Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.
Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.
Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.
CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is April 25, 2016. The completion date for this contract is October 15, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Xxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Payments from the Gross Settlement Amount Within 14 days after Defendants fund the Gross Settlement Amount, the Administrator will mail checks for all Individual Class Payments, all Individual PAGA Payments, the LWDA PAGA Payment, the Administration Expenses Payment, the Class Counsel Fees Payment, the Class Counsel Litigation Expenses Payment, and the Class Representative Service Payment. Disbursement of the Class Counsel Fees Payment, the Class Counsel Litigation Expenses Payment and the Class Representative Service Payment shall not precede disbursement of Individual Class Payments and Individual PAGA Payments.
4.4.1. The Administrator will issue checks for the Individual Class Payments and/or Individual PAGA Payments and send them to the Class Members via First Class U.S. Mail, postage prepaid. The face of each check shall prominently state the date (not less than 180 days after the date of mailing) when the check will be voided. The Administrator will cancel all checks not cashed by the void date. The Administrator will send checks for Individual Settlement Payments to all Participating Class Members (including those for whom Class Notice was returned undelivered). The Administrator will send checks for Individual PAGA Payments to all Aggrieved Employees including Non-Participating Class Members who qualify as Aggrieved Employees (including those for whom Class Notice was returned undelivered). The Administrator may send Participating Class Members a single check combining the Individual Class Payment and the Individual PAGA Payment. Before mailing any checks, the Settlement Administrator must update the recipients’ mailing addresses using the National Change of Address Database.
4.4.2. The Administrator must conduct a Class Member Address Search for all other Class Members whose checks are retuned undelivered without USPS forwarding address. Within 7 days of receiving a returned check the Administrator must re-mail checks to the USPS forwarding address provided or to an address ascertained through the Class Member Address Search. The Administrator need not take further steps to deliver checks to Class Members whose re-mailed checks are returned as undelivered. The Administrator shall promptly send a replacement check to any Class Member whose original check was lost or misplaced, requested by the Class Member prior to the void date.
4.4.3. For any Class Member whose Individual Class Payment check or Individual PAGA Payment check is uncashed and cancelled after the void date, the Administrator shall transmit the funds represented by such checks to the California Controller's Unclaimed Property Fund in the name of the Class Member thereby leaving no "unpaid residue" subject to the requirements of California Code of Civil Procedure Section 384, subd. (b).
4.4.4. The payment of Individual Class Payments and Individual PAGA Payments shall not obligate Defendants to confer any additional benefits or make any additional payments to Class Members (such as 401(k) contributions or bonuses) beyond those specified in this Agreement.
Payment of Settlement Amount (1) Within thirty (30) days of the Execution Date, the Settling Defendants shall pay the Settlement Amount to Siskinds LLP for deposit into the Trust Account. The Settlement Amount shall be converted into Canadian currency upon deposit into the Trust Account.
(2) The Settling Defendants shall deposit the Settlement Amount into the Trust Account by wire transfer. Siskinds LLP shall provide the necessary wire transfer information to Counsel for the Settling Defendants with reasonable advance notice so that the Settling Defendants have a reasonable period of time to comply with section 3.1(1) of this Settlement Agreement.
(3) The Settlement Amount and other consideration to be provided in accordance with the terms of this Settlement Agreement shall be provided in full satisfaction of the Released Claims against the Releasees.
(4) The Settlement Amount shall be all-inclusive of all amounts, including without limitation, interest, costs, Class Counsel Fees and Class Counsel Disbursements.
(5) The Releasees shall have no obligation to pay any amount in addition to the Settlement Amount, for any reason, pursuant to or in furtherance of this Settlement Agreement or the Proceedings or any Other Actions.
(6) Once a Claims Administrator has been appointed, Siskinds LLP shall transfer control of the Trust Account to the Claims Administrator.
(7) Siskinds LLP and the Claims Administrator shall maintain the Trust Account as provided for in this Settlement Agreement. While in control of the Trust Account, Siskinds LLP and the Claims Administrator shall not pay out all or part of the monies in the Trust Account, except in accordance with this Settlement Agreement, or in accordance with an order of the Courts obtained after notice to the Parties.
