Breach and Remedies If Seller discovers or is notified of a security breach or potential security breach based on the restrictions contained in this article (“Security Breach”), Seller immediately shall: (i) cease access to any Proprietary Information and Materials that are the subject of the Security Breach and shall not review any Unauthorized Proprietary Information and Materials; (ii) provide notice to Buyer, including notice of the materials involved in the Security Breach, by sending notice to xxxxx@xxxxxx.xxx and to Buyer’s Authorized Procurement Representative for this Contract; and (iii) assist Xxxxx in investigating, remedying, and taking any other action Buyer deems necessary to address such Security Breach, including related to any dispute, inquiry, or claim related to such Security Breach. Seller agrees to permit Buyer to review its security control procedures and practices via physical or electronic access by Buyer, including access to Seller facilities in which such systems are located, as well as any and all premises where maintenance, storage or backup activities are performed. Any material breach of this article by Seller may be considered a default for which Buyer may suspend Electronic Access and/or cancel this Contract, and any other contracts between Buyer and Seller, in accordance with the "Cancellation for Default" article of this Contract. Further, Seller acknowledges that any attempts by Seller or any Seller Personnel to circumvent any security measures designed to prevent unauthorized access to the Boeing Systems may be subject to criminal or civil penalties under the U.S. Federal Computer Fraud and Abuse Act and other applicable laws and regulations.
Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.
Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.
BREACH AND TERMINATION 22.1 Termination in accordance with clause 6 [Term and Cancellation] shall not prejudice or affect any right of action or remedy which shall have accrued or shall thereafter accrue to either Party and all provisions which are to survive this Agreement or impliedly do so shall remain in force and in effect.
Indemnification Claims (a) An Indemnified Party shall give written notification to the Indemnifying Party of the commencement of any Third Party Action. Such notification shall be given within 20 days after receipt by the Indemnified Party of notice of such Third Party Action, and shall describe in reasonable detail (to the extent known by the Indemnified Party) the facts constituting the basis for such Third Party Action and the amount of the claimed damages; provided, however, that no delay or failure on the part of the Indemnified Party in so notifying the Indemnifying Party shall relieve the Indemnifying Party of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such Third Party Action with counsel reasonably satisfactory to the Indemnified Party; provided that (i) the Indemnifying Party may only assume control of such defense if (A) it acknowledges in writing to the Indemnified Party that any Damages that may be assessed against the Indemnified Party in connection with such Third Party Action constitute Damages for which the Indemnified Party shall be indemnified pursuant to this Article VII and (B) the amount of damages claimed is less than or equal to the amount of Damages for which the Indemnifying Party is liable under this Article VII and (ii) the Indemnifying Party may not assume control of the defense of Third Party Action involving criminal liability or in which equitable relief is sought against the Indemnified Party. If the Indemnifying Party does not, or is not permitted under the terms hereof to, so assume control of the defense of a Third Party Action, the Indemnified Party shall control such defense. The Non-controlling Party may participate in such defense at its own expense. The Controlling Party shall keep the Non-controlling Party advised of the status of such Third Party Action and the defense thereof and shall consider in good faith recommendations made by the Non-controlling Party with respect thereto. The Non-controlling Party shall furnish the Controlling Party with such information as it may have with respect to such Third Party Action (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party in the defense of such Third Party Action. Notwithstanding any other provision of this Agreement, the reasonable fees and expenses of counsel to the Indemnified Party with respect to a Third Party Action shall be considered Damages for purposes of this Agreement if (i) the Indemnified Party controls the defense of such Third Party Action pursuant to the terms of this Section 7.3(a) or (ii) the Indemnifying Party assumes control of such defense and the Indemnified Party reasonably concludes that the Indemnifying Party and the Indemnified Party have conflicting interests or different defenses available with respect to such Third Party Action. The Indemnifying Party shall not agree to any settlement of, or the entry of any judgment arising from, any Third Party Action without the prior written consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed. If the Indemnified Party withholds its consent to any such settlement or entry of judgment which settlement or entry of judgment relates to cash Damages only, then the liability of the Indemnifying Party to the Indemnified Party with respect to the matter which would have been concluded or settled shall be limited to the amount for which such matters could have been concluded or settled but for the fact the Indemnified Party withheld its consent. The Indemnified Party shall not agree to any settlement of, or the entry of any judgment arising from, any such Third Party Action without the prior written consent of the Indemnifying Party, which shall not be unreasonably withheld, conditioned or delayed.
Third Party Claims If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a party to this Agreement or an Affiliate of a party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) calendar days after receipt of such notice of such Third-Party Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have the right to participate in, or by giving written notice to the Indemnified Party, to assume the defense of any Third-Party Claim at the Indemnifying Party’s expense and by the Indemnifying Party’s own counsel, and the Indemnified Party shall cooperate in good faith in such defense. In the event that the Indemnifying Party assumes the defense of any Third-Party Claim, subject to Section 8.03(b), it shall have the right to take such action as it deems necessary to avoid, dispute, defend, appeal or make counterclaims pertaining to any such Third-Party Claim in the name and on behalf of the Indemnified Party. The Indemnified Party shall have the right to participate in the defense of any Third-Party Claim with counsel selected by it subject to the Indemnifying Party’s right to control the defense thereof, provided that the fees and disbursements of such counsel shall be at the expense of the Indemnified Party.
Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).
