the second sentence of the immediately preceding subsection (e), shall be absolute, unconditional and irrevocable and shall be paid strictly in accordance with the terms of this Agreement and any other applicable Letter of Credit Document under all circumstances whatsoever, including without limitation, the following circumstances: (A) any lack of validity or enforceability of any Letter of Credit Document or any term or provisions therein; (B) any amendment or waiver of or any consent to departure from all or any of the Letter of Credit Documents; (C) the existence of any claim, setoff, defense or other right which the Borrower may have at any time against the Issuing Bank, the Administrative Agent or any Lender, any beneficiary of a Letter of Credit or any other Person, whether in connection with this Agreement, the transactions contemplated hereby or in the Letter of Credit Documents or any unrelated transaction; (D) any breach of contract or dispute between the Borrower, the Issuing Bank, the Administrative Agent, any Lender or any other Person; (E) any demand, statement or any other document presented under a Letter of Credit proving to be forged, fraudulent, invalid or insufficient in any respect or any statement therein or made in connection therewith being untrue or inaccurate in any respect whatsoever; (F) any non-application or misapplication by the beneficiary of a Letter of Credit or of the proceeds of any drawing under such Letter of Credit; (G) payment by the Issuing Bank under any Letter of Credit against presentation of a draft or certificate which does not strictly comply with the terms of such Letter of Credit; and (H) any other act, omission to act, delay or circumstance whatsoever that might, but for the provisions of this Section, constitute a legal or equitable defense to or discharge of the Borrower’s Reimbursement Obligations. Notwithstanding anything to the contrary contained in this Section or Section 12.10., but not in limitation of the Borrower’s unconditional obligation to reimburse the Issuing Bank for any drawing made under a Letter of Credit as provided in this Section and to repay any Revolving Loan made pursuant to the second sentence of the immediately preceding subsection (e), the Borrower shall have no obligation to indemnify the Administrative Agent, the Issuing Bank or any Lender in respect of any liability incurred by the Administrative Agent, the Issuing Bank or such Lender arising solely out of the gross negligence or willful misconduct of the Administrative Agent, the Issuing Bank or such Lender in respect of a Letter of Credit as determined by a court of competent jurisdiction in a final, non-appealable judgment. Except as otherwise provided in this Section, nothing in this Section shall affect any rights the Borrower may have with respect to the gross negligence or willful misconduct of the Administrative Agent, the Issuing Bank or any Lender with respect to any Letter of Credit.
Performance of Borrowers’ Obligations Agent may, in its discretion at any time and from time to time, at Borrowers’ expense, pay any amount or do any act required of a Borrower under any Loan Documents or otherwise lawfully requested by Agent to (a) enforce any Loan Documents or collect any Obligations; (b) protect, insure, maintain or realize upon any Collateral; or (c) defend or maintain the validity or priority of Agent’s Liens in any Collateral, including any payment of a judgment, insurance premium, warehouse charge, finishing or processing charge, or landlord claim, or any discharge of a Lien. All payments, costs and expenses (including Extraordinary Expenses) of Agent under this Section shall be reimbursed to Agent by Borrowers, on demand, with interest from the date incurred to the date of payment thereof at the Default Rate applicable to Base Rate Revolver Loans. Any payment made or action taken by Agent under this Section shall be without prejudice to any right to assert an Event of Default or to exercise any other rights or remedies under the Loan Documents.
